Masonry contract 1
Party A: _ _ _ _ _ _ Party B: _ _ _ _ _ _
Quality is life, and safety brings benefits. In order to ensure the completion and accept
Masonry contract 1
Party A: _ _ _ _ _ _ Party B: _ _ _ _ _ _
Quality is life, and safety brings benefits. In order to ensure the completion and acceptance of the project on time and with good quality, all woodworking operations of this project are contracted to Party B, and the specific contract is as follows:
First, the way of contracting:
1 Contract form: single contractor
2. Workload: The wall, floor and stair steps are paved in 30 yuan per square meter, with the intention of 20xx square meters. According to the actual square meters, stone dry hanging is counted separately.
2. Project progress: According to Party A's requirements, the total construction period is days, and Party A guarantees that the site will be completed on schedule, and the site must be cleaned up and the supplied materials will be in place on time. Party B shall not be responsible for the project delay caused by design changes.
Third, safety: we must ensure the safety of construction and put an end to any accidents. Party B must be equipped with safety officers, and safety helmets shall be provided by all types of work. However, Party B must purchase products that meet the national safety supervision standards, sign safety contracts for employees, make safety technical disclosure for sub-projects and obey on-site safety management, and report hidden dangers in time. Party B (contractor) shall be responsible for all safety during construction, and Party A shall not bear any responsibility.
Fourth, civilization and health.
The site is kept clean, civilized and hygienic every day, and all kinds of work are coordinated, which has left a good impression on the owner and supervisor. Materials should be neatly stacked when entering the site, and garbage should be returned to the heap. Clean up the materials after work every day and don't waste them.
Verb (abbreviation of verb) payment terms
When Party B enters the site, Party A will pay part of Party B's expenses, and the rest will be settled after completion and acceptance.
6. This contract is made in duplicate, which will take effect after being signed by both parties, and each party holds one copy.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Masonry contract 2
Employer: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
According to the needs of engineering production, relevant laws and regulations, and following the principles of equality, fairness, honesty and credibility, Party A and Party B, through consultation, conclude this contract for mutual compliance.
I. Project name:
Second, the project site selection:
Three. Scope of contract: all the sub-items based on the construction drawing of this project and all the work contents included in the budget quota (including covering consumables nails, wires, machines and tools, getting on and off the required materials, cleaning and stacking, making and installing the secondary structure template).
Four. Contracting method: contracting labor and materials.
Verb (abbreviation for verb) Contract price:
1, template production and installation contract comprehensive unit price:
total amount
2, the basement template production and installation contract comprehensive unit price:
total amount
3. The comprehensive unit price includes all the expenses that should be paid for the whole process of employment, such as labor regulations and labor protection articles stipulated in the national unified labor quota and the provincial budget quota, and is linked to indicators such as quality, safety, progress and material saving.
Among them, quality accounts for the total cost, progress accounts for, materials account for, and safe and civilized construction accounts for. If any index is not up to standard, the comprehensive cost of the corresponding proportion shall be deducted. This price is the price of sub-projects that meet the quality standards. Non-conformity shall not be settled, and losses such as rework materials shall be borne by Party B, subject to the actual losses on the construction day.
Settlement method of intransitive verbs:
1, contact area calculation.
2. The underground garage is calculated according to the concrete contact area.
Seven, project management and time limit for a project:
1. According to the needs of the project, Party B's personnel will enter the site according to the construction progress plan, and the construction site needs 1-2 full-time management personnel to live. Their names, telephone numbers and personal resumes should be reported to Party A (Project Department) for the record, so as to form a construction team with management ability and certain technical and economic strength. The above managers must work on the sign-in form of Party A (Project Department) every day. Any form of signing or not signing shall be punished by liquidated damages of 300 yuan/day, and management and construction personnel shall not be changed at will during the performance of the contract. If it is really necessary to change due to other circumstances, it can only be transferred with the consent of Party A's project department, otherwise, a penalty of 5000-20_0 yuan will be imposed.
2. Construction period: The construction period of this project is determined by Party A in stages according to the specific conditions of the project, and the construction period has a specific timetable, that is, according to, within the determined construction period, it shall not be arbitrarily delayed without Party A's consent. If the construction period is delayed, payment will be made for each node delayed for more than three hours.
Yuan's liquidated damages for delayed performance shall be rewarded with the same amount in advance of the construction period.
3. Party B's personnel entering the site must be healthy and abide by the management system and technical disclosure of the project department.
4. Party B's contractor must always participate in site management and leave the site after obtaining permission.
Eight, engineering quality and inspection:
1, quality standard grade: excellent
2. Party B shall carefully organize the construction according to the specifications, design requirements and technical disclosure, and accept the inspection of Party A, the supervisor, the construction unit and the quality supervision department at any time during the construction.
The quality of inspection during construction is unqualified. Party B shall rework unconditionally and bear all expenses for rework. If the rework is unqualified, Party A has the right to ask Party B to leave and settle this part of the project.
3. The quality requirements of this contract include the requirements of current national or industrial standards and the standard requirements of technical disclosure during construction.
4. The key quality control parts of this contract are as follows:
① Axis elevation standard system: if the axis elevation exceeds the allowable error of the specification, it will be fined 1 1,000 yuan. Especially serious to dismantle rework, all losses shall be borne by the contractor.
(2) The verticality control of columns and walls, if the verticality exceeds the allowable error of specifications, 200 yuan will be fined everywhere on the facade, and 300 yuan will be fined everywhere on the facade.
③ Joints of horizontal construction joints of walls and columns: If the joints are straight, there is no obvious joint. If there is obvious joint and several, 200 yuan will be punished at every place.
④ Beam-column joint control: The stare blankly angle shall be clear, flat and accurate in geometric dimensions, and 200 yuan shall be fined for exceeding the specified requirements.
⑤ Stairs: Stairs have accurate geometric dimensions and are horizontal and vertical. Otherwise, each floor will be fined 200 yuan.
⑥ Detail control: The edges and corners of the boards with different elevations are complete and straight, and the parts such as cantilever plates, hanging formwork in puddles, collecting wells, etc. , requirements conform to the requirements of the drawings, angular. Otherwise, fine 50 yuan everywhere.
Nine, safe production and civilized construction:
1. In order to ensure safe production, Party B shall operate in strict accordance with the construction safety specifications and obey the safety management of Party A. ..
Party B shall be responsible for the accidents caused by the construction of Party B's personnel at work, and Party A shall not bear any responsibility.
2. After entering the site, Party B shall conduct safety education for employees and abide by the site safety management regulations. It is forbidden to command or operate illegally.
3. The site safety facilities should be protected during construction, and it is forbidden to dismantle or use the site safety facilities, signs, publicity slogans, etc. Without permission.
4. During the construction, the scattered materials shall be recovered immediately, and the site shall be cleaned after work, actively cooperating with the civilized construction on the site.
5, all materials on the construction site must be neatly stacked according to the types and specifications, complete identification.
X. Settlement and payment of project funds:
After the sectional works contracted by Party B are completed, the quality inspection and acceptance shall be carried out first, and then reported to the quality inspection team of Party A and the supervision for acceptance. After the acceptance, handle the qualified or high-quality sub-project acceptance sheet, and settle the project payment in advance with this sheet. If the construction of the next working procedure is started without reporting to Party A for acceptance, the fine of1000-3,000 yuan will be deducted at the time of payment. After completing the above procedures:
(1) is calculated as 50% of the quantity of work completed each month.
② Pay 80% of the estimated total amount before the Spring Festival. (If it is capped before the Spring Festival, it will be paid to 90% of the completed project quantity)
(3) The remaining 10% of the project payment shall be paid as a quality guarantee within one year after the completion of the project.
(4) All economic penalties shall be deducted from the first advance payment.
⑤ If all kinds of economic penalties exceed 10 times, 3% of the total price will be reduced when the fourth payment is made.
6. Party B's settlement procedures are perfect. If Party A fails to pay in time, Party A will be fined 3000 yuan each time.
XI。 Responsibilities and obligations of both parties:
1. During the construction period, Party B will raise its own living expenses. After the completion of the contracted project, the project payment shall be settled according to the acceptance procedure, and no pre-settlement shall be carried out without the intermediate acceptance certificate.
2, bring your own small tools (all mechanical construction electricity aw0.4/n2 above).
3. It is forbidden to subcontract the contracted subdivisional work. In case of subcontracting, Party A has the right to terminate this contract, and the project payment shall be settled at 30%.
4. During the construction period, Party A is responsible for providing Party B with domestic water and electricity, arranging accommodation for Party B's construction personnel, and implementing it according to the location and management system specified by Party A, otherwise it will be given certain economic penalties.
5. All materials shall be equipped and used according to site regulations. If it is found that materials are not used or the quantity of materials is changed according to the on-site disclosure, Party A has the right to punish according to the regulations.
6, actively do a good job in living area health, packed up daily necessities;
Abide by the housing management system, it is strictly forbidden to use or move the living quarters facilities without authorization, and those who violate the regulations and do not listen to the advice will be punished according to the on-site management system.
7. Stealing, gambling, fighting, making trouble and violating regulations are strictly prohibited on the construction site. In addition to investigating the responsibility of the parties concerned, they will be fined 500-20 yuan and bear all economic losses and consequences. If the circumstances are serious, it will be handed over to the public security organ.
8. Party B unconditionally cooperates with Party A in the construction survey and setting-out of each floor.
Twelve. Claim:
1. If the workload within the contracted scope of Party B fails to meet the promised quality standards, Party A will claim 5%- 10% of the total project cost within the contracted scope from Party B. ..
2. If the promised weekly or monthly progress cannot be completed due to Party B's construction, which affects the normal construction of other types of work, Party A will claim compensation from Party B, and will be fined 20_ yuan for each day of delay, and there is no limit on the claim for delay time.
3. If Party B subcontracts or subcontracts without Party A's consent, Party A will claim 5% of the total project cost within the contracted scope on behalf of Party B. ..
4. During the construction period, Party B refuses to obey the correct command of the management personnel of the banking technology department of Party A, and fines 500 yuan every time.
5. During the construction period, the subcontracted construction contractor leaves his post without authorization, claiming a fine from 200 yuan every time, absent from the on-site work meeting without reason, and claiming a fine from 500 yuan every time.
Thirteen. Matters not covered in this contract can be settled by both parties through consultation at any time.
14. This contract is made in triplicate, with Party A holding two copies and Party B holding one copy. This contract shall come into force as of the date of signature by both parties, and shall automatically become invalid after the execution of the contract terms.
15. The annexes are Security Team Construction Contract and Technical Disclosure, which have the same legal effect as this contract.
Party A (official seal): _ _ _ _ _ _
Party B (official seal): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _
Legal representative (signature): _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Masonry contract 3
Party A:
Party B:
In order to clarify the rights, obligations and responsibilities of both parties in the construction, based on the principle of cooperation and responsibility, both parties agreed to sign a contract through consultation and abide by it together.
1. Project name and scope: bricklayer, full-time.
2. Contract method and price:
(1), the contractor does not include materials, and the tools at hand are self-made.
(2) The construction area of this project is: square meters, and the contract price per square meter is RMB.
3. Payment method: payment according to the big contract.
4. Responsibilities and obligations of both parties:
Party A's responsibilities:
(1), responsible for coordinating related civil construction disputes and contradictions.
(2) Responsible for materials that will not delay Party B's construction.
(3) Be responsible for Party B's accommodation and kitchen.
5. Party B's responsibilities:
(1), the construction shall be carried out according to the construction specifications, and Party B shall be responsible for the wastes caused by processing errors.
(2) Party B must carry out the construction according to the construction progress of Party A. ..
6. Safety matters: Party B must carry out the construction according to the site safety rules and regulations. In case of an industrial accident, Party A will not take any responsibility, and Party B will take full responsibility.
7. Other matters:
(1), this contract is made in duplicate, with each party holding one copy.
(2) This contract shall come into effect as of the date of signature by both parties.
(3) For matters not covered in this contract, both parties may formulate relevant clauses according to specific conditions, which shall be taken as annexes to this contract and shall be followed by * * *.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 4 of masonry contract
Party A: Party B:
Quality is life, and safety brings benefits. In order to ensure the completion and acceptance of the project on time and with good quality, all woodworking operations of this project are contracted to Party B, and the specific contract is as follows:
First, the way of contracting:
1 Contract form: single contractor 2 Workload: 30 yuan per square meter for wall surface, ground pavement and stair tread pavement, with an intention of 20xx square meters. Calculated according to the actual square meters, stone dry hanging is counted separately.
2. Project progress: According to Party A's requirements, the total construction period is days, and Party A guarantees that the site will be completed on schedule, and the site must be cleaned up and the supplied materials will be in place on time. Party B shall not be responsible for the project delay caused by design changes.
Third, safety: we must ensure the safety of construction and put an end to any accidents. Party B must be equipped with safety officers, and all kinds of workers should bring their own safety helmets. However, Party B must purchase products that meet the national safety supervision standards, sign safety contracts for employees, make safety technical disclosure for sub-projects, obey on-site safety management, and report hidden dangers in time. Party B (contractor) shall be responsible for all safety during construction, and Party A shall not bear any responsibility.
Four. Civilized health 1 Keep the site clean and tidy, civilized and healthy every day, and coordinate with each type of work, so as to leave a good impression on the owner and supervisor. Materials should be neatly stacked when entering the site, and garbage should be returned to the heap. Clean up the materials after work every day and don't waste them.
Verb (abbreviation of verb) payment terms
When Party B enters the site, Party A will pay part of Party B's expenses, and the rest will be settled after completion and acceptance.
6. This contract is made in duplicate, which will take effect after being signed by both parties, and each party holds one copy.
Party A:
Party B:
Date:
date month year
Article 5 of masonry contract
General contractor: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
In order to clarify the work contents and rights of both parties, meet the requirements of project progress, quality, safety and civilized construction, and ensure the smooth progress of the project, Party A and Party B follow the principles of voluntariness, equality, fairness, honesty and credit, and reach the following terms through negotiation.
I. Overview of the Project:
1. Project name:
2. Project location:
3. Signing method:
Second, the scope of contracted projects:
1. All contents in the construction drawing (building) except external wall insulation, including the erection and demolition of all temporary facilities, hardening of roads and sites, etc.
2. Cleaning and maintenance of the floor during concrete pouring; Masonry material turnover, etc.
3. After the first layer of wall masonry is completed, clean up the first layer, and clean up the concrete, bricks and other construction wastes on the external wall scaffolding. And cooperate with the project department to do a good job of setting out the floors of the building on the construction site, and be responsible for the material cleaning and sanitation work in the early stage of the inspection by the quality and safety department of the building.
4. Construction and cleaning of roof, balcony and various joint surfaces of balcony;
Three, the construction area calculation and unit price:
The calculation method of the construction area of this project is to calculate the area according to the construction drawing documents stipulated by the state, and the unit price is calculated according to the total construction area of RMB/㎡. The unit price of the project includes the unit price of the construction drawings and all contracted scope. If there is any increase or decrease in the project and design change project, the unit price shall be interviewed according to the project size. In the case of other hourly work, the hourly wage is
Four. Degree of settlement and payment method:
Pay% of the completed workload,% of the completed workload of the main body,% of the workload after completion acceptance and% after audit according to the image progress, and pay the balance within one year.
Five, the construction quality and requirements:
The quality grade of this project is qualified. Quality requirements are as follows:
1. Party B must carry out the construction in strict accordance with the design drawings, design changes and construction acceptance specifications.
2. Party B shall obey the strict supervision and deployment of the construction unit, supervision unit, quality inspection unit, Party A and other relevant units, and carry out the construction in a planned way.
3. The person in charge of Party B shall actively cooperate with the construction personnel and management personnel of Party A in the strict management of this project. Strictly carry out civilized construction, safe production, strict quality control and progress education, and make technical disclosure and safety disclosure before work every day.
4. Quality standard: Cushion, concrete beam, plate, column and roof are vibrated tightly, without swelling, honeycomb, pits and exposed tendons, and the sensory quality is good; Stairs should be poured tightly, and steps and platforms should be polished and leveled. The ground is poured tightly, the upper part is sanded, and the thickness is controlled correctly according to the drawing requirements; The position of construction joints must be constructed according to the requirements of drawings. After the floor slab pouring is completed, the safety net of the external wall must be cleaned manually with tap water and hung neatly; After the completion of concrete pouring, the cement slurry leaking to the next layer must be cleaned up with water in time, and the excess concrete must be fully utilized; Masonry requirements: the verticality is high, the mortar joint is full, the double-sided jointing is horizontal and vertical, and the size of the hole of doors and windows should be controlled according to the drawings; The interface between the wall and the beam should be constructed according to the specification requirements; The lien () of constructional column masonry must be vertically symmetrical; Painting requirements: vertical division should be done well, the wall should be painted flat, with high verticality and straight angle of yin and yang.
Cost control of intransitive verbs
Carefully study the drawings, put forward reasonable saving and rectification plans, and strive to achieve the goal of cost control. If there is waste of materials, Party A will impose a fine of twice the value of the materials on Party B. For materials beyond the plan, Party A will trace them from all aspects. If it is found that it is caused by Party B's construction reasons or poor management, Party A will also impose a fine of twice the material value on Party B. ..
Seven, safe production and civilized construction
(1) Safety in production
1, Party B must be equipped with full-time security officers to be responsible for on-site production safety. Resolutely carry out a series of guidelines, policies, laws, regulations and provisions of the state and the people's governments at all levels where the project is located, and must take necessary measures and means to strengthen safety management, improve the level of safe construction, and determine a strict safety construction system to ensure the safety and health of construction personnel during construction and ensure the safety of the project.
2. Party B must implement the policy of safety first and prevention first, and strictly implement the construction safety management regulations of construction projects. As the first responsible person, the team leader must personally pay attention to safety, establish a strict safety monitoring network and an effective safety guarantee system.
3. Before entering the site, Party B shall carefully select personnel to ensure their high ideological and moral quality, high technical quality and good physical quality. It is forbidden to recruit/kloc-minors under the age of 0/8 and elderly people over the age of 55 to enter the site for construction. All personnel must go through three-level safety education and sign with a safety card after passing the examination. Party B's operators should strengthen the study of safety production knowledge and safety operation procedures, wear all kinds of automatic labor protection articles, and give full play to the operational role of the three treasures of safety.
4. All management personnel and special operations personnel of Party B shall hold relevant certificates, and construction personnel shall hold valid professional qualification certificates. When entering the site, the original or copy of valid post certificates shall be submitted to Party A for filing.
5. Party B shall take full responsibility for all kinds of safety accidents during construction. Party B shall immediately report the accident to Party A's project department and take emergency measures to save people in time.
6. Any safety violation of Party B at the construction site will be subject to economic punishment, and at the same time, any punishment suffered by Party A due to Party B at the construction site will be borne by Party B twice.
7. Party B must operate in accordance with the operating rules for safety in production, strictly abide by the regulations on safety in production and various rules and regulations, and conscientiously implement the national mandatory regulations. Party B's personnel will be fined 200.00 yuan for not wearing safety helmet and slippers to work after drinking.
8. Party B shall implement the relevant regulations on safety construction management of engineering construction, take safety protection measures seriously, abide by the safety management regulations of Party A, obey the unified management of Party A, and accept the safety inspection and supervision of Party A at any time.
9. Safety objective: no major personal injury or death accidents; The minor injury rate is less than five thousandths; No major mechanical and transportation accidents; Put an end to major fire accidents and avoid heavy equipment accidents with personnel responsibility; Party A encourages Party B to put forward higher safety objectives and implement them in the project.
10. All equipment must be connected with the leakage protector by Party A's professional electrician, and the temporary construction electricity will be arranged and used by Party A's professional electrician. It is strictly forbidden to pick up and throw, and all equipment must be cut off after use every day. It is strictly forbidden to change the direction of the original power wires and increase the electrical equipment in the living area without authorization. Those who use rice cookers, rapid heating and other electrical equipment without permission will be fined 200.00 yuan/time, and the electrical appliances will be confiscated. 300 yuan will be rewarded for the team with better management.
(2), civilized construction
1, Party B must be equipped with full-time civilized construction administrators, and strictly implement the Management Measures for Civilized Construction of Building Projects and other documents issued by the municipal government; Strictly implement the documents and regulations of other functional departments of the city.
2. During the construction period, Party B shall keep the site working face smooth and orderly, remove rainwater and sewage in time, properly arrange all equipment and materials, and remove the garbage left by Party B's construction from the site, and the labor costs shall be borne by Party B..
3. Party B's leftovers shall not be littered. Party A shall conduct civilized safety inspection on Party B's construction site, production area and living area from time to time, and impose a fine of 500.00 yuan if it fails to meet the standards at one time.
4. Party B must carry out civilized construction, clean up the site after work, and pile up the materials by classification; After the completion of each node, clean up the node and keep it clean, so as not to leave construction waste and domestic waste for the construction team in the next working procedure.
5. From the beginning of the project to the end of the project, Party B shall be fully responsible for the safety of construction personnel and keep the site and the project in a good environment; Take reasonable measures to protect the construction site and surrounding environment, and avoid pollution, noise or damage or interference to public personnel and property due to improper construction methods; Ensure that the construction site is civilized and tidy, and that the work is finished, the materials are exhausted and the site is clear. When handed over to the site, the results of site cleaning shall satisfy Party A in time.
Eight. Responsibility of both parties
(I) Party A's responsibilities
1, providing construction-related documents such as construction drawings, design changes and records of the blue prints.the design;
2. Provide temporary living facilities for Party B's construction personnel;
3. Provide raw materials in time to ensure the needs of engineering construction;
4. Responsible for providing water and electricity for construction;
5, timely organize relevant departments to acceptance of the completed project, in order to facilitate the construction of the next working procedure;
6. Provide the construction site, coordinate the surrounding relations, and ensure a good construction environment;
7. Pay the project progress payment in time according to the payment method stipulated in the contract;
(II) Party B's responsibilities
1. Party B must unconditionally obey Party A's construction requirements and overall management on safety, quality and progress.
2. If Party B fails to meet all the requirements within the scope of this contract, Party A has the right to deduct the living expenses of the current month or make a corresponding fine, or even terminate this agreement, and all the responsibilities and expenses arising therefrom shall be borne by Party B. ..
3. The authorized representative of Party B at the construction site must be stationed at the site every day, and Party A will attend this person's attendance. If there are special circumstances, you must ask for leave from Party A's project department, who is solely responsible for the management of construction quality, construction progress, construction safety and civilized construction and the collection of project funds. Attend various meetings hosted by the construction site on time, convey the meeting spirit to every construction worker, supervise the implementation of the meeting spirit, and accurately feedback the implementation of the meeting spirit to the project department.
4. Party B must submit to Party A the list of full-time safety officers, full-time quality inspectors, full-time civilized construction administrators, full-time production administrators and other construction workers, and attach the employment certificates of Party B's management personnel and special types of work, and the expenses shall be borne by Party B. Party B's construction workers shall be relatively stable and shall not be deployed at will, and shall be deployed reasonably according to the size of construction tasks to meet the requirements of construction progress.
5, take good care of the company's property, put an end to material waste in the construction process, and control the material loss at the lowest point.
6, each team should be self-effacing, friendly cooperation, do a good job of unity between each type of work, if there is a contradiction between the workshop to find the project department site management personnel to solve.
7. Carry out the construction according to Party A's overall construction plan to ensure that the construction task is completed on schedule.
8. Party B guarantees to sign labor contracts with all construction workers and purchase various insurances for them in time. Regardless of whether insurance is purchased or not, Party B shall bear all the responsibilities and expenses of all accidents during the construction of this project. Party A may directly pay workers' wages or supervise Party B's payment according to the actual situation. The funds used are deducted from Party B's project payment, and the funds allocated by Party A are special funds. Party B shall pay the laborer in time and shall not use it for other purposes. Handle labor disputes in a timely manner, stop complaints and petitions, and it is strictly forbidden to push labor disputes to the society.
9. Party B's construction personnel must go through the formalities of temporary residence permit when entering the construction site, obey the management, and it is forbidden to fight, steal or gamble on the construction site, and it is forbidden to bring children into the construction site. In case of violation of law and discipline, fighting, reporting complaints and petitioning to 1 10, all responsibilities shall be borne by Party B. ..
10. As an independent economic entity, Party B manages its own employees, such as related safety education, safety knowledge and skills training, production work arrangement, salary distribution, accident insurance, endowment insurance, medical insurance, living expenses, labor insurance supplies and other expenses. Party B shall be equipped with safety helmet, raincoat, rubber shoes and construction tools.
1 1. During the project construction, Party B shall keep the construction status at any time every day. After the completion of the project, the remaining materials and wastes will be cleaned and classified according to the location designated by Party A's management personnel.
65438+
13. If the construction period is delayed due to the following reasons, the construction period can be postponed after being confirmed by Party A: engineering quantity changes; Force majeure; Other circumstances in which Party A agrees to postpone the construction period.
14 If the construction period cannot be completed normally due to Party B's reasons, Party A has the right to compensate Party B for additional economic losses.
Nine. Dispute resolution method
Disputes arising in the course of performance shall be settled by both parties through consultation. If negotiation fails, a lawsuit may be brought to the people's court where the project is located, requesting the people's court to make a ruling.
The above agreement is made in duplicate, each with seven pages. It will take effect after being signed by both parties, and will automatically become invalid after the project payment is settled.
Person in charge of Party A: Person in charge of Party B:
Telephone number:
ID number: ID number: