5 Sample Contracts for the Sale and Purchase of Self-Built Houses
In fact, if the contract seller overpays for the subject matter, the buyer can receive or refuse to receive the overpaid portion of the contract, so do you know how the contract looks like now? I am here to share with you some sample contracts for the sale and purchase of self-built houses, I hope you can help.
Self-built house sale contract model (Selected 1)
Party A: ________________________
Party B: ________________________
Party A has been through the legal procedures to obtain a land-use rights, is now intended to be transferred to the B party, by the two sides of the friendly Consultation, in line with the principle of equality, voluntariness, compensation, honesty and credit, on the transfer of land to reach an agreement on the following matters:
I. Overview of the parcel
1, the parcel is located in ______________, the land area of ______________ square meters (length _______ meters, width _______ meters) east to _______ Street, south to ______________ Street, west to ______________ Street, west to _______ Street, west to _______ Street, west to ______________ Street, west to ______________ Street, west to ______________ Street, west to _______ Street. , south to _______ Street, west to _______ and north to _______.
2. The current use of the site is residential.
2. Transfer Price and Payment Methods
1. The transfer price is RMB _______.
2. Payment shall be made in _______ installments.
The first installment Party B pays a deposit of RMB _______ to Party A. The second installment shall be paid by Party B to Party A. The second installment shall be paid by Party B to Party A.
The second period in the lawyer's office on the date of signing the agreement, Party A to do a good job of housing mortgage formalities and to provide land-related information (including the management area, the company confirms the formalities, etc.) to pay the transfer of the deposit of RMB _______ yuan.
The third installment is paid within one day after the roof of the house built by Party B is sealed with RMB _______.
The fourth installment will be paid after the exterior wall bricks of the project have been put up by Party B. The balance of the payment will be RMB _______.
C. Party A's responsibility
1. Party A shall guarantee to enjoy all rights and interests of the land. Party A shall guarantee that the land use right is transferred to Party B without any dispute. Otherwise, Party A shall compensate Party B for the relevant losses.
2, Party A is responsible for all the procedures for the commencement of construction (tentative thirteen floors), to improve the land three through one leveling, and to resolve all disputes during the construction period (including the installation of water and electricity, supply, the relevant village committees, law enforcement teams and other government management issues).
3, Party A to provide _______ whole house use right as a mortgage guarantee, the mortgage of the use of the house area of _______ square meters, _______ layer, the scope of the mortgage guarantee is the same as the scope of the responsibility assumed by the Party A. Both parties agree to go to the law firm for mortgage registration within _______ days after the signing of this agreement, and the cost shall be borne by Party A.
4. The term of the mortgage shall be until the date of completion of the house built by Party B. The mortgage shall be renewed on the date of completion of the house. If the construction cannot be started in _______ months from the date of Party B's payment of RMB _______ transfer deposit, Party B has the right to request Party A to return the paid transfer deposit of RMB _______ and pay RMB _______ as compensation for loss.
Fourth, Party B's responsibility
1, should be in accordance with the provisions of the relevant procedures (in accordance with the village villagers the same requirements to do for compliance).
2. Pay the land transfer fee on time.
3, the project operates independently, Party B's own design and construction, independent operation, self-financing.
V. Liability for breach of contract
1. If Party B fails to obtain the land use right within two months after the payment of the transfer fee of RMB _______, Party A must return the transfer fee of RMB _______ paid by Party B on the same day, and pay RMB _______ as liquidated damages. Late payment shall be paid at _______ times of the bank loan interest rate.
2. If Party B fails to pay the transfer fee on time, the unpaid portion of the fee shall be paid at _______ times of the bank loan interest rate. If the failure to pay on time for more than _______ working days, it is deemed to terminate this agreement, Party A has the right to dispose of the deposit paid.
Sixth, other
1, this agreement is not exhaustive, shall be negotiated by the two sides to solve, and signed the corresponding supplementary agreement, supplementary agreement and this agreement has the same legal effect.
2, this agreement in the implementation of the process of contradictions, disputes, after consultation is invalid, to the court ruling.
3, this agreement shall come into force after signed and sealed by the representatives of the parties.
4, this agreement is a copy of _______, A and B each _______, lawyers _______, the village committee _______, with the same legal effect.
Party A (seal): ________________ Party B (seal): ________________
________ year ________ month ________ day ________ year ________ month ________ day
Self-built house sale and purchase contract model (selected) (Part 2)According to the "Chinese People's *** and State Consumer Protection Rights and Interests Law", "Chinese People's *** and State Contract Law", the relevant provisions of the contract, signed this contract, and *** with compliance.
Material
Furniture Name
Specification
Color Sample
Quantity
Unit Price
Total
Total Upper Case Amount: Gleanings 10,000 Thousand Hundred Hundred Dollars and Angle Minutes Total Lower Case ￥:
1. Advance Payment ￥:___________ Remaining Payment ￥: ____________ (before shipment, Party A must pay the full amount after Party B according to the single shipment as scheduled)
2, because of the use of the deposit method of payment, such as the A and B parties, either party default, midway to terminate the contract will be 3 times the total amount of the order to compensate each other.
3. Delivery time is within 10 days after the effective date of the order.
4, Party A requires Party B to produce furniture material is the African raw material book name: hedgehog rosewood material, each single piece of furniture table body color shall be all the same.
Note: The contract confirmed by the signature and seal of Party A and Party B will be implemented in accordance with the provisions of the above articles.
Party A (buyer) Signature: _______________ Party B (seller) Chapter: ________________
Party A Address: _______________________ Party B Address: ______________________
_______________________ Responsible person: ______________________
Tel: _______________________ Tel: ______________________
Date of contract: ______ ______ Month ___ Day
Self-built house sale contract model (Selected Part 3)Contract No.: [20] No.
Supply unit (Chapter): Purchasing unit (Chapter): Signing place: Signing time:
Order list
Product code
(with the flow of the registered product code) product name product category product
Level specification/model measurement
Unit box contains medicine
(kg) order
Quantity unit price
(yuan) amount
I. This contract shall be executed in accordance with the "Contract Law of the People's Republic of China*** and the State of China," and other relevant provisions. The buyer and seller shall strictly abide by the provisions of the "People's Republic of China *** and the State Safety Production Law", "Regulations on the Safety Management of Fireworks" and other relevant laws and regulations, operate in accordance with the law and ensure safety.
II. Product quality standards and requirements:
III. Requirements for prohibited (restricted) drugs:
IV. Product packaging standards and requirements:
V. Time and place of pick-up (delivery):
VI. Transportation mode and cost burden:
VII. Acceptance standards and methods:
VIII. Period for raising objections:<
IX. Settlement method and period:
X. Product safety and quality responsibility:
XI. Transportation safety responsibility:
XII. Liability for breach of contract:
XIII. Settlement of disputes of contract: Disputes occurring in the course of the fulfillment of the contract shall be settled by the two parties through consultation, and if the consultation fails, the dispute shall be settled according to the following way (choose one) 1. Both parties agree to submit the dispute to the Arbitration Commission arbitration;
2. Litigation to the People's Court according to law.
XIV, other agreed matters (can be attached to another page):
Purchasing unit (chapter) unit name? License number? Unit address? Postal code? Legal representative
(signature)? Contact phone? Authorized agent
(Signature)? Contact phone number? E-mail address? E-mail address? Bank? Account? Supply unit (chapter) unit name? License number? Unit address? Postal code? Legal representative
(signature)? Contact phone number? Authorized agent
(Signature)? Contact phone number? E-mail address? E-mail address? Bank? Account?
Valid from the date of the year to the date of the year
Self-built house sale contract (Selected 4)Buyer: ___________________ (hereinafter referred to as Party A)
Seller: ___________________ (hereinafter referred to as Party B)
A and B on the purchase and sale of vehicles to reach the following agreement, *** with compliance:
Article 1: Party A to purchase a motor vehicle owned by Party B. Agreement, *** with compliance:
Article 1: Party A purchases a motor vehicle owned by Party B:
Car number: ___________________ Color: ___________________
Place of origin: ___________________ Model: ___________________
Engine number: ___________________(top-printed and pasted)
Chassis number: _____________________(top-printed and pasted)
Article 2: Party A pays Party B the car payment of RMB one time in cash of ____________ million yuan.
Article 3: Party B shall immediately deliver the defect-free vehicle and accompanying tools on the date of receipt of Party A's payment for the vehicle. The defective guarantee period is one month from the date of delivery of the vehicle. And guarantee that others do not have any claim on the vehicle.
Article 4: Both parties hereby declare that since the date of signing of this contract, the vehicle and its accompanying tools, ownership certificates, relevant certificates and information, payment of taxes and fees have all been handed over to the buyer under this contract. The parties will not issue a separate handover list. Party B guarantees that all the documents and tax and fee payment certificates of the vehicle delivered to Party A are true and valid.
Article 5: Party B shall bear the cost of transfer or notarization. Party A has the obligation to assist in the process.
Article 6: Party B shall ensure that the maintenance of the vehicle is normal and the formalities are complete before delivery. After the signing of this contract, because the vehicle is under the management of Party A, the vehicle caused by all the responsibilities of Party A is responsible for, and has nothing to do with Party B. If Party B bears the responsibility because of the vehicle, Party A will not be responsible for it. If Party B bears the responsibility because of the vehicle, it has the right to recover the full amount from Party A.
Article 8: Both parties shall pay liquidated damages to each other for violation of this contract.
Article 10: This contract shall enter into force on the date of signature by both parties. This contract is in duplicate. If you need to notarize, then increase the number of copies to the notary public for the record.
Party A: ___________________ Party B: ___________________
Address: __________________ Address: _______________________________
Document number: ______________ Certificate No.: ___________________________
Year Month Day Year Month Day
Self-built House Sale and Purchase Contract Model (Selected Part 5)Party A: Shandong Branch of Dalian Chuksung Group Co., Ltd, Dongping County Book Building Project Department
Party B: Shandong Weifang Zhongding Steel Structure Ltd.
Based on the Contract Law of the People's Republic of China, the Construction Law of the People's Republic of China and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and honesty and credit, Party A enters into the agreement by consensus on the procurement of color steel plate room produced and installed by Party B.
Party A is a member of Dalian Chucheng Group Co.
I. Project Overview:
Project Name: Dongping County Book Building
Project Location: 24# Xishan Road, Dongping County
Project Content: One layer of the skeleton flat roof rock wool color steel plate room and two layers of the skeleton flat roof rock wool color steel plate room. All of the above color steel plate rooms are required to use flame retardant materials and comply with the management regulations and national standards for safe production.
Second, the scope of contracting
Contracting scope: the supply and installation of all materials required for the color steel plate room.
Third, price and area
1, color steel plate room area of about 566 square meters (the final settlement area to the actual measurement of the area shall prevail).
2, ○1, double-story color steel room calculated at 235 yuan per square meter (this unit price does not include civil construction, water, electricity, ceiling, floor decoration, security nets, curtains) door and window models see Article 5 6.
○2, anti-theft window installation (including materials, labor costs) 100 yuan / a (anti-theft window according to the actual number of installations, not separate area).
○3, gypsum board ceiling (including materials, labor costs) 20 yuan / square meter (calculated according to the actual construction area).
○4, local bathroom bathroom roof with 75mm thick flame retardant color steel plate, (including materials, labor costs) 90 yuan / square (calculated according to the actual construction area).
The above unit price includes tax, transportation cost, loading and unloading cost.
3, calculate the area: one-story house calculation: length × width = total area
two-story house calculation: first floor length × width + second floor length × width + (aisle length × width + canopy length × width) ÷ 2 + staircase 4.5 square meters (each) = total area
4, from Liaocheng demolition of movable houses to Dongping installation, according to the construction area of 60 yuan/square meter (including the Liaocheng demolition of movable houses, transportation, installation and supplemental incidental materials, as well as the construction area)
Fourth, the duration
The contract duration of the total number of working calendar days (15) days. In case of delay caused by the following reasons and written visa by Party A, the work period may be appropriately postponed.
1, due to continuous power outage for more than 8 hours, more than 8 winds, continuous rain for more than 48 hours.
2. Major design changes and increase in workload exceeding more than 20% of the tentative volume of work under this contract.
V. Product quality:
1, wall panels: rock wool board double-sided white thickness of 5cm, tin national standard 0.3mm.
2, the top plate: rock wool board on the blue under the white thickness of 5cm, tin national standard 0.3mm.
3, the skeleton columns of C-beam steel 8 × 4 all 1.8mm, spray blue.
4, flat beam and pointed beam purlin sprayed red rust paint, C steel 8 × 4, all with 1.8mm.
5, the second floor with multi-layer planks 1.5cm thick.
6, the windows are plastic steel windows with screens, office buildings, staff dormitory buildings with security doors, the above facilities are included in the unit price, no longer separate costs.
7, floor bracket for 40cm a, stair board width of 0.2m, corridor railing using 1.5mm thick square tube.
8, party B to provide the above color steel plate room material service life should meet party A and the owner of the construction project signed in the construction contract agreed to the total duration of the requirements, and at least be able to ensure that party A in the contract within the total duration of the construction period and the end of the period of two years after the continued use of the time, and the arrival of each item of material is required to be designated by the acceptance of party A after the acceptance of the qualified personnel before use.
Sixth, Party B commitment:
1, Party B to ensure that all materials under this contract are in line with national standards and Party A site design, construction, use of the needs;
2, the first floor and the second floor of the skeleton room are all screwed fixed, no welding
3, Party B to ensure that the Party issued ordinary formal invoices, or else the Party has the right to refuse to pay the contract price.
VII, Party A's rights and obligations
1. Party A shall provide the construction of water, electricity, into the ground and deal with the city, including construction, neighboring relations.
2. After the completion of the project, Party B issued a written acceptance application to Party A within seven days after Party A organization acceptance (such as delayed acceptance is considered qualified). Acceptance by Party A, Party A issued a written acceptance certificate; otherwise, Party B shall assume the responsibility of replacement, repair, etc. in accordance with the requirements of this contract, such as Party A notification, Party B refused without cause or delay in the deadline to assume the responsibility of replacement, repair, etc., Party A shall have the right to select a separate builder, do not pay the contract price, do not assume any responsibility for breach of contract, such as this affects the use of Party A, Party B shall compensate for all the economic losses of Party A If this affects Party A's use, Party B shall compensate Party A for all the economic losses; and calculate the liquidated damages according to one-thousandth of the total price agreed in this contract on a daily basis.
3, the project is not accepted before Party A shall not move in, such as moving in is deemed to be accepted. And pay the end of the project.
4, Party A designated for the acceptance of the contract under the acceptance of the person responsible for the measured area verification and acceptance.
5. Party A has the right to supervise Party B's behavior during the construction process and eliminate the occurrence of non-compliance with safe production.
8, Party B's rights and obligations
1, Party B arranged all the installers should be in accordance with the construction needs of the license on duty, and will be relevant to the certificate of duty by Party A archives for inspection. Party B guarantees that the construction of the color plate room in strict accordance with the construction procedures, such as in the construction process of personal injury and Party A has nothing to do.
2. Obey Party A's arrangement, guidance and supervision.
3, strictly in accordance with the agreed material specifications construction.
Nine, payment
This contract Party B agreed to take advances construction. For this both sides on the payment terms agreed as follows:
1, office building double color steel plate room materials arrived at the construction site installation is completed, and by the party after acceptance of 50% of the project payment. Dormitory building installation dismantling labor costs and other installation is completed by party A after acceptance to pay 100% of the project.
2, the library building project first payment of the project price of 90% of the color steel room.
3, the remaining 10% of the project as a warranty, in the warranty period, and confirmed in writing by the Party A no default, no quality problems after payment, but Party B shall issue a full invoice.
X. Warranty period and scope:
Warranty period of one year, since Party A accepted and issued a written record of acceptance, the warranty period due to the quality of construction and materials of any problem by Party B gratuitous repairs, except for man-made damages and damages caused by natural disasters.
XI, this agreement in four copies of Party A, Party B, a copy of three, signed and sealed by Party A and Party B shall come into force.
XII, this agreement must be complied with by both parties, either party violates this contract, the defaulting party shall compensate the contracting party for all economic losses, including but not limited to direct and indirect losses, and in accordance with the relevant provisions of this contract and the agreement of this article, respectively, to bear the contract price of 3% of the liquidated damages.
xiii, this agreement is not exhaustive of the two sides to solve the consultation, the consultation fails to be appointed by the people's court jurisdiction of the location of the project to bring a lawsuit.
Party A: (seal)
Party B: (seal)
Responsible for:
Responsible for:
Telephone:
Telephone:
Date:
Date:
Date:
Date:
Date: