In the ever-progressing society, men and women may need to use the letter of agreement, the signing of the letter of agreement can ensure that the two sides work together happily. A reference to the agreement is how to write it, the following is my collection of labor team contracting agreement model, just for reference, I hope to help you.
Labor team contracting agreement model 1Contractor (hereinafter referred to as Party A):
Residence:
Representative:
Contractor (hereinafter referred to as Party B):
Responsibility:
Residence:
I. Overview of the project
1 , Name of the project:
2, Scope of the project:
3, Unit price of the contract:
4, Content of the contract:
5, Scope of the contract:
6, Mode of contracting:
7, Duration of the project:
Planned date of commencement of the project:
Planned date of completion of the work:
Planned date of commencement of the work:
Planned date of completion of the work:
Planned date of completion of the project: _______ ____ ____ day, total *** ________ calendar days.
Second, the responsibilities of both parties
1, Party A's responsibilities
(1) to provide Party B contracted within the scope of the project calculations, is responsible for the hidden acceptance, materials reported for examination, the use of the function of the test, and other technical information of the visa work.
(2) Provide the necessary safety facilities and living facilities and water and electricity.
(3) Responsible for the preparation of as-built drawings, project settlement and price review.
(4) Arranging timely acceptance when the project is completed.
2, Party B's responsibilities
(1) Party B needs to strictly abide by the safety construction norms, obey the guidance of the project management personnel, and the safety accidents caused by Party B's improper construction in the process of construction will be borne entirely by Party B.
(1) Party B should strictly abide by the safety construction norms and obey the guidance of the project management personnel.
(2) Party B must strictly implement the progress plan and quality requirements formulated by the project department, Party B in the construction and management process due to quality problems caused by Party A are Party B to bear the losses. Construction process, such as not according to the construction plan, and not in accordance with the construction specifications, and the total project caused by the Ministry of fines by the Party B is responsible for.
(3) Party B must be civilized construction, to achieve the construction site clean, construction materials are strictly prohibited littering.
(4) Party B shall strictly follow the construction schedule set by the General Project Department to reasonably organize the personnel and complete the construction tasks on time. If the construction period is delayed due to Party A's factors, Party B will not be responsible.
(5) Party B shall coordinate with each team during the construction process, and Party B shall be responsible for any loss caused by improper coordination.
(6) Party B shall purchase life insurance for the plumbers and electricians in accordance with the regulations, and the plumbers and electricians shall have appropriate qualifications.
Third, the settlement
After the completion of the project, Party A to complete the acceptance, the two sides to settle, Party B to prepare the settlement basis.
Fourth, payment
Monthly _______ B to Party A to report the progress of the project, Party A in the next month ________ to pay Party B progress of the payment of _______ (based on the General Contractor contract payment method).
Fifth, safety provisions
1, into the site construction personnel, must implement the Company's rules and regulations, by Party B is responsible for supervising the safety of all work to eliminate unauthorized operation. Work time with a license, the use of machinery operated by a person.
2, the implementation of safe, civilized construction.
3, Party B special types of work must be licensed, such as found to be seized by the relevant departments of the fine is responsible for Party B.
4, all the machinery, lamps and wires can not be dismantled and installed.
5, in the process of construction, because of Party B's unauthorized operation of all personal injury and death accidents, all costs by Party B is responsible for.
Six, disciplinary system
1, Party B into the work, the team must be handed over to the identity card and relevant procedures for Party A check, no documents of workers, not allowed to enter the construction, Party B contractors of the team's behavior is fully responsible for.
2, fights are illegal, Party A does not support the disputes, Party B should coordinate in a timely manner or to reflect the mediation of Party A management personnel, who participated in or instructed the fights are punished by RMB ______ / person, the circumstances are serious are handed over to the judiciary for punishment, Party B shall not be any reason to shirk their responsibilities, fights occurring in the medical expenses, lost wages, fines are responsible for Party B The person in charge of Party B will bear the responsibility.
VII, quality terms
Party B must ensure that the quality of the project to meet the ______________________________ standard, such as the quality factors caused by Party B can not reach this quality standard, then the penalty for Party B's total price of the project's '______% punishment.
