In the process of building construction, we will all contract the project, through the contracting contract to clarify the responsibilities and obligations of both parties. Then how to write the canteen contract? The following is a sample canteen contract contract that I have organized for you, for reference only.
Engineering Contract Agreement Template 1
Contractor: _________________ (hereinafter referred to as Party A)
Contractor: _________________ (hereinafter referred to as Party B)
In accordance with the "Chinese People's ** and State Contract Law" by the Chinese Government. ** and State Contract Law" by consensus of both parties, sign this contract and perform it seriously.
Article I Project
1. Name of the project: _________________
2. Location of the project: _________________
3. Project No.: _________________
4. Scope and content of the project: all the project Building area _________ square meters.
5. Project Cost: The budgeted cost of the construction drawings of all projects is RMB _________, of which: labor cost _________. (For details of each individual project, please refer to the list of projects)
Article 2 Project Period
1. Commencement and Completion Dates: In accordance with the working period quota promulgated by the state, the commencement and completion dates of the project under this contract are agreed by both parties as follows:
All the projects have been commenced since the _________ month of _________, and will be completed in the following dates:
All the projects have been commenced since the _________ month of _________, and will be completed in the following dates. _________ completed on _________, _________ (see the list of projects for details of the commencement and completion dates of each individual project).
2. Before the construction of the preparatory work, the two sides should be in accordance with the provisions of Article 3 of the project agreement, respectively, responsible for the completion in accordance with.
3. In the construction process, such as the following circumstances, can be postponed. Extend the period, should be negotiated by both parties in a timely manner, signed the agreement, and reported to the relevant departments for the record.
(1) due to manpower irresistible disasters, and was forced to stop work;
(2) due to changes in plans or changes in construction drawings, and can not continue to construction;
(3) because the Party can not be supplied on schedule for the drawings, materials, equipment, or materials and equipment required is not required, and was forced to stop work can not be constructed smoothly.
Article 3 Material Supply
1. All the materials required for the project shall be supplied according to the following (_________).
(1) Special materials, materials under unified distribution and departmental control, and mechanical and electrical products under unified distribution and departmental control shall be purchased by Party A and supplied to Party B's designated place. Other materials shall be purchased and supplied by Party B.
(2) Uniform and departmental materials, Party B is responsible for application, ordering, transferring and using, special materials and uniform and departmental mechanical and electrical products, Party A is responsible for purchasing and supplying to Party B's designated location, and Party B is responsible for purchasing and supplying all other materials.
(3) The contractor does not include the materials in the project, and all materials and equipments will be purchased and supplied by Party A to the site or the designated processing place.
(4) Other ways: _________
2. The varieties, specifications, quantities and deadlines for the materials and equipment to be supplied by Party A (see the list of materials and equipment to be supplied by Party A).
3. Complete sets of equipment and non-standard equipment, Party A is responsible for application, ordering and processing, the introduction of the establishment of equipment before delivery to Party B, Party A is responsible for the inspection. Party B commissioned by Party B to undertake general contracting equipment ordering and non-standard equipment processing, should sign another agreement.
4. The materials required for the project, such as the supply department's specifications, varieties or materials can not meet the project requirements, must be replaced by other specifications, varieties, or processing, should be obtained in advance from the original design unit and Party A agreed, and signed by the three parties to implement the agreement. As a result of substitution or processing and the amount of difference, price difference and processing fees, should be in accordance with the current provisions of the settlement.
5. Where the materials should be accompanied by a certificate of conformity, in the field must be responsible for the verification of the supply side; if there is no certificate of conformity, it must be tested by the supply side of the qualified before allowing the use of the test costs, should be borne by the supply side. Because of the construction unit or design unit of the factory certificate of conformity of the materials required to re-test, the test costs, should be borne by the Party.
6. Party A is responsible for the supply of materials and equipment, such as the supply on time, or specifications, quality does not meet the requirements, the efforts of both sides can not be resolved, thus causing losses to Party B, shall be borne by Party A.
The fourth article is about the supply of materials and equipment.
Article IV Settlement of Project Costs
1. The settlement of all project costs shall be handled in accordance with the following (_________) provisions.
(1) Settlement is made with the budget of the reviewed construction drawings plus the increase or decrease of the change budget.
(2) Settlement of the lump-sum cost determined by the construction drawing budget plus lump-sum coefficient, and payment of costs outside the lump-sum scope in accordance with the relevant provisions.
(3) According to the standard construction drawings unilateral cost lump sum settlement, lump sum outside the scope of the cost, another payment in accordance with the relevant provisions.
(4) The contractor does not include the material works, according to the budget quota of the labor cost settlement.
(5) Tenders for the project, according to the winning price settlement.
2. Payment and settlement of works, according to the current provisions (see Annex).
Article V. Construction and design changes
1. Party B shall be based on the state-issued construction acceptance specifications and quality inspection standards, as well as equipment requirements for the organization of the construction, to achieve all qualified.
2. To adhere to the construction plans, no party shall not change the design. In the event of the following circumstances to the other side caused by nesting, rework, materials, components of the backlog, construction forces and organizations to relocate and other losses, should be borne by the responsible party.
(1) If the design is found to be wrong or seriously unreasonable during the construction, Party B shall notify Party A in writing, and Party A shall agree with the original design unit within seven days to put forward modification or change of the design documents, and the construction shall be permitted only after an agreement is signed between Party A and Party B.
(2) If the design is found to be wrong or seriously unreasonable during the construction, Party B shall notify Party A in writing.
(2) In the construction, in case of design changes beyond the original design standard or scale, it should be re-submitted for approval in accordance with the approval procedure before construction, the project budget is examined by the examination office, the investment is examined by the bank and an agreement is signed by Party A and Party B before construction is allowed. Otherwise, no party shall force the construction.
(3) in the construction, such as the case of stopping midway, slow construction, A and B on the construction in progress, should be agreed to do safe parts.
(4) in the construction, such as found that Party A investment is insufficient, can not be on time to pay the progress of the project, and stop building, slow construction, to Party B caused by the loss, should be borne by Party A.
3. Party B shall strictly implement the hidden works acceptance system, where hidden works are completed, must be recorded after acceptance, before continuing the construction of the next process. Concealed works in the hidden before, Party B should notify Party A check. If Party A fails to check in time, Party B can check on its own, fill in the record of inspection of concealed works, and send the record to Party A. Afterwards, Party A will have a better understanding of the concealed works. Party A shall inspect the concealed works afterwards, and the inspection cost shall be borne by Party A if it meets the quality standard; and the inspection cost shall be borne by Party B if it does not meet the quality standard. Party B did not notify Party A to check, their own hidden works, the inspection costs borne by Party B.
4. Party A and Party B in the construction of the project encountered raw items, should be in accordance with the quota management methods for approval. Changes in the engineering agreement attached to the change budget, should be sent to the bank in a timely manner before the construction, as the basis for settlement of the project.
Article 6: Completion and acceptance, settlement and warranty
1. Party B will notify Party A in writing of the acceptance date five days before the completion of a single project, such as Party A can't participate in the acceptance on time, Party B must be notified in advance to obtain Party B's consent to set another date for acceptance, but Party A must recognize the date of completion, and then fail to take part in the acceptance on time, the management fees and losses incurred by Party A. Party A shall bear the responsibility for the acceptance and acceptance. and reimbursement to Party B in accordance with the budget. And reimbursement to Party B in accordance with the budget cost of one ten thousandth of the daily late liquidated damages.
2. Completion of the project acceptance, within three days from the date of acceptance, Party B to Party A to hand over the completion of the project, such as Party A can not take over on time, resulting in the acceptance of the project after the occurrence of losses, should be borne by Party A.
3.
3. A project in the unit works, such as the need for separate transfer to Party A, in the transfer, the two sides should handle the intermediate acceptance procedures, as the unit of the completed project acceptance of the basis.
4. In the completion of the project acceptance, such as found that the quality of the project does not meet the requirements, Party B shall be responsible for free repair or rework, and in the measures agreed upon by the two sides and within the period of time to complete. After acceptance, the project will be handed over again. As a result of the late delivery of the project, Party B shall reimburse Party A one ten thousandth of the budgeted cost per day of late liquidated damages.
5. The project has been basically completed, such as the case of a material or equipment can not be resolved by both sides, resulting in the project can not be completed on schedule, the two sides agreed to do a reduction in the completion of the project, and the completion of the project for the completion of the acceptance and handover procedures.
6. Completion of the project acceptance, the construction acceptance criteria issued by the state, quality inspection standards and construction drawings as the basis. In the completion of the acceptance, Party B should be ten days before the acceptance of Party A to provide the following documents:
(1) increase or decrease the change of documents and other negotiation records;
(2) hidden works acceptance records and intermediate handover acceptance records;
(3) after the completion of the project, should be drawn as-built drawings, the project changes are not significant by the construction unit in the original construction drawings to explain, submit to the construction unit for archives. Archives of the construction unit. Engineering changes, can be drawn by the construction unit or commissioned by the design unit, the construction unit to draw as-built drawings.
7. Party B in a single project after the completion and acceptance, belonging to the civil construction projects should be completed within fifteen days after acceptance, belonging to industrial construction projects, should be completed within thirty days after acceptance, the completion of the settlement sent to Party A for review. Party A shall, after receiving the completion of the settlement, review the civil construction within fifteen days and the industrial construction within twenty days, and if no objection is raised at the expiration of the period, the bank shall finalize the appropriation.
8. After the completion and acceptance of the project, Party B is responsible for the construction of civil engineering quality warranty for one year (heating works in the first warm period). In the warranty period, the construction unit is responsible for the roof leakage, pipeline leakage, leakage, blockage and other quality accidents, Party B shall be responsible for repair without compensation (belonging to the professional construction and installation works in accordance with the State Council's special provisions of the relevant competent departments).
9. Without acceptance of the project, Party A will use it in advance or use it without authorization, and Party A will be responsible for the quality or other problems occurred as a result.
Article VII Liability for breach of contract and arbitration
1. Due to Party B's responsibility for the completion of the contract is not according to the date specified in the contract, (calculated on the date of completion and acceptance) for each day late, should be reimbursed to the Party according to the budget of the cost of one ten thousandth of the late penalty; belonging to the package of work without materials, for each day late, should be reimbursed to the Party according to the budget of the cost of labor of _________ the overdue penalty. Liquidated damages.
2. Party A and Party B shall not default on all kinds of payables, such as delayed payment, according to the bank's short-term loan interest rate to the other side of the late payment penalty.
3. The implementation of rationalization proposals and early completion of the award, A and B should be in accordance with the provisions of the relevant policy, a separate agreement.
4. Construction and installation contracting contract disputes, the parties should consult in a timely manner, the consultation fails, either party can apply for urban and rural construction committees at all levels or the two sides of the higher authorities, mediation; can not be resolved, can be directed to the building or directly to the People's Court.
Article VIII By-laws
1. Budget review procedures, the construction unit will be building and installation contract (with construction budget) to the municipal construction contract budget review. Requirements for authentication, you can go to the district or county administration for industry and commerce where the building is authenticated.
2. Before the signing of this contract, the two sides signed the construction preparation contract (engineering agreement), can be made as an attachment to this contract. Correspondence, faxes, e-mails, etc. confirmed by both parties will be treated as an integral part of this contract and will have the effect of a contract.
3. For bidding works, the contract shall be signed in accordance with the "Interim Measures for Bidding and Tendering for Construction Works in _________ City".
4. Other matters agreed upon by both parties: _________________________________
Article IX Number of copies of the contract and validity period
1. This contract is in one _________ copy. A and B each of the original copy, and were sent to the business department of the two sides of a copy; the rest of the copies, sent by Party A to the bank, building the location of the district and county administration for industry and commerce each one for the record.
2. This contract shall enter into force on the date of signing by both parties. It will expire after the completion and acceptance of all the works and the settlement of the final payment.
Party A (signature): ________________ Party B (signature): ________________
_________ year ________ month ________ day _________ year ________ month ________ day
Engineering Contract Agreement Template 2
Contractor: ________________
Contractor: ________________
In order to ensure the quality of the construction of the ________________ construction, the completion of the construction task on schedule, and to achieve the purpose of mutual benefit between the two parties. According to the "Chinese People's *** and State Contract Law", "Chinese People's *** and State Construction Law" and other laws and regulations, the two sides friendly consultation, on the construction project consensus, to enter into this contract.
I. Name of the project: _______________________
II. Floor area (form of the project) ____________
III. Place of construction: _______________________
IV. Duration of the project:
1. Commencement of construction: ______ month ______ day;
2, Completion: ______ month ______ day;
3, the total **** of the contract period lasted ______ days.
5, the form of contract: _______________________
6, the quality standard of the project: __________________
7, the price of the project: *** counted RMB ____________ yuan.
VIII, payment: after the entry into force of this contract to pay the contract sum of ______% of the amount of ______ yuan; after the completion of the project and acceptance, pay the project price of ______% of the amount of ______ yuan; warranty deposit ______ yuan, the warranty period expires after payment.
IX. Warranty period: ______ years.
X. Responsibilities and obligations of both parties
1. Responsibilities and obligations of the contractor.
① Provide the contractor with good construction sites, roads, water, power to meet the conditions for the start of work. To solve the construction needs to be coordinated by the contractor to solve the four neighboring relations and disputes;
② supervision and management of the construction process of the quality of the project, the quality of materials, supervise the progress of the project;
③ to provide the contractor with the construction drawings, coordinates, elevation points;
④ on time to the contractor to allocate money and acceptance, settlement;
2, the contractor's responsibility and obligations.
① according to the contractor's requirements and drawings for construction;
② on schedule to complete the construction task;
③ accept the contractor's technical guidance and quality standards;
④ responsible for the contractor to provide materials and equipment protection;
⑤ education and construction personnel to take care of the materials and materials of the party, shall not be stolen or damaged;
⑥ Undertake the construction of all safety accidents and costs;
XI, other
1, the contract since the two sides signed and stamped after the entry into force, valid until the expiry of the warranty period.
2, this contract is not exhaustive, can be negotiated between the two sides to solve and sign a written supplementary agreement, the supplementary agreement and this contract enjoy the same legal effect. Consultation is unsuccessful, submitted to the People's Court of Shandong Caoxian litigation.
3, the contract annexes for the contract terms of the component parts of this contract, the contract with the annexes in two copies, each party a copy, with the same effect.
Party A (signature): _______________ Party B (signature): _______________
___________ year _______ month ______ day ___________ year _______ month ______ day
Engineering Contract Agreement Template 3
Construction unit (hereinafter referred to as Party A): _________________________
Construction unit (hereinafter referred to as Party B): _________________________
In accordance with the "People's Republic of China*** and State Economic Contract Law", combined with the specific circumstances of the project, in order to clarify the project and the responsibilities of both parties, in line with the principle of mutual collaboration to ensure the successful completion of the construction project, after consultation to sign this contract.
Article I Project
(a) Project location: __________________________
(b) Project content: specific details see Annex I remodeling project worksheet.
(iii) Contracting method: contracted labor and materials.
Article II Project Cost
*** Counting RMB ____________.
Article III Contractual Duration
1. The two sides agreed on the total construction period _____ days.
Commencement date: ______ in ___________ _______ month, completion date: ______ in ___________ _______ month.
2. In case of the following circumstances, the construction period can be postponed after the visa of Party A's representative.
① In case of natural disasters irresistible to manpower (typhoons, fires, earthquakes) and other stoppages.
② When it is affected by the modification of the design drawings, which increases the amount of work.
③ When it is due to water or power failure for more than six hours.
④ When Party A is affected due to insufficient financial resources or non-payment of project preparation and progress payment according to the contract.
⑤ When Party A fails to hand over the construction site and connect the construction water source and power supply five days before the commencement of the construction according to the contract.
Article 4 Project quality standards and warranty period
(a) Project quality standards according to the current national construction specifications for acceptance
(b) Project warranty in accordance with the relevant provisions of the construction of the warranty from the date of completion of the acceptance of the date of signing
(c) belongs to the scope of the construction of Party B project, due to the quality of the construction of the damage caused by the problem, Party B shall give free of charge to repair. Repair.
Article V. Supply of Materials and Equipment
(a) The materials required for the project shall be purchased by Party B in accordance with the brand and model specified by Party A. The materials shall be supplied by Party B in accordance with the brand and model specified by Party B.
(b) The materials and equipment are accompanied by factory certificates of conformity, and the materials and equipment are inspected for objections.
Article 6 Payment Method
(a) Party A pays ______% of the total cost to Party B when Party B completes ______% of the project volume;
(b) Party B pays ______% of the project volume when Party B completes ______% of the project volume; Party A pays ______% of the total cost to Party B;
(c) When Party A pays ______% of the total price of the completed settlement within seven days after the completion of the acceptance of the project ______% of the total cost of completion;
(d) The remaining ______% of the project will be settled in one lump sum within three years from the date of completion and acceptance.
Article 7 Scope of Responsibility
(a) Party A's responsibility:
1, responsible for solving the construction and living water, electricity, road smooth;
2, timely organization of the completion of the acceptance of the project;
3, according to the period specified in the contract for the completion of the acceptance and payment of Party B's project.
(B) Party B's responsibility:
1, according to the construction safety standards to ensure the quality of construction, careful construction, completion on time, delivery and use, where construction quality, safety accidents occurring during the construction period by Party B is responsible.
① The contractor should strengthen the site construction personnel fire and theft safety education, construction personnel
shall not be illegal on the construction site, once the problem occurs, the consequences.
② Party B on-site construction personnel should unconditionally obey the construction site to comply with the provisions of the management, unconditional obedience to the site security management, properly handle the relationship between neighboring units, or all the consequences.
③ Party B should be responsible for all the consequences of damage to the original building, fire facilities during construction.
2, is responsible for the procurement of materials, equipment, storage work:
3, is responsible for the timely cleanup of construction debris, after the end of the project, is responsible for cleaning up the completion of the field of construction debris.
Article VIII Other Matters
(a) After the signing of the contract, Party A requires to increase or change the project, must comply with the following principles:
1, after full consultation between the two sides, issued a "notice of design changes"
2, to be submitted to the design drawings, quotations, or adjustments, Party A must be signed by both sides. Adjustment, Party A must be signed and stamped approval;
3, increase or change the content of the materials required to be implemented;
(b) Party B construction of any improper construction due to Party B personnel losses caused by Party B at their own expense;
(c) Party A does not have the conditions for the construction of the stoppage of construction or losses caused by the Party to assume responsibility and compensation for the Party B stoppage of the lost time;
(d) The contract is not a contractual agreement between the two sides, the contract is not a contractual agreement between the two sides, the contract is not a contractual agreement;
(i) The contract is a contractual agreement between the two sides. (D) the contract is not exhaustive matters, the two sides to study the establishment of another supplement, and the contract has the same legal effect. If there is a dispute in the implementation of the contract, it should be resolved through friendly consultation. Consultation is ineffective, can be submitted to the relevant arbitration institutions.
(e) The contract signed and sealed by both parties to enter into force, until the completion of the project acceptance and settlement of the project after the expiration of the payment.
Article 9 This contract is in _____ copies, of which: Party A _____ and Party B _____ are equally valid.
Party A (signature): _______________ Party B (signature): _______________
___________ year _______ month ______ day ___________ year _______ month ______ day
Related posts to construction contract agreement template :
★ construction contract agreement template
★ construction contract agreement template
★ construction contract agreement template
★ construction contract model agreement
★ classic construction contract model contract
★ construction contract agreement
★ The latest construction contract contract model
★ Construction contract book model 3
★ Engineering contract standard version of the agreement
★ Construction labor contract contract book model
★ Engineering contract agreement