Repair and maintenance contract general model 1
Party A:
Party B:
In order to prevent Party A due to the equipment repair and maintenance in a timely manner can not be caused by the loss of normal work caused by the production of financial losses, Party B hereby accepts Party A entrusted. Party B to ensure the normal use of Party A's equipment, Party A's contract equipment repair and maintenance services. In order to protect the legitimate rights and interests of Party A and Party B, according to the "Chinese People's *** and the State Contract Law", Party A and Party B follow the principle of fairness and friendly negotiation signed this contract. Before signing the contract for the first time, the equipment should be normal operation before signing the contract. The contents of the contract are as follows:
Article I of this contract instructions for use
1.1 equipment system to provide repair, maintenance services contract;
1.2, the contract reserved spaces, the contract can not be vacant after the signing of the contract;
1.3, the content of the terms of the contract changes should be made by the A and B after negotiation, the use of written form by the two parties method of designated representatives or authorized representative duly signed, and stamped with the unit contract seal/official seal to take effect, no party can not change without authorization. The changed part is an integral part of this contract.
Article 2 Scope of repair and maintenance
Because the monitoring equipment used by Party A is not purchased from Party B, Party B can only repair and maintain part of Party A's equipment.
2.1, repair and maintenance of the scope of the equipment are ;
2.2, not in the scope of maintenance are .
Article 3 Party B obligations:
3.1, Party B according to Party A contract equipment failure repair notice, Party B priority arrangements for door-to-door maintenance. In the legal working days from Monday to Saturday, Party B arrived at the scene within 8 hours; emergency accidents need to arrive at the scene within 2 to 4 hours;
3.2, Party B door-to-door repair without charging door-to-door fee and labor hourly fee;
3.3, Party B door-to-door repair without a limit on the number of times;
3.4, such as the equipment can not be repaired the same day to use, you can be provided by the Party B to provide temporary standby equipment
3.5, such as damage to the equipment confirmed by both sides, can no longer continue to use, by Party B to provide free equipment replacement, repair and maintenance;
3.6, Party B according to the Party's contract equipment to develop equipment maintenance program, and reported to Party A. In the absence of Party A repair notification, Party B can provide temporary spare equipment. In the absence of Party A repair notice, Party B according to the maintenance plan, Party A contract equipment for door-to-door maintenance. Under normal circumstances, the maintenance service shall be once every four months. Party B each maintenance work is completed, respectively, by the two parties responsible for signing the archives;
3.7, Party B all work is not subcontracted to other units, once found, Party A has the right to terminate the contract;
3.8, Party B for the Party's contract for the maintenance of equipment repair and maintenance of the tools required by the Party B equipped with their own.
Article 4 Obligations of Party A
4.1, Party A shall promptly notify Party B after the failure of the agreed equipment.
4.2 Party A can not use spare parts and consumables not recognized by Party B, otherwise Party B will not be responsible for equipment failure;
4.3 Without Party B's approval, Party A shall not invite third-party units to carry out repair and maintenance services on the contracted equipment, otherwise Party B will not be responsible for the consequences and liabilities arising therefrom;
4.4 Party A shall not carry out private disassembly of the contracted equipment, otherwise Party B will not be responsible for the consequences and liabilities arising therefrom;
4.4. equipment for private disassembly, otherwise Party A shall bear the resulting . All losses;
4.5, the agreement on the transfer or transfer of equipment, Party A shall promptly notify Party B;
4.6, Party A has a supervisory obligation to Party B to provide temporary standby equipment, such as Party A in the use of the process of man-made damages, loss of the situation occurs, to its Party B caused by all the losses borne by Party A.
Article V. Calculation of repair and maintenance costs
Article VI. Validity of the contract and payment
6.1, the contract is valid for the year signed by both parties from the date of entry into force to the date of annulment;
6.2, the repair and maintenance costs are payable in two installments, every six months as a cycle, from the date of signing of the contract to pay the first maintenance service costs of RMB yuan, capital letters. The first repair and maintenance fee is paid within 2 (two) days from the date of signing of this contract, i.e. RMB Yuan, capitalized yuan: the second repair and maintenance service fee is paid in full within 2 (two) days from the date of month of year, i.e. RMB Yuan, capitalized yuan.
Article 7 Disclaimer
7.1, due to force majeure (i.e., unforeseen, unavoidable, insurmountable objective circumstances, including but not limited to earthquakes, floods, fires, wars, governmental actions, etc.) or other damages and losses caused by non-Party B's work errors, Party B will not be responsible for;
7.2, due to force majeure causes delay in the performance of the contract or can not be performed, then in the event of force majeure, Party A shall not be liable for any damage to the contract or losses caused by force majeure. If the contract is delayed or cannot be performed due to force majeure, the party in case of force majeure shall notify the other party within 48 hours from the date of force majeure and submit relevant supporting materials at the same time. Except for the losses caused by the other party due to the delay in the fulfillment of the notification obligation, both parties shall not be liable to each other for the losses caused by the force majeure. In the event of force majeure, one party shall notify the other party within 48 hours after the force majeure is eliminated, and the two sides shall negotiate whether to continue to fulfill the contract;
7.3, in the event of force majeure, the party in the event of force majeure is still responsible for taking the necessary measures to prevent the force majeure event from expanding the impact of the force majeure.
Article 8 Responsibility for breach of contract
8.1 Both parties shall fulfill their obligations in strict accordance with the terms of this contract. Except as otherwise provided in this contract, if either party fails to fulfill any of the terms of this contract, it shall be deemed to be in default. The defaulting party shall pay 3% of the total amount of this contract as liquidated damages to the defaulting party. However, the maximum shall not exceed 5% of the total price of this Contract. If the agreed liquidated damages are not enough to compensate for the losses suffered by the defending party, the difference shall also be compensated;
8.2. If a party fails to fulfill its contractual obligations or the fulfillment of its contractual obligations is not in accordance with the agreement, and if the defending party has any other losses after fulfilling its obligations or taking remedial measures, the defaulting party shall compensate for the losses;
8.3. If both parties are in breach of the contract, they shall each bear the corresponding responsibility;;
8.4. If a party breaches the contract due to a third party, it shall bear the responsibility for the breach of contract to the contract-keeping party. Disputes between the defaulting party and the third party shall be resolved in accordance with the law or in accordance with the agreement.
Article 9 Disputes and Dispute Resolution
All disputes arising from the fulfillment of this contract shall be resolved by both parties through friendly consultation first. If no agreement can be reached after consultation, the dispute can be submitted to the local people's court and resolved through litigation.
Article 10: Termination of the Contract
10.1 The parties may terminate this contract in the event of any of the following circumstances:
(1) If one of the parties delays in the performance of the main obligations under this contract and fails to make corrections for more than one day after the receipt of a written notice of default from the other party;
(2) If force majeure occurs, which makes it impossible to fulfill the purpose of the contract.
10.2. This contract shall be terminated when the notice of termination reaches the other party;
10.3. After the termination of this contract, if it has not yet been performed, it shall not be performed; if it has been performed, the party who performs it shall have the right to demand that the party who violates the contract pay for the part of the default that has been performed, or to compensate for the damages.
Article 11 Contract Entry into Force and Other
11.1, if at any time any provision of this contract becomes illegal, invalid or unenforceable but does not fundamentally affect the validity of this contract, the other provisions of this contract shall not be affected, the two sides should be invalid part of the negotiation of the signing of a supplemental agreement;
11.2, the title of each article of the contract is only for The content of the articles should determine the rights and obligations of the two sides shall prevail; 11.3, this contract in duplicate, A and B each holds a copy, with the same legal effect;
11.4, this contract by the A and B legal representatives or authorized representatives to sign and stamped with the unit of the contract seal / official seal after the entry into force;
11.5, the contract is not yet completed, by the A and B After friendly consultation, sign a supplementary agreement. The supplementary agreement and this contract have the same legal effect.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ ____ ____ _________ ____ ____ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ _________ ____ Day
Repair and Maintenance Contract General Model 2
Party A:
Party B:
According to the "People's Republic of China *** and the State of the Contract Law" and related legal provisions, A and B through friendly consultation, the air-conditioning maintenance matters reached an agreement on the agreement signed by both parties according to their agreement to perform.
First, the subject of the contract
Party B was commissioned by Party A, for its business hall in use - brand air conditioning system to provide paid maintenance services. Maintenance scope is: host, end, the maintenance of the entire system.
which includes: business hall 1 floor host 2, end 10; business hall host by ___ yuan / unit maintenance fee, end by ___ yuan / unit maintenance fee. The above total, the total annual contract price of ___ yuan whole. ￥: ___ yuan
Second, the maintenance period:
20___ ___ month ___ to 20___ ___ month ___.
Third, the payment method:
Contract signed within ten days of the date of Party A to pay the full amount of RMB ___ yuan, ￥: ___ yuan
Fourth, the maintenance service standards and content:
Strictly in accordance with the ---- air conditioning system maintenance manual, air conditioning maintenance.
Specific content is as follows:
1, air conditioning end system every year at the beginning of summer and winter to carry out a sterilization, disinfection, purification treatment to remove microbial growth, eliminate the root cause of bacteria, so that the fan sent to regulate the wind in line with the air health standards.
2, the host system and pipeline anti-corrosion treatment once a year.
V. Party A's responsibility:
1, for Party B in and out of the air conditioning maintenance work to provide convenience.
2, to provide a complete air conditioning technical information.
Sixth, Party B's responsibility
1, strictly in accordance with the company's air conditioning maintenance manual to provide air conditioning maintenance services.
2, accept Party A supervision to ensure that the service is in place.
3, in the party received a repair notice within 24 hours to the scene.
4, replacement of faulty spare parts to Party A check, maintenance only charge for accessories and materials, accessories prices see accessories price list.
5, each repair must have a repair order, and reported to the use of the department and the property department to sign the confirmation; outside the contract costs incurred in the maintenance project to be signed by the power division to confirm.
VII. Contract termination:
a. Party A has the right to terminate the contract by written notice to Party B in one of the following cases:
1, Party A to provide proof of change in property rights.
2, the maintenance program is not on schedule, according to the quality of the full performance of more than one quarter, and by the --- city authority to identify the problem does exist.
3, Party A due to force majeure reasons can not fulfill the contract.
b. In one of the following cases Party B has the right to notify Party A in writing to terminate the contract:
1, change of ownership.
2, Party B can not fulfill the contract due to force majeure.
3. If Party A is in bankruptcy, liquidation (except for merger or reorganization) or fails to pay the debts due.
VIII. Liability for breach of contract:
1. If Party A defaults on the contract: Party B shall pay liquidated damages of --- yuan whole. And pay off the outstanding amount, Party B has the right to require Party A to continue to fulfill the contract.
2. If Party B is in breach of contract: Party B shall pay liquidated damages to Party A --- Yuan. Party A has the right to require Party B to continue to fulfill the contract.
Nine, other agreed matters:
1, air conditioning repair if the replacement of spare parts --- yuan within the cost borne by Party B, --- yuan more than the Party assumed.
2, if the third party repair air conditioning damage caused by Party B is not responsible.
3, the contract has not been resolved through friendly negotiations between the two sides.
X. This contract is in four copies, Party A holds three copies, Party B holds a copy, since the two sides signed and sealed the establishment, and effective in accordance with the law.
Party A:
Party B:
Date of signing:
Repair and Maintenance Contract 3
Party A:
Party B:
Based on the "People's Republic of China*** and the State of the contract law" and related legal provisions, A and B through friendly consultations, on Central air conditioning repair and maintenance matters reached agreement, agreed to sign this contract.
First, the project overview
1, the project is located in Shenzhen.
2, the scope of maintenance is: host removal, testing, repair; electric auxiliary heating equipment installation; host forced exhaust cooling device processing and installation; end, water circulation system, air circulation system repair, renovation, maintenance, debugging; room partitioning, sub-control system renovation and retrofitting; the entire central air conditioning system maintenance, debugging. Make the system normal use.
Second, construction time:
(1) 20___ years ___ months ___ before, Party B sent engineering and construction personnel to arrive at the site to start overhauling the construction;
(2) 20___ years ___ months ___ before, complete the pre-concealed construction and acceptance;
(3) 20___ years ___ months ___ before. Completion of the end, water circulation system, air circulation system repair, maintenance and commissioning of the entire air conditioning system operation. Make the whole air conditioning system normal operation.
Third, the project cost and payment:
The project cost of this contract is 150,000 yuan. (CAPITALS: one hundred and fifty thousand yuan)
20___ ___ month ___ ago, Party A to pay Party B 40% of the contract price, all works completed, acceptance and signature confirmation by Party A, Party A to pay Party B 50% of the contract price.
10% of the contract price for the warranty. If all the works are completed, accepted and signed by Party A to confirm the warranty period of one year without quality problems, within five working days after the end of the warranty period, Party A to pay Party B.
All of the above.
All the above payments before payment, Party B shall provide Party A with invoices that meet Party A's requirements.
Fourth, the quality of the project and acceptance
The quality of the project must be in line with the design requirements and the construction specifications issued by the state and quality assessment standards.
Upon completion of the project, Party A will conduct acceptance in accordance with national industry and technical specifications.
V. Material and equipment procurement
The materials and equipment required for this project will be purchased by Party B. The materials and equipment purchased by Party B must comply with the specification requirements and have product qualification certificates and quality inspection certificates. The quantity and price of the purchased parts are shown in the annex to this contract.
Sixth, Party A's rights and obligations
1, according to this contract for labor inspection and pricing procedures, appropriation and settlement of the project price.
2, the quality of the project and the progress of the project supervision and inspection, the inspection of the quality problems and safety hazards found in the right to require Party B to stop work and repair.
3, according to the relevant norms to organize the completion of acceptance handover.
7, Party B rights and obligations
1, the air-conditioning system for inspection, preparation of construction programs, reported to Party A after the validation of the implementation.
2, according to the terms of this contract to do a good job of material procurement.
3, strictly in accordance with the relevant norms for construction, to ensure the quality of the project, according to the contract agreed upon the completion of the construction period and delivery of use.
4, after the completion of the project, in accordance with the provisions of the complete completion information.
5, adhere to civilized construction, to achieve safe production, and do a good job of construction site environmental protection and labor protection.
6, Party B shall be responsible for repairing or compensating for the damage caused to Party A's facilities during the construction process.
Eight, the project warranty
The project warranty period since the completion of the project, Party A acceptance of the signature confirmation of one year. During the warranty period, Party B rushed to the scene within 6 hours after receiving Party A's repair notice. Replacement of faulty spare parts to Party A check, non-mainframe fault repair, Party B shall not charge accessories and materials.
Each repair must have a repair order, and reported to Party A personnel to sign the confirmation.
If the condensate or liquid leakage occurs due to the quality of engineering problems caused by the loss of Party A's property in the room, Party B shall bear the responsibility for compensation.
Nine, safety construction
In the construction of Party B must comply with the relevant state safety regulations, pay attention to the construction site safety, to avoid the occurrence of various types of accidents, such as the occurrence of safety accidents by the Party B bear the responsibility.
Party B shall organize the construction according to the relevant regulations or safety norms. During the construction process, any loss of personnel or property not caused by Party A, Party B shall bear full responsibility for compensation. Party B shall have the construction qualification stipulated by the state to carry out the works agreed in this contract. Party B's staff members who undertake the construction under this contract have the corresponding qualification certificates and induction certificates. Party B shall submit the originals of the above documents to Party A for checking, and Party A shall keep the copies.
XI, liability for breach of contract
Party A's liability for breach of contract
1, Party A did not fulfill its obligations under the contract, causing economic losses to Party B shall be compensated.
2. If the project is delayed due to Party A's reasons, the contract period will be postponed.
3. If Party A fails to pay for the project according to the contract and affects the progress of the project, Party A shall be responsible for it.
Party B default
1, Party B for their own reasons can not be completed according to the contract date of completion and acceptance of delivery, should bear the responsibility of late completion of the contract for each day late, should be the total contract price of five thousandths of the total amount of liquidated damages payable to Party A until the delivery of the project.
2, the quality of construction does not meet the design and specification requirements, Party A has the right to require Party B to rework or repair, the cost of which Party B shall bear, late delivery, every day late, shall pay liquidated damages of five thousandths of the total contract price to Party A until the delivery of the project.
3. Party A has the right to terminate this contract if the project can not be continued due to Party B's responsibility, and Party B shall bear the economic loss caused by it.
4. If the relevant documents submitted by Party B in accordance with Article 10 of this contract are invalid or false, Party A has the right to terminate this contract, and Party B shall double the amount of money paid by Party A. If Party B's personnel and property is not in good condition, Party A shall not be liable for any loss or damage. If Party A's personnel and property losses, Party B shall bear full responsibility for compensation.
XII, dispute resolution
This contract in the performance of disputes, the two sides should be in line with the principle of fairness and reasonableness of the timely negotiation to deal with the consultation fails to be submitted to the People's Court of the location of the Party's jurisdiction.
XIII, Supplementary Agreement
This contract is not exhaustive, the two sides can sign a supplementary agreement, the supplementary agreement and the contract has the same legal effect, the budget, the construction program as a copy of the contract also has the force of law.
XIV, bylaws
Two copies of the original of this contract, Party A, Party B, each signing a copy.
Party A:
Party B:
Date of signing:
Repair and Maintenance Contract General Model 4
Party A: _________
Party B: _________
After the negotiation between the two sides, Party A agrees to entrust Party B to be responsible for the maintenance and repair of smart Wireless temperature measurement equipment maintenance, maintenance, repair work, the two sides agreed to sign a contract as follows:
1. Maintenance equipment: _________
Equipment name: _________
Equipment model: _________
Number of equipment: _________
2, Maintenance methods and instructions:
2.1 Maintenance
2.1.1 Party B is responsible for the maintenance of the above equipment, to ensure that the overall maintenance is carried out once a quarter, to ensure that the equipment's temperature measurement points are accurate, the external equipment is complete, and the temperature measurement data is accurate.
2.1.2 Party B will provide qualified maintenance technicians to inspect, maintain, repair and repair all parts of the equipment according to the regulations to ensure that the equipment maintains the best state of operation.
2.1.3 Party B provides brand new equipment spare parts for the replacement of faulty equipment.
2.2 Emergency repair
During the contract period, if the equipment failure needs to do emergency repair, Party A should immediately notify Party B, explain the situation, Party B must arrive within one day after receiving the notice to repair. (In the event of special circumstances can not be reached, Party B should explain the situation, and Party A personnel to negotiate a reasonable solution)
2.3 Related instructions
2.3.1 Party B in the maintenance work, Party A operators should be on site to assist, and designate a person responsible for both sides of the contact, for Party B staff to provide work convenience.
2.3.2 Repair and maintenance of materials required by Party B is responsible for the cost, but involves fire welding and other work, Party A should provide the appropriate welding equipment, and fire operation ticket invoicing work.
2.3.3 During the maintenance of equipment, if there is intentional damage to equipment, Party A shall supervise and penalize.
And need to pay Party B maintenance costs.
3, maintenance period
The contract period is one year (from _________ year _________ month _________ to ________ year ________ month _________ day)
4, maintenance costs and payment
4.1 Total maintenance costs: _________ RMB
4.2 Payment: Party A pays 50% half a year after the contract is signed, and the remaining 50% is paid within 3 days after the contract expires.
5, breach of contract:
5.1 This contract, either party without good reason and does not fulfill the above, it will be dealt with as a breach of contract, the breaching party to compensate the other party for the total cost of the contract 10% each time of the liquidated damages.
5.2 This contract in duplicate, each party holds a copy of the outstanding matters, the two sides to resolve the negotiations.
Signature of Party A: _________
Signature of Party B: _________
Date: _________
Repair and Maintenance Contract General Model 5
Party A: _________
Party B: _________
Hereby Party A and Party B, after friendly consultation and on the principle of equality and mutual benefit, reach the following agreement on Party B's undertaking of _________ maintenance works:
I. Name of the maintenance unit: _________.
Second, the maintenance contract content: _________.
Third, the maintenance cycle and content: monthly inspection
a. Test the automatic door functions.
b. Testing radar sensitivity.
c. Check the door body and stop swing fastening.
Fourth, random events: (received a call to the scene within 48 hours)
1. Electrical failure: 12 hours to remove.
2. Mechanical failure: eliminated within 24 hours.
3. For glass breakage replacement: within 3 days.
V. Maintenance procedures:
1. Party A coordinates and arranges suitable maintenance time, which can be arranged on Saturdays and Sundays.
2. Party B arranges the working time according to the working condition, morning or afternoon.
3. After each maintenance by Party B staff to fill in the maintenance records, Party A staff to verify the records item by item after signing the approval, the maintenance work can end.
VI. Replacement costs:
1. Party A undertakes all the replacement costs.
2. Party A has the right to purchase parts.
3. Party A has the right to ask Party B to purchase parts.
VII. Maintenance cost: The annual maintenance cost is RMB _________ (_________ yuan).
VIII. Payment: Within one week from the date of signing this contract, Party A pays Party B RMB: _________ (_________ yuan). Half a year after the expiration of one week, pay She payment. Counted RMB: _________ yuan (_________ yuan)
IX, the contract implementation period in the event of special circumstances can not be carried out in accordance with the above terms, A, B **** with the negotiation solution.
X. This contract is in duplicate, A, B, each party to sign a copy of the two sides signed and sealed the date of entry into force.
Party A (seal): _________
Party B (seal): _________
On behalf of the (signature): _________
On behalf of the (signature): _________
_________ year ____ month ____ day
_________ ____ month ____ day
Repair and Maintenance Contract General Model 5 Related Articles :
★ New version of the maintenance contract General 5
★ Equipment Maintenance Service Contract Model 5
★ General Facilities and Equipment Repair and Maintenance Contract Model 4
★ After-sales service contract model 5
★ Standard maintenance contract general model five
★ 5 practical equipment maintenance service contract model
★ General maintenance contract model 4
★ Formal equipment maintenance contract format 5
★ Equipment maintenance contract model 5
★ 5 about the after-sales service contract Sample Articles