Eight , breach of contract
1, the two sides should strictly abide by the agreement, if there is a violation, according to the relevant provisions of this agreement to assume responsibility for breach of contract.
2, such as delay in the construction period, every day over, according to the contract total price of ____% to bear liquidated damages, or every day at ______ yuan to pay liquidated damages to the Party.
IX. Dispute Resolution
Disputes arising from the performance of the contract between the two parties shall be negotiated on the principle of amity, and in the event of failure of negotiation, either party shall have the right to sue in the court of the place where the contract is to be performed and the place where the contract is to be signed.
X. By-laws
1. This agreement shall enter into force after both parties have signed and sealed it.
2. This Agreement is signed at __________________ (place) on the ____ day of _______.
3. This Agreement is executed in _____ copies, each of the parties executing _____ copies, with the same legal effect.
XI, this agreement is not exhausted, the two sides to negotiate to resolve
Party A:
Representative:
Contact phone number:
Signing place:
_______ year ____ month ____ day
Party B:
Responsible person:
Contact number:
Signing place:
_______ ____ month ____ day
Labor Shift Contracting Agreement Model 2Contractor (hereinafter referred to as Party A):
Residence:
Contractor (hereinafter referred to as Party B):
Residence:
Party A's __________ project painting project is now contracted by Party B. In order to clarify the responsibilities of both parties, division of labor, better cooperation with each other, to ensure that the project safety, quality and civilization of the construction successfully completed on schedule, and combined with the specific circumstances of the project, by Party A and Party B friendly consultation, unanimous agreement after the signing of the following terms, the two sides to comply with the implementation.
First, the project overview
1, the construction unit:
2, the project name:
3, the type of structure:
4, the project address:
5, the scope of contracting:
6, the project cost:
7, the mode of payment:
8, the oil, the oil, the oil, the oil, the oil, the oil and the oil. p>
8, painter team leader:
Second, the contracted works
Interior wall: keep the flatness of the corner layer of high and low line wrapping _____mm, _______ yuan/square.
Exterior wall: two bottom two coated, pulled hair, with high-level elastic exterior latex paint, __________ yuan / square; if you do not include the exterior latex paint materials then __________ yuan / square.
Third, quality requirements
According to Party A's requirements, Party B must be _________________ standard construction. Civilized construction, strive for quality projects, if there is a paint quality problems caused by the loss of Party A, Party B is fully responsible for compensating Party A for all losses caused by this.
Fourth, the duration
1, the planned date of commencement _______ ____ ____, the planned date of completion _______ ____ ____, *** _____ calendar days.
2. During the construction, Party B must strictly implement the progress of the construction plan formulated by Party A. The construction period will be postponed due to Party B's delay. When the construction period is delayed due to Party B, the payment _______ will be deducted every day. When the construction period is delayed due to other circumstances, Party B must obtain Party A's written consent.
Fifth, safety management
1, Party B in the construction period, must ensure that the civil workers safe construction and civilized construction.
2, into the construction site must wear a helmet, seriously implement the safety measures, is strictly prohibited in the construction of noisy scolding, if the occurrence of criminal cases, fire, theft and other accidents, Party B is responsible for and punishment.
3, due to Party B in the construction of mismanagement, violation of rules, discipline and other accidents caused by industrial accidents, are Party B, Party A is responsible for the duty to assist in the rescue responsibility.
4, Party B personnel shall not fight in the site, living area, otherwise the parties involved in a fine of ______ yuan, Party B fined ___________ yuan, and depending on the severity of the case, the parties will be sent to the relevant public security organs to deal with.
5, Party B personnel must conscientiously implement the rules and regulations of the project, violators of the project penalties according to the regulations on its punishment.
Six, Party B obligations
1, Party B hired workers must hold the relevant documents, the state requires qualifications, should have the appropriate qualifications.
2, Party B must ensure that the hired workers are healthy, in line with the requirements of the construction, such as construction workers themselves are not physically suitable for the work of the disease, the consequences are borne by Party B.
2, Party B must ensure that the hired workers are healthy, in line with the requirements of the construction.
3, Party B must be regularly on the civil workers for safety, civilized construction of ideological and moral education, to track the management, found that the problem is resolved in a timely manner, to improve the construction site hygiene, pay attention to saving water, electricity, and actively participate in the safety meetings held by the Party.
4, Party B in the construction period should do a good job of product protection, taking into account the protection of this process before handover. Acceptance of each process, timely organization of workers with Party A, supervision, acceptance of the owner, with untimely and the costs caused by Party B bear.
Seven, the responsibility for breach of contract
In the performance of this contract, any party to the violation of this agreement is a breach of contract, the breaching party shall bear the corresponding responsibility for breach of contract to the contracting party.
VIII. Dispute resolution
In the process of contract fulfillment, A and B on the terms of the contract or construction problems encountered disputes should be resolved in the spirit of friendly negotiation, consultation does not work, either party can be to the location of the project, the court where the contract is signed.
Nine, bylaws
This Agreement shall enter into force upon signature by the representatives of both parties, and shall expire upon completion of the project.
This agreement is a form of _______ copies, Party A and Party B are each executed _______ copies.
Party A:
Representative:
Place of signing:
Date of signing:
Party B:
Responsibility:
Place of signing:
Date of signing:
Sample Agreement on Contracting of Labor Group 3Party A:
Party B:
Masonry sub-projects labor contract content introduction:
Pengxi County Pengnan Town "Fuyuan Mingju" project, the project has been general contracted by Party A, due to production needs, by the friendly consultation between Party A and Party B, Party B to provide skilled contracted labor team and the corresponding management team to participate in the construction of the project. In order to clarify the responsibilities and obligations of both parties, the two sides in accordance with the "Chinese People's *** and the State Contract Law" and "Chinese People's *** and the State Construction Law", consensus, the following contract terms, for both parties *** with compliance.
First, the project name : Pengxi County Pengnan Town, "Fuyuan Mingju" project
Second, the project location: Pengnan Town, Electronic Industrial Park
Third, the project overview: seven floors above ground, the ground floor, the ground floor, the ground floor, the ground floor, the ground floor, the ground floor, the ground floor. seven floors above ground and one underground floor with a total floor area of about 4662m2 (subject to the actual area after completion), for the brick mixed bottom two frame structure. (The total height of the building ground 25.1 meters)
Fourth, the contracting mode:
Party A is responsible for the project management, Party B to provide contracting labor team, package labor package main and auxiliary materials package small tools and equipment, package safety and civilization construction, package quality, package construction contracting mode.
Fifth, the scope of contract
1, the design drawings of all the structure of the bricklaying, internal and external plastering, pouring concrete, flooring, roofing, foundation (including basement grooves, pits, picking up the bottom of the basement picking up and so on), the exterior wall brick pasting, the external frame building (frame pipe fasteners provided by the Party A, the up and down by the Party B is responsible for).
Six, work content
Completion of the scope of the above project all the work content and the corresponding site materials, tools, machinery and equipment of the field transfer, clean up, civilized construction, safe production of labor and drawings within the scope of the stay hole set groove, embedded parts placement. The turnover of materials on and off the car and stacking and other labor.
VII. Project Settlement
7.1 Project Pricing and Settlement: The project is calculated according to the construction area of each square meter (38 yuan) thirty-eight yuan,
7.2 Payment Methods: After the pad to the conversion layer, the last day of each month to report the verification of the actual completed workload of the month (according to the finished product of the poured concrete), according to the 70% payment within 7 days, all the main project is completed, and the payment is made within 7 days. Payment will be made within 7 days after the completion and acceptance of all main works, and the balance will be paid within 1 month after the settlement (with a grace period of 7 days).
VIII, schedule requirements
8.1 Party A according to the requirements of the total construction period, the preparation of the construction of the total progress plan. On this basis, Party B prepares detailed weekly and monthly plans. Party A reserves the right to claim compensation for any loss suffered by Party A due to Party B's poor planning, poor organization and insufficient technical force, resulting in construction delay. If you can't reach the specified progress requirements, Party A has the right to arrange for other teams to work, and the amount of work done will be deducted from Party B's settlement to other teams.
8.2 Requirements for the construction period: according to Party A's total progress plan for assembly line construction, only allowed to advance, no delay.
Nine, other matters: In the construction of the
This agreement in duplicate A and B each take one of the two sides to sign and take effect
Party A: ID card:
Party B: ID card:
Year month
Labor team contracting agreement model 4Contracting party (hereinafter referred to as Party A):
Address:
Contractor (hereinafter referred to as Party B):
Address:
In accordance with the relevant laws and administrative regulations, following the principles of equality, voluntariness, fairness and honesty, the two sides on the _____________ project _____________ project carpentry construction matters consensus, to enter into this contract.
I. Project Overview
1, Project Name:
2, Project Location:
3, Scope of Construction:
4, Nature of the Project:
5, Project Cost:
6, Method of Payment:
7, Duration of the project:
Planned start date: _______ ____ ____, planned completion date: _______ ____ ____, total *** ________ calendar days.
Second, the quality requirements
According to the national current engineering quality specification requirements, to achieve __________________ standards. If rework is caused by Party B, Party B will be responsible for all the losses caused.
Third, the responsibilities of Party A and Party B
1, Party A's responsibilities
(1) Party A is responsible for providing Party B with construction sites, due to the limited construction site Party A does not arrange for the accommodation of Party B's construction personnel, only to provide tool room and office space.
(2) Party A can check the construction progress and construction quality of Party B at any time according to the current construction specifications, if found that the construction progress and quality of construction does not comply with the current national norms or drawings and design requirements, can be notified in writing to rectify the Party B or rework, which causes all the losses by the Party B is responsible for, Party B refuses to rectify the Party A has the right to require Party B to stop construction.
(3) Party A is responsible for organizing the intermediate acceptance and completion acceptance of the sub-projects.
(4) Party A must pay Party B's progress payment according to the contract.
2. Duties of Party B
(1) Party B must notify Party A for acceptance after completion of each sub-project, and Party A will organize the supervision and construction unit for acceptance.
(2) Party B is responsible for organizing safety education and training for workers, and must wear helmets and all safety measures when entering Party A's construction site.
(3) Comply with all the rules and regulations of Party A, strictly implement the national laws and regulations on production safety, civilized construction, and accept Party A's inspection and supervision of the quality of the project at any time, and be responsible for the safety and quality accidents caused by Party B.
(4) Party B in the construction process to do a good job in the protection of finished products, shall not destroy the existing facilities of Party A site.
(5) After the completion of the project, to assist Party A to organize the relevant departments for inspection and acceptance, according to the requirements of Party A to do a good job of finishing the project.
(6) Party B must do the work is done, construction is complete, all the demolition template must be classified neat yard.
Fourth, the safety provisions
1, Party B must provide their own wrenches, helmets, safety belts, steel ruler, line drop, level and other tools and appliances.
2, it is strictly prohibited to steal, rob, fight, every time there is a fine of __________ yuan.
3, it is strictly prohibited mobbing and other phenomena occur, the site of any thing must be promptly reported to the Party A project manager, *** with the consultation, properly dealt with, to prevent the expansion of the situation, the emergence of the above behavior, regardless of the reasons, each time a fine of _________ yuan, project settlement deducted.
4, Party B according to the needs of the project to receive 'tools, instruments, equipment and other materials, to strictly manage the use, prohibit damage and loss. If damage and loss occurs, according to its economic value of _________ times the collection of fines.
5, all personnel entering the construction site, must provide ID cards to register clearly one by one.
6, the body does not meet the construction conditions, is strictly prohibited to enter the construction site, the concealment of each person fined _________ yuan.
7, without the consent of the party, it is strictly prohibited to open the stove, prohibited the use of electric stoves and other electrical equipment, violators bear the corresponding economic and legal responsibility.
V. Liability for breach of contract
1, the two sides should strictly abide by the agreement, if there is a violation, according to the relevant provisions of this agreement to assume responsibility for breach of contract.
2. If the construction period is delayed, for every day exceeding one day, we shall bear the liquidated damages according to ____% of the total price of the contract, or we shall pay the liquidated damages to Party A according to ______ yuan per day.
Six, other
This contract is a _________, both sides of the _________, signed and sealed by both parties with legal effect.
In the performance of the contract, if there are disputes and outstanding issues, the two sides to negotiate a solution, if the negotiated settlement fails, either party can be to the project location, the contract signed the court.
After both parties fulfill all the obligations of the contract, the contract expires on its own.
Party A:
Representative:
Contact phone number:
Place of signing:
_______ year ____ month ____ day
Party B:
Responsible person:
Contact phone number:
Place of signing:
_______ year ____ month ____ day
Labor team contracting agreement model 5Party A:
Party B:
Steel sub-project labor contract content introduction:
__ County __ Town "Fuyuan Famous Residence" project project has been general contracted by Party A, due to the production needs of the A and B sides through the friendly negotiation of the B and the B side, the B side to provide skilled contracting labor team and the corresponding management team to participate in this project. Corresponding management team to participate in the construction of the project. In order to clarify the responsibilities and obligations of both parties, the two sides in accordance with the "Chinese People's *** and the State Contract Law" and "Chinese People's *** and the State Construction Law", consensus, the following contract terms for the two sides *** with compliance.
I. Project name: ___ County ___ Town, "Fuyuan Mingju" project
Second, the project location: ___ Town, Shunhe Street
Third, the project overview: seven floors above ground, one underground floor with a total floor area of about 4,662m2 (to the actual area of the grim work after the actual area shall prevail), for the brick mixed structure.
Fourth, the contracting method and scope of contracting
4.1 Contracting method: design drawings of all the structure of the package work, package quality, package auxiliary materials (tie wire, cutting sheet, to welding, machine tools. Party A only provides steel) package saving materials, package construction period, package safety, package civilized construction.
4.2 Scope of contracting: ___ County ___ Town, "Fuyuan Mingju" project, from the foundation to the roof of all steel production binding installation.
V. Project settlement
5.1 Project pricing settlement: the project is calculated according to the construction area per square meter (17 yuan) one hundred and seventy dollars, including plus or minus zero below and the roof of the daughter wall.
5.2 Payment: the last day of each month to report the actual completion of the month's workload (calculated according to the finished product has been poured concrete), according to 70% in 7 days to pay, all the main body of work is completed and acceptance of the settlement within 7 days after the settlement of the month after the payment of all the remaining balance (grace period of 7 days).
Six, the duration of the requirements
6.1 Party A according to the requirements of the total construction period, the preparation of the construction of the total progress plan. On this basis, Party B to prepare a detailed weekly plan, monthly plan. Party A reserves the right to claim compensation for any loss suffered by Party A due to Party B's poor planning, poor organization and insufficient technical force, resulting in delays in the construction period. If you can't reach the specified progress requirements, Party A has the right to arrange for other teams to work, and the amount of work done will be deducted from Party B's settlement to other teams.
6.2 Requirements for construction period: according to Party A's total progress plan for assembly line construction, only allowed to advance, no delay.
VII. Other matters:
This agreement is in duplicate, A and B each sign a copy of the two sides to take effect.
Party A:
ID:
Party B:
ID:
___year ___months ___
Labor team contracting agreement model 6Contractor (hereinafter referred to as Party A):
Residence:
Contractor (hereinafter referred to as Party B):
Residence:
In accordance with the relevant provisions of the "Contracting Agreement", the contract is signed by both parties. p>
In accordance with the relevant "Chinese People's *** and State Contract Law" administrative rules, regulations, etc., following the principle of equality, voluntariness, fairness and good faith, Party A entrusts the ____________________ project of _____________________ to Party B for construction, in order to strengthen the management, to ensure the quality of the construction, and to make clear the responsibilities of both parties, both parties agree on the construction of this project. This project construction matters consensus, enter into this contract.
I. Project Overview
1, Project Name:
2, Contracting Mode:
3, Contracting Scope:
4, Contracting Unit Price:
Calculated according to the construction drawings of the actual completion of the amount of the external wall tiles _______ yuan / m2; bathroom wall tiles _______ yuan/m2; bathroom floor tiles _______ yuan/m2; indoor floor tiles _______ yuan/m2; skirting _______ yuan/m; guttering _______ yuan/m.
Two, the quality of the project
The project quality grade requirements ________________ standard, Party B must be strictly in accordance with the design and the requirements of the relevant construction specifications of the construction, strict management, rational use of all kinds of materials, waste is strictly prohibited, otherwise all losses by Party B is responsible for compensation. In the construction should actively cooperate with the owner, supervision, the company and other quality inspection personnel, where the inspection does not meet the contract quality requirements Party B should be timely rectification or rework, the losses caused by Party B, Party A and depending on the circumstances to be punished, penalties ____________ yuan.
Third, the rights and obligations of the two sides
1, Party A's rights and obligations
(1) in the Party B before the start of the Party A must do a good job in the preparatory work for the project, all the raw materials required by Party A is responsible for procurement.
(2) Party A shall notify Party B in advance _______ days if Party A needs to change the program, otherwise, the cost of missed work caused by Party A shall be borne.
(3) Party A promises Party B to pay the contract price according to the period and payment method required by the contract.
(4) Upon completion of the project, timely organization of acceptance without undue delay.
2. The rights and obligations of Party B
(1) Party B must construct the project in strict accordance with Party A's requirements, fulfill the principle of saving, and not waste. Otherwise, the additional losses caused by Party B shall be borne by Party B itself.
(2) Party B in the construction process, must strengthen the site construction personnel safety education, establish and improve the safety measures, operating procedures, civilized construction, safety management system. Strengthen construction personnel, materials, vehicles, electricity safety measures. In case of safety accidents and the costs incurred as a result, Party B shall bear the responsibility.
(3) If the state stipulates that the construction personnel need to have certain qualifications, the construction personnel must meet certain qualifications.
(4) Party B (except for natural disasters, emergencies, force majeure, can be postponed) must be completed on time.
Fourth, the duration of the requirements
The specific progress of the project by the Party A co-ordination arrangements, the construction team to comply with the arrangements, and actively cooperate with the progress of the overall construction of the quality and quantity of the organization of the construction, or else overdue according to the daily ________ yuan penalty. After the completion of the construction section must be cleaned up in a timely manner after the residual material, to achieve the completion of the work site clear.
Fifth, the payment method
According to the monthly progress of the completion of the amount of qualified works of the total price of ______% to pay the progress payment, after the completion of the project to pay the total price of ______%, the project is completed and acceptance of payment of ______% of the total price of the balance of the amount of the work in the Party B report settlement, the Party audited and cleared within one month. The balance will be paid within one month after Party B reports the work volume settlement, and Party A reviews it.
Six, construction safety
Party B all participants in the construction of the personnel, must pay attention to production safety, according to the provisions of the helmet, etc. (self-purchase). Production, life must obey the unified arrangement and command of the site management personnel, not in the site gambling, alcohol, trouble. If Party B's workers have safety accidents, all economic and legal responsibilities arising will be borne by Party B itself. Workers must hold valid certificates in accordance with national and local regulations, Party B should carry out self-checks, and Party B will be responsible for any disputes arising from the lack of certificates.
VII. Liability for breach of contract
Party B in the construction, due to delays in the construction period can not be completed in a timely manner, or due to quality problems need to rework, Party A has the right to make Party B to withdraw from the scene, the economic losses caused by Party A by Party B.
Party A is the only party in the construction of the project, and Party B has the right to withdraw from the site.
VIII. Dispute Resolution
Once this agreement is signed, both parties shall strictly abide by it. If any dispute arises from the fulfillment of this contract, both parties shall consult to solve it, and if the consultation fails, the people's court of the place where the project is located and where the contract is signed shall adjudicate.
IX. Entry into force and termination of the contract
This contract shall enter into force on the date of signature by both parties, and shall automatically expire after the settlement of the balance. This contract is a ______ copy, A, B each party executes ______ copies, with the same legal effect.
X. Matters not covered in this contract shall be resolved through consultation between the two parties
Party A:
Representative:
Contact information:
Place of signing:
_______ year ____ month ____ day
Party B:
Representative. :
Contact information:
Signed at:
_______ ____ ____