2022 School Maintenance Project Contract 1
Party A:
Party B:
Party A has the township government office building, the Judicial Institute, the cultural station and so on a number of office maintenance project a, after discussing the contract to Party B to carry out the construction of the construction and repair in order to clarify the responsibility to be on time, the decorative ____ yuan (____ yuan).
Fourth, the duties and obligations of both parties:
(a) Party A's duties and obligations: responsible for the technical guidance; according to the construction progress of the project payment.
(2) Party B's duties and obligations: strictly according to Party A's technical requirements for construction, and according to Party A's requirements, on time to complete the project tasks.
V. Quality requirements: Party B should do quality and quantity, to ensure the quality of the project and the project is completed in full. After the completion of the project, the Party organized by the acceptance of the personnel, such as construction does not meet the quality standards or project requirements, the Party refused to pay the project, the consequences of Party B at your own risk.
Six, start to completion time: 20 - July 28 to August 28th.
VII. Project settlement and payment:
(a) Project settlement: After acceptance, the amount of work confirmed by both parties shall prevail, and the actual amount of work shall be settled.
(ii) project payment: A and B signed the contract, by Party B with construction tools into the construction, Party A funds in place according to the total cost of the project prepaid 30% to Party B, the remaining portion of the progress of payment according to the project. After the project is completed and accepted by Party A, the project will be paid off immediately
Party A: Party B:
Date of signing:
2022 School Maintenance Project Contract 2
Contractor (Party A):
Contractor (Party B):
In order to improve the logistic work of our school, we need to improve the management of socialization, according to the "School Maintenance Project". In order to improve the management of socialization of our school logistics work, according to the "school sporadic maintenance project management approach", in accordance with the "Chinese People's *** and the State Contract Law" and the relevant laws and regulations, combined with the specific circumstances of the project, the campus property sporadic maintenance by Party B to undertake the two sides negotiated to reach the following agreement.
Article I Project Overview
1.1 Project Name:
1.2 Project Location: School
1.3 Contracting Mode: Party B contracted materials
1.4 Duration: the project since the signing of the contract was completed before the end of the month.
1.5 Project quality: qualified.
1.6 Contract price (RMB): capital (￥ )
Article II Party A work
2.1 3 days before the commencement of work, to Party B on-site briefing. Provide Party B with water, electricity, gas and telecommunication equipment required for construction, and explain the precautions for use.
2.2 Assigned as Party A's representative at the site, responsible for contract fulfillment. Supervise and inspect the quality and progress of the project, and handle acceptance, change, registration formalities and other matters.
2.3 If it is determined that there is a need to demolish or change the structure of the original building or equipment pipelines, it is responsible for the relevant departments for the appropriate approval procedures.
Article 3 Responsibilities of Party B:
3.1 Quality of the project: Party B shall strengthen the quality control measures and management in the construction to ensure that the quality of the project reaches the qualified level.
3.2 Labor safety: Party B shall strengthen the labor management and labor education of the construction site personnel, pay attention to labor safety, and do a good job of the construction site fire prevention, anti-theft, anti-electricity, etc., and shall not arbitrarily destroy the construction site of the safety enclosure, such as the occurrence of work-related injuries or accidents, Party B is responsible for its own. At the same time, Party B construction personnel must obey and comply with the relevant provisions of Party A's management and rules and regulations.
3.3 civilized construction: material stacking and on-site construction should be subject to Party A's management, so that the material stacked neatly, standardized, construction site to ensure that the work is done site clear; to keep the construction site clean and smooth. Construction site is strictly prohibited fighting, brawling, drinking before work is strictly prohibited, the violation of the responsibility of the person will be heavily penalized, the penalty will be deducted directly from the project.
3.4 Finished product protection: Party B should strengthen the protection of finished products, not only to prevent the finished product is destroyed by others, but also to prevent the destruction of other people's finished products. Party B's own finished products, destroyed by Party B responsible for their own; Party B damage to other people's finished products, losses borne by Party B, the cost of losses deducted from the project.
3.5 Responsible for the protection of the surrounding buildings and decoration, equipment, pipelines, green space, etc. from damage, or should bear the corresponding costs.
3.6 Cooperate with the relevant departments to do a good job in site defense, fire fighting, garbage disposal and removal, etc., and bear the costs.
3.7 Insurance and all accidents such as injuries and deaths during the construction period shall be borne by Party B, and all expenses incurred shall be fully paid by Party B.
3.8 All the work shall be carried out by Party B, and all expenses shall be paid by Party B.
3.6 Assigned as Party B's representative at the site, responsible for contract fulfillment. Organize the construction according to the requirements, complete the construction tasks with good quality, quantity and on schedule, and solve the matters which Party B is responsible for.
Article 4 Work Schedule Agreement
4.1 Party A shall obtain Party B's consent and pay for the cost of measures taken by Party B due to the hurrying up of the work when Party A requests to complete the work earlier than the `work schedule' agreed in the contract.
4.2 If the work period is affected because Party A fails to complete the work as agreed, the work period shall be postponed.
Article V Project Quality and Acceptance Standards
5.1 The project is based on construction drawings, practice notes, design changes and the "Construction and Acceptance Specification for Building Decoration Engineering" (JGJ73-91), "Building and Installation Engineering Quality Inspection and Evaluation Consent Criteria" (GBJ300-88) and other nationally designated construction and acceptance norms for the assessment and acceptance criteria for quality.
5.2 The quality of the project has reached the national quality assessment standards.
5.3 Party A and Party B shall handle the inspection and acceptance procedures of concealed works and intermediate works in time. Party A does not attend the hidden works and intermediate works acceptance on time, Party B can acceptance, Party A should be recognized. If Party A requests for re-inspection, Party B shall handle re-inspection according to the requirements. If the re-inspection is qualified, Party A shall bear the costs, resulting in work stoppage, the extension of the work period; if the re-inspection fails, the re-inspection and rework costs borne by Party B, but the extension of the work period.
5.4 Quality accidents caused by Party B, the rework costs borne by Party B, the construction period will not be postponed.
5.5 After the completion of the project, Party B shall notify Party A of the acceptance, and Party A shall inform Party B of the acceptance time within 7 days from the receipt of the acceptance notice, and the acceptance shall be completed within fifteen working days in principle, but due to Party A's reasons, more than fifteen working days to set a different date for the acceptance, Party A shall recognize the date of completion and bear the caretaker's fees and related costs of Party B.
Article VI.
Article VI Settlement of Project Payment
6.1 The two sides agreed that the price of this contract shall be the price approved by the government-appointed appraisal company with appraisal qualification for the maintenance of the project.
Article VII Quality Guarantee Period
The warranty period of this project is 1 year. Warranty period, the project due to natural forces and other subjective and objective factors such as loosening, detachment and other phenomena, Party B needs to be within 2 days to the scene of free maintenance.
Article VIII Payment
8.1 After acceptance of the project, the operator to fill out the "School Contract Class Payment Approval Form", in accordance with the relevant provisions and attached all relevant materials, after approval at each level, the school finance to pay Party B to the contract price of 90% of the contract amount;
8.2 10% of the settlement price to stay in the quality of the project quality assurance deposit, to be the expiration of the warranty period without quality problems. Bidder to return the project quality deposit (no interest).
8.3 Within 45 days after the acceptance of the project, the two sides to complete the settlement and complete the payment in accordance with the provisions of 8.1, 8.2.
Article 9 Material Supply Agreement
9.1 Materials purchased by Party B shall be qualified products that meet the requirements of the project and comply with relevant national standards.
9.2 All materials purchased by Party B shall be prohibited to be used if they do not meet the quality requirements or there are differences in specifications. If it has been used, all the losses caused to the project shall be borne by Party B.
Article 10 Safety and Fire Protection Agreement
10.1 The construction drawings or practice notes provided by Party A shall be in accordance with the "Regulations on Fire Protection of the People's Republic of China*** and the State of China" and the relevant fire protection design codes.
10.2 Party B shall strictly observe the Safety Technical Regulations for Construction and Installation Works, Safety Operation Regulations for Construction and Installation Workers, Regulations of the People's Republic of China on Fire Protection and other relevant regulations and norms during the construction period. As Party B violates the relevant safety operation regulations and fire safety regulations during the construction and production process, resulting in safety or fire accidents, Party B will bear all the economic losses caused by this.
Article 11 - Liability for breach of contract
11.1 Party B shall pay Party A 5% liquidated damages for each day of late completion due to Party B's reasons.
11.2 Party B shall properly protect the equipment provided by Party A and the furniture, furnishings and finished products piled up at the site, and shall compensate for any loss caused.
11.3 Party A has not carried out any formalities, unauthorized consent to the demolition of the original building structure or equipment pipelines, the resulting loss or accident (including fines), Party A is responsible for and bear the loss.
11.4 Without the consent of Party A, Party B unauthorized demolition of the original building structure or equipment pipeline, the resulting losses or accidents (including fines), Party B is responsible for and bear the losses.
11.5 Without acceptance procedures, Party A use in advance or unauthorized use, resulting in loss of Party A is responsible for.
11.6 Due to one party's reasons, the contract can not continue to perform, should notify the other party, for contract termination agreement, and the responsible party to compensate the other party for the resulting economic losses.
Article 12 Dispute or Dispute Handling
12.1 In case of disputes between the two parties during the period of fulfillment of this contract, the two parties may settle the disputes through consultation or ask the relevant departments to mediate without affecting the progress of the project.
12.2 Settlement of contractual disputes: disputes occurring during the performance of this contract shall be resolved through consultation between the two parties; they may also be conciliated by the local industrial and commercial administrative departments; if the consultation or conciliation fails, they shall be resolved in accordance with the following (2) way.
(1) submitted to the School Economic Arbitration Commission arbitration;
(2) according to law to the people's court where the construction project.
Article 13 Other Agreements
13.1 Party B shall always pay attention to the construction safety in this construction, and at the same time, try to avoid generating a lot of noise in the campus, so as not to affect the normal study and personal safety of students.
13.2 Party B will strictly follow the construction procedures, and each procedure must be accepted by Party A before constructing the next procedure, so as to ensure the quality of the project.
13.3 During the construction, Party A shall notify Party B in time if there is any change in the project.
13.4 If Party A fails to notify you in time, Party A will bear the economic loss of Party B for rework of the completed works.
13.5 Attach the list of projects.
Article 14 Other outstanding matters, the two sides in line with the principle of equality, voluntariness, fairness, honesty, credit, negotiation and settlement.
Article 15 The qualification documents for Party B's on-campus services are an integral part of this contract, and the qualification documents shall prevail over any unspecified contents of this contract.
Article 16 This Agreement shall be executed in triplicate, with two copies for Party A and one copy for Party B.
The contract shall be signed in accordance with the terms and conditions of the contract.
The contracting party (Party A): school (seal) Contractor: (seal) Legal representative: Legal representative:
Manager: Manager:
Contact phone number: Contact phone number:
Year Month Day Year Month Day
2022 School Maintenance Contract 3
(hereinafter referred to as Party A)
(hereinafter referred to as Party B)
a, project profile
1, project name: Hutang Street, a street of commerce and road maintenance
2, the project location: Hutang Street, Hutang Village
2, the scope of the project contract: this project is the scope of the construction drawings package package materials, once a Package fixed.
Third, the duration of the project: from - October 30 to - November 30.
Fourth, the quality of the project and technical requirements:
The project is in strict accordance with the specifications of the construction drawings, the quality must be qualified and above.
V. Settlement and payment of the project
The project for the contract price (capitals): ten thousand four hundred seventy-eight hundred eighty-one dollars, RMB: 14781.00 yuan, the project is completed and accepted as a one-time payment.
Six, this contract in duplicate, the two sides each take one, since the two sides signed and sealed after the entry into force, the two sides *** with the trust.
Party A (official seal): --------- Party B (official seal): ---------
Legal representative (signature): --------- Legal representative (signature): ---------
--------- ---- ---- --------- --------- ---- ---- Day
2022 School Maintenance Project Contract 4
Party A:
Party B:
By the friendship and consultation between Party A and Party B, in line with the principle of fairness and impartiality, Party B undertakes the renovation of Party A's Yuping Ziqi Mountain Farmer's Market, the specific matters are as follows:
A. Construction content: by the Party A designated projects for construction.
Second, the amount of construction work: farmers market:
1, stainless steel electric rolling door project (manual 1, electric 3);
2, glass partition wall project (with 12mm toughened glass, woodworking panels, including imitation ceramic, stainless steel compression strips, etc. production);
3, the canopy, walls, and columns of the imitation ceramic project;
4, lamps and lanterns with Energy-saving lamps;
5, stainless steel electric door with a special line (4mm2 Yudie brand steel core);
6, power lines to the ground square (4mm2 white pay sets of wires made of lead core);
7, brick masonry glass footing;
8, carpenter's boards wrapped plumbing columns and include imitation ceramic materials;
9, replacement of damaged sewerage works;
10, cleanup, cleaning up, and the columns of imitation ceramic material;
10, clean up, and the wall, and the columns of imitation ceramic works;
11, clean-up and the wall of imitation ceramic works. p>
10, clean up the sewer project.
Third, the way to undertake: by party B to take the form of package materials, party B in the construction process, such as party A has changed the content, must be negotiated by the two sides to solve.
Fourth, the project cost: three hundred and ten thousand one hundred and eighty yuan (￥: 3618000.00 yuan) dry.
Fifth, quality assurance: Party B strictly in accordance with Party A agreed to the project construction, quality and quantity.
VI, the date of commencement of work: the month of January, the completion date: the month of January.
VII, safety: safety accidents in the construction process by Party B. Eight, the deposit: the date of the contract, Party B to Party A to play the deposit of 20,000 yuan, delivered to Party A, the project started and completed within six months after Party A to return the deposit (20,000 yuan) to Party B.
Nine, the payment method: the progress of the project to pay the project to Party B, every ten days to pay once, the first December 28th allocation of 100,000 yuan, the completion of the project Party A need to pay Party B project payment of three hundred and fifty thousand one hundred and eighty dollars, the rest of the project by the acceptance of the Party A six months after the quality of the problem does not occur when the one-time payment to the Party.
X. Liability for breach of contract: (duration of 40 days) Party B does not finish on time, overdue one day fine of one thousand yuan, one day in advance of the reward of one thousand yuan, Party A does not pay the project on time, resulting in the project can not be completed on time, Party A is solely responsible.
XI, the two sides to negotiate separately, the contract in quadruplicate, A, B, both sides of the two copies, the above content of the two sides to sign the date of entry into force.
Party A (official seal): --------- Party B (official seal): ---------
Legal representative (signature): --------- Legal representative (signature): ---------
--------- year ---- month ---- day --------- year ---- month ---- Day
2022 School Maintenance Contract 5
Contractor (Party A): University
Contractor (Party B):
In accordance with the "Chinese People's Republic of China*** and the State of the Contract Law" and the provisions of the relevant laws, regulations, and combined with the specific circumstances of the project, the two sides reached the following agreement.
Article I. Overview of the project
1.1 Name of the project:
1.2 Location of the project: University
1.3 Contracting method: Party B contracted the work
1.4 Duration: the project is completed before the day of the month of the year from the signing of the contract.
1.5 Project quality: qualified.
1.6 Contract price (RMB): capital (￥ )
Article II Party A work
2.1 3 days before the commencement of work, to Party B on-site briefing. Provide Party B with water, electricity, gas and telecommunication equipment required for construction, and explain the precautions for use.
2.2 Assigned as Party A's representative at the site, responsible for contract fulfillment. Supervise and inspect the quality and progress of the project, and handle acceptance, change, registration procedures and other matters. Involving economic visas, need to be in accordance with the requirements of the relevant provisions of the University for approval procedures.
2.3 If it is determined that there is a need to dismantle or alter the original building structure or equipment pipelines, it is responsible for going to the relevant departments for the appropriate approval procedures.
Article 3 Responsibilities of Party B:
3.1 Quality of the project: Party B should strengthen the quality control measures and management during construction to ensure that the quality of the project reaches the qualified level.
3.2 Labor safety: Party B shall strengthen the labor management and labor education of the construction site personnel, pay attention to labor safety, do a good job in the construction site fire prevention, anti-theft, anti-electricity, etc., and shall not arbitrarily destroy the safety enclosure facilities of the construction site, such as the occurrence of work-related injuries or accidents, Party B is responsible for its own. At the same time, Party B construction personnel must obey and comply with the relevant provisions of Party A's management and rules and regulations.
3.3 civilized construction: material stacking and on-site construction should be subject to Party A's management, so that the material stacking neat, standardized, construction site to ensure that the work is done site clear; to keep the construction site clean, smooth. Construction site is strictly prohibited fighting, brawling, drinking before work is strictly prohibited, the violation of the responsibility of the person will be heavily penalized, the penalty will be deducted directly from the project.
3.4 Finished product protection: Party B should strengthen the protection of finished products, not only to prevent the finished product is destroyed by others, but also to prevent the destruction of other people's finished products. Party B's own finished products, destroyed by Party B responsible for their own; Party B damage to other people's finished products, losses borne by Party B, the cost of losses deducted from the project.
3.5 Responsible for the protection of the surrounding buildings and decoration, equipment, pipelines, green space, etc. from damage, or should bear the corresponding costs.
3.6 Cooperate with the relevant departments to do a good job in site defense, fire fighting, garbage disposal and removal, etc., and bear the costs.
3.7 Insurance and all accidents such as injuries and deaths occurring during the construction of the project shall be borne by Party B, and all expenses incurred shall be fully paid by Party B.
3.6 Assigned as Party B's representative at the site, responsible for contract fulfillment. Organize the construction according to the requirements, complete the construction tasks with good quality, quantity and on schedule, and solve the matters which Party B is responsible for.
Article 4 Work Schedule Agreement
4.1 Party A shall obtain Party B's consent and pay for the cost of measures taken by Party B due to hurrying up the work when Party A requests to complete the project earlier than the contracted work schedule.
4.2 If Party A fails to complete the work as agreed and affects the construction period, the construction period shall be postponed.
Article V Project Quality and Acceptance Standards
5.1 The project is based on the construction drawings, practice notes, design changes and the "construction and acceptance specification for building decoration works" (jgj73-91), "building and installation project quality inspection and evaluation of consent standards" (gbj300-88) and other nationally designated construction and acceptance specifications for the quality assessment acceptance standards.
5.2 The quality of the project has reached the national quality assessment of qualified standards.
5.3 Party A and Party B shall handle the inspection and acceptance procedures of concealed works and intermediate works in time. Party A does not attend the hidden works and intermediate works acceptance on time, Party B can acceptance, Party A should be recognized. If Party A requests for re-inspection, Party B shall handle re-inspection according to the requirements. If the re-inspection is qualified, Party A shall bear the costs, resulting in work stoppage, the extension of the work period; if the re-inspection fails, the re-inspection and rework costs borne by Party B, but the extension of the work period.
5.4 Quality accidents caused by Party B, the rework costs borne by Party B, the construction period will not be postponed.
5.5 After the completion of the project, Party B shall notify Party A of the acceptance, Party A since the acceptance of the notice received by Party B, another date for acceptance. However, Party A shall recognize the date of completion and bear the caretaker's fee and related expenses of Party B.
Article 6 Settlement of Project Payment
6.1 The two sides agreed to adopt the price of the contract (2);
(1) fixed price.
(2) Awarded price (including bidding risk) + economic visa. The change part is finalized according to the actual amount of work incurred. Involving economic visas, approval procedures are required in accordance with the requirements of the relevant University regulations.
(3) adjustable price; calculate the cost in accordance with the relevant state engineering pricing regulations, adjustments and completion settlement in accordance with the relevant provisions.
6.2 project settlement using the quota: 20 years of "the national unified construction engineering foundation quota Anhui Province comprehensive valuation table Hefei area comprehensive price list" (second edition), 1999 "Anhui Province, decorative engineering comprehensive valuation table Hefei area price list", "the national unified installation engineering budget quota 20 Anhui Province valuation table". Material prices using the year month - city construction engineering market price information.
6.3 Fees standard: according to the four categories of fees.
Article VII Quality Guarantee Period
The project warranty period of 1 year. Warranty period, the project due to natural forces and other subjective and objective factors such as loosening, detachment and other phenomena, Party B needs to be within 2 days to the scene of free maintenance.
Article 8 Payment
8.1 After the acceptance of the project, the contract amount of 70% of the contract price will be paid to the successful bidder;
8..2 95% of the final price will be paid after the audit by the university audit department and the issuance of the settlement report, and at the same time, the performance bond will be refunded (without interest).
8..2 5% of the settlement price is set aside for the quality deposit of the project. Upon expiry of the warranty period without any quality problem, the bidder will refund the quality deposit of the project (without interest).
Article 9 Material Supply Agreement
9.1 The materials purchased by Party B shall be qualified products that meet the requirements of the project and comply with relevant national standards.
9.2 All materials purchased by Party B shall be prohibited to be used if they do not meet the quality requirements or if there are differences in specifications. If it has been used, all the losses caused to the project shall be borne by Party B.
Article 10 Safety and Fire Protection Agreement
10.1 The construction drawings or practice notes provided by Party A shall conform to the "Regulations on Fire Protection of the People's Republic of China*** and the State" and the relevant fire protection design norms.
10.2 Party B shall strictly abide by the Safety Technical Regulations for Construction and Installation Works, Safety Operation Regulations for Construction and Installation Workers, Fire Protection Regulations of the People's Republic of China and other relevant regulations and norms during the construction period. As Party B violates the relevant safety operation regulations and fire regulations during the construction and production process, resulting in safety or fire accidents, Party B bears all the economic losses arising therefrom.
Article 11 - Liability for breach of contract
11.1 Party B shall pay Party A 5% liquidated damages for each day of late completion due to Party B's reasons.
11.2 Party B shall properly protect the equipment provided by Party A and the furniture, furnishings and finished products piled up at the site, and shall compensate for any loss caused.
11.3 Party A has not carried out any formalities, unauthorized consent to the demolition of the original building structure or equipment pipeline, the resulting loss or accident (including fines), Party A is responsible for and bear the loss.
11.4 Without the consent of Party A, Party B unauthorized demolition of the original building structure or equipment pipeline, the resulting losses or accidents (including fines), Party B is responsible for and bear the losses.
11.5 Without acceptance procedures, Party A use in advance or unauthorized use, resulting in loss of Party A is responsible for.
11.6 Due to one party's reasons, the contract can not continue to perform, should notify the other party, for contract termination agreement, and the responsible party to compensate the other party for the resulting economic losses.
Article 12 Dispute or Dispute Handling
12.1 In case of disputes between the two parties during the period of fulfillment of this contract, the two parties may settle the disputes through consultation or ask the relevant departments to mediate without affecting the progress of the project.
12.2 Settlement of contractual disputes: disputes occurring during the performance of this contract shall be resolved through consultation between the two parties; they may also be conciliated by the local industrial and commercial administrative departments; if the consultation or conciliation fails, they shall be resolved in accordance with the following (2) way.
(1) submitted to the Hefei Regional Economic Arbitration Commission arbitration;
(2) according to law to the people's court where the construction project.
Article 13 Other Agreements
13.1 Party B should always pay attention to the construction safety in this construction, and at the same time, try to avoid generating a lot of noise in the campus, so as not to affect the normal learning and personal safety of students.
13.2 Party B will strictly follow the construction procedures, and each procedure must be accepted by Party A before constructing the next procedure, so as to ensure the quality of the project.
13.3 During the construction, Party A shall notify Party B in time if there is any change in the project and give economic visa.
13.4 If Party A fails to notify Party B in time for rework of completed works, Party A shall bear Party B's economic loss.
Article 14 Other outstanding matters, the two sides in line with the principle of equality, voluntariness, fairness, honesty, credit, negotiation and settlement.
Article 15 The bidding documents are an integral part of the contract, and the bidding documents of the project shall prevail over any unspecified contents of the contract.
Article 16 This Agreement shall be in one copy, four copies for Party A and two copies for Party B. The contract shall be signed in accordance with the terms and conditions of the contract.
Contractor: University (seal) Contractor: (seal)
Legal representative: Legal representative:
Entrusted agent: Entrusted agent:
Phone: Phone:
Bank of account: Bank of account:
Account No.: Account No.:
20--year month day 20--year month day
★ Sample After-Sales Service Contracts 5 of 2022
★ Personal Renovation Construction Contracts 5 of 2022
★ Simple Maintenance Contracts 5 of 2022 Sample Contracts
★ Formal Maintenance Contracts Generic Templates 5 of 2022
★ Architectural Engineering Construction Contracts 5 of 2022
★ 2022 Formal Maintenance E-Contract Agreement 5 articles