Model earthwork contract 1
Party A (Employer):
Party b 1 (contractor):
Party B 2 (Contractor):
Based on the principles of equality, voluntariness, honesty and credit, Party A and Party B entered into this contract through consultation and strictly performed it in accordance with the Contract Law of People's Republic of China (PRC), Regulations on Construction and Installation Project Contracting and other relevant provisions of Ningxia Hui Autonomