Hydropower Maintenance Agreement 1 Employer (hereinafter referred to as Party A):
Contractor (hereinafter referred to as Party B):
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC), the Labor Law of People's Republic of China (PRC) and the relevant laws and administrative regulations within the jurisdiction where the project is located, following the principles of equality, voluntariness, honesty and credit, and combining with the specific conditions of the construction site, Party A contracts this project: the hydropower installation project of B8 plot in Dayu New Town to _ _.
I. Overview of the Project
Name of construction unit: Kunming Dianchi National Tourism Resort State-owned Assets Investment Management Co., Ltd.
Project Name: Hydropower Installation of B8 Plot of Dayu New City Phase I in Dianchi National Tourism Resort, Kunming
Structure type: concrete frame structure
Construction site: Dayu District, Dianchi National Tourism Resort, Kunming
Bidding (building number):
Building area (water and electricity installation): subject to the actual completed civil construction area of each labor contract.
Total construction area: subject to the actually completed civil engineering area.
Two. Number of participants of Party B (list attached)
According to relevant national regulations, Party B employs temporary workers and signs a labor service construction agreement. According to the contents undertaken by this project, Party B will organize the required types of workers to enter the site, and handle the employment permit with my ID card, health certificate and marriage certificate to the relevant administrative department according to the Measures for the Administration of Floating Workers in Kunming, so as to achieve "three certificates are complete". Related jobs and special jobs must hold relevant certificates, and irrelevant personnel are not allowed to enter the site.
Third, the schedule requirements
(1) Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
(2) Total (calendar) construction period: _ _ _ _ months
(3) The specific construction period and work content must be completed according to the progress node formulated by Party A. ..
Fourth, the way and scope of contracting.
(1) contract mode: contract work, quality, auxiliary materials, tools, construction period, safe and civilized construction.
(2) Scope of contract:
1. Water supply and drainage installation: water supply pipes are installed to households, drainage pipes are installed to septic tanks, floor drains are installed, valves and test taps are installed, and cast iron pipes are anticorrosion.
2. Electrical installation: including embedding of threading pipe, threading in pipe, bridge installation, electrical box installation, lightning protection and grounding, and lamp installation; Installation of indoor switch socket, equipotential connection, water pump, power box, electric control box and other equipment.
3. Weak current installation: installation of user box, telephone, TV and broadband conduit embedded bottom box, installation of conduit embedded bottom box of building intercom system, etc.
4. The construction scope of all divisions and subdivisional works listed in the design drawings and bidding documents.
5. Hydropower test, water supply test, power supply test, etc.
6. The contents of auxiliary materials used within the scope of design drawings; Work scope of Party B: 1, the above-ground parts of Buildings 2, 5 and 6 (including-2.70m floors).
7. The foreman and management personnel shall be allocated by Party B, and the expenses shall be borne by Party B. ..
(3) The corresponding unit price of the project contracted by Party B: total _ _ _ yuan/㎡, with a total price of _ _ _ ten thousand yuan.
1. Party B shall be responsible for purchasing accident insurance for its employees for labor costs and water and electricity installation and management fees within the scope of engineering drawings.
2. Costs of all tools, such as fixed tools, hand tools, welding machines, threading machines, grooving machines, welding machines, cutting machines and testing tools; Water, electricity and loading and unloading fees for materials.
3. Accessories refer to oxygen, acetylene, foam, tie wire, steel wire, iron wire, nails, expansion screws, sealant tape, saw blade, grinding wheel cutting piece, insulating tape, hoop, covered electrode, toothless saw blade, marble machine piece, polishing machine piece, sealing strip, sponge strip, safety helmet, safety belt, insulating shoes, glasses, rain boots and raincoat. Glue, broom, roller brush, striped cloth, work gloves, dust mask, plastic cloth, nylon rope, bamboo broom, broom, hemp rope, hose, sprayer, adhesive tape, chalk, low-pressure light bulb, cotton yarn, various paints, thinners, gasoline, engine oil, butter, gear lubricating oil, alcohol, decontamination powder and interface agent.
4. Other subcontracting teams and teams that need water and electricity cooperation (such as fire fighting, ventilation, lighting, construction wires, electricity meters, etc.). ). When Party B enters the site for construction, Party B shall provide .. The public facilities used in the construction shall be borne by Party B. ..
5. For the design change, if the labor cost increases within 6,543,800 yuan, Party A will not make up the price for Party B; If it exceeds 654.38+00000 yuan, the excess shall be paid according to the actual price.
Verb (abbreviation for verb) Engineering requirements:
(1) Quality requirements: Organize the construction according to ISO9002 quality standards and engineering quality acceptance standards.
1. It must have corresponding engineering technology and organizational management capabilities within the scope of its contracted work, and be able to independently perform corresponding on-site management responsibilities. The construction personnel must also have corresponding qualifications, operation certificates and work licenses.
2. Party B must carry out the construction in accordance with the relevant national codes and standards, design drawings (including written notice) and construction organization design requirements, and all parts of the project must be qualified for acceptance, and pass the filing to reach the qualified standards.
3. Party B must actively cooperate with Party A, truthfully record the construction process, and accept Party A's quality inspection, on-site visa and various tests.
4. For the detected nonconforming products (items), Party B must unconditionally and timely rectify them until the quality inspection meets the requirements.
5. Party B must be responsible for the effective protection of semi-finished products and finished products, and its protection measures must be approved by Party A in advance to ensure the quality of products submitted for inspection.
6. Party B must be equipped with corresponding technical personnel and management personnel. If Party B's technology is not in place or he doesn't understand the drawings, he will make mistakes, omissions and rework. Party B shall not only bear the labor cost and construction period, but also compensate the corresponding material cost.
7. Party A advocates all construction parties to carry out competitions on progress, quality, safety and civilized construction, with technology compared with management, progress compared with quality and safety compared with civilized construction, and rewards good units. If the management progress, quality, safety and civilized construction are seriously insufficient, or the rectification by the construction unit, supervision personnel and management personnel of Party A is not in place, the corresponding economic punishment will be given, and the serious cases will be retired.
8. The warranty period is two years.
(2) Time limit for a project requirements
1. Party B must organize the construction according to the progress plan formulated by Party A, and accept the inspection, rectification and supervision of the progress by the supervision unit, the owner and the project construction management personnel of Party A; When the actual progress of the project is inconsistent with the construction progress plan, Party B shall put forward rectification measures according to the requirements of the owner, supervision engineer or Party A, and implement them after confirmation.
2, the time limit for a project delay
(1) Party B shall take the initiative to construct, and the embedded pipes shall not be arranged separately, and the water and electricity embedment shall be completed when the steel bar installation is completed.
(2) If the construction period is delayed due to Party B's own reasons, Party B shall bear all losses (including fines imposed by the constructor); Party A will impose a double fine on Party B. ..
(3) Cost control requirements
1. Party B must carry out scientific management and reasonable construction to avoid the occurrence of slowdown; Strive to improve work efficiency and implement the principles of saving water, electricity and materials.
2. All kinds of engineering materials must be picked up in a limited amount, and Party B shall bear all excess consumption, waste caused by Party B's rework and engineering losses caused by rework delay.
3. If Party B uses Party A's materials, it must be approved and signed by Party A before it can be used.
4. If the materials brought out by Party B are lost or damaged, Party B shall go to double indemnity.
5. Party B must abide by Party A's material management system.
(4) Safety construction requirements
1. Party A shall provide Party B with safety technical disclosure and safety education.
2. Party B must abide by the laws, regulations, rules and operating procedures of production safety, and organize construction inspection in strict accordance with the requirements of "one standard and three specifications".
3. Party B must conduct safety education for its employees. Without safety technical disclosure and safety education, Party B shall not operate at his post, command or operate illegally.
4. Party B shall do a good job in labor protection, handle accident insurance for its operators according to relevant national regulations, and submit the receipt to Party A for filing.
5. Party B's work injury, death and disability (including those caused by Party B) in the construction process shall be handled according to the provisions of the Reply of the General Office of the Ministry of Labor on How to Confirm the Subject of Temporary Employment, and Party B shall bear all the responsibilities, but Party A shall not bear them.
Settlement formula of intransitive verbs
Pre-tender estimate settlement method: In principle, according to Party B's construction progress, the project payment shall be settled with the labor fee agreed by both parties.
1. After reporting each successful project progress payment to the employer, Party A shall pay 70% of the labor fee to Party B..
2. After one-time completion acceptance of installation and commissioning, Party A shall pay 95% of the labor cost to Party B within 30 days after completing the project completion settlement formalities with the Employer.
3, 5% maintenance quality deposit, one-time payment after two years.
4. During the warranty period, due to quality problems, Party A informs Party B to carry out maintenance. If Party B fails to carry out maintenance in time, Party A has the right to deduct the maintenance quality deposit in proportion.
Seven. Handling of liability for breach of contract
(1) In any of the following circumstances, it shall be deemed as a breach of contract:
1. The construction quality of Party B's project fails to meet all the engineering requirements listed in this agreement;
2. Party B subcontracts or subcontracts the contracted project without authorization;
3. Other negligent acts that cause various losses of the project;
4. Party B fails to perform or change everything without authorization, and unilaterally terminates this Agreement.
5. Disobeying the management of Party A. ..
(2) liquidated damages
1. Party A has the right to prove Party B's breach of contract by failing to carry out the construction according to the quality schedule orally and in writing. If Party B fails to rectify in time, Party A has the right to terminate the contract and compensate the losses caused thereby.
2. The observant party has the right to investigate other breach of contract of the defaulting party and impose a penalty of 30,000 yuan.
3. Party B must guarantee to pay the wages and living expenses of its own labor force and put an end to the use of child labor. In case of labor disputes among the members of Party B's labor service team during the construction period and within 3 months after the completion and acceptance, the labor supervision department will impose a fine of1000 ~ 5,000 yuan each time.
4. If Party B fails to properly manage the materials, Party A will impose a one-time fine of 65,438+0,000 ~ 5,000 yuan on Party B..
5. If Party B does not obey the management of Party A, and fails to make timely rectification, it will be fined 20xx~5000 yuan each time.
(3) Other reward and punishment agreements.
In case of public security cases, in addition to Party B's own responsibilities, Party A will also be punished, with the first fine of 10000 yuan. If it happens again, Party B will automatically accept the unconditional exit, and Party B will be responsible for the engineering losses caused thereby.
Nine. Supplementary terms:
(1) In case of any dispute arising from this agreement, both parties shall negotiate in time. If negotiation fails, both parties may apply to the economic contract promotion committees at all levels for arbitration or bring a lawsuit directly to the people's court. However, during the dispute settlement, the project construction shall not be affected under any circumstances. If the normal construction is affected for more than two days, it shall be deemed that Party B automatically terminates the agreement, and Party B shall bear all the responsibilities, and Party A has the right to find another labor force.
(2) The construction group insurance for on-site personnel shall be purchased by Party B, and Party B may purchase other types of insurance as a supplement. In case of any accident, Party B shall handle it together with the insurance company and the parties (or their relatives). If the expenses involved are beyond the scope of the insurance company, Party B shall bear them.
(3) This Agreement is made in sextuplicate, with Party A holding five copies and Party B holding one copy. The agreements held by both parties have the same legal effect.
(IV) The annex to this agreement is the division of bid sections.
(V) This Agreement shall come into force as of the date of signature by both parties and automatically become invalid after the project warranty period ends.
Party A (seal): _ _ _ Party B (seal): _ _ _
Legal Person of Party A _ _ Legal Person of Party B _ _
Or entrusted agent (signature) _ _ or entrusted agent (signature)
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Water and electricity maintenance agreement II Party A:
Party B:
The primary school was appraised by the higher authorities and decided to lay bricks on the main road of the campus to maintain the garden. According to the required quality standards, Party A and Party B shall jointly supervise the construction and decide the contracting method of the project and materials. We hereby sign the following agreement:
I. Building materials: Building materials
Fine sand, cement, red bricks and other high-quality materials will be used to repair the garden and lay the main roads.
Second, the construction plan
1. The school entrusts Party B with full authority to implement the construction.
2. The school will jointly supervise the construction with Party B in the form of contracting and materials.
3. Both Party A and Party B should participate in the measurement of pavement area.
4. Check the quality acceptance when the project is completed.
Third, the material construction employment accounting
Garden maintenance: 220m× 25 yuan /m = 5500 yuan.
Paving campus 1456 m2× 5 yuan /m2 =7280 yuan.
The total cost is estimated to be 12780 yuan.
Fourth, the construction time
20xx August 2 1 to September 8, 20xx.
Verb (abbreviation for verb) building safety
In case of safety accidents and material losses during the construction period, the school will not bear the responsibility, and Party B will bear all the responsibilities.
This agreement is made in triplicate and will come into effect after being signed by both parties.
Signature of Party A:
Signature of Party B:
Xx，xx，XX，XX
Third Owner of Water and Electricity Maintenance Agreement (Party A): Yangjiabao Primary School
Contractor (Party B): Zhang
According to the Contract Law of People's Republic of China (PRC) and relevant laws and administrative regulations, Party A and Party B, following the principles of equality, fairness, honesty and credibility, have reached the following contract terms on Party A's maintenance and construction through friendly negotiation.
1. Project Name: Yangjiabao Primary School Bus Parking Lot Project
Two. Project content: Laying of school bus parking lot in Yangjiabao Primary School.
Three. Construction period: the project will be completed from April 9, 20xx to April 12, 20xx.
Fourth, the specific construction requirements
1. The school bus parking lot is 225m2 on the north lawn outside the school gate.
2, laying foundation with sand compaction.
3. The surface is paved with red bricks, and the east and north sides are paved with inverted teeth bricks.
4, the paved red brick surface sand filling processing.
5. PVC pipes (double pipes) with a length of 23m and a diameter of 70cm are laid under the foundation.
Verb (abbreviation for verb) The responsibility of both parties.
1. Red bricks and inverted bricks required by Party B in the construction shall be transported to the campus by Party B..
2. In the process of completing the entrusted affairs of the school, Party B must unconditionally compensate the school property losses caused by its personal behavior.
3. Party B is responsible for the safety of the entrusted affairs, and Party A does not guarantee it.
4. Party B shall do a good job in safety protection and warning during construction. In case of accidental injury caused by inadequate protection, Party A shall not bear joint liability, and all responsibilities shall be borne by Party B. ..
5. All losses caused by unqualified acceptance due to Party B's failure to complete the entrusted affairs as required by Party A shall be borne by Party B. ..
6. Party B shall be responsible for cleaning up the construction waste generated by the project.
7. Party A is responsible for providing water, electricity and roads, and educating students not to play in the construction site.
8. After the acceptance of the project, the project price shall be subject to the price approved by the Financial Audit Center and the price determined by Party A and Party B through consultation according to the actual engineering quantity, and the project payment shall be paid by Party A in one lump sum.
Party A: (signature) Party B: (signature)
Representative: representative:
Tel: 1383074373 Tel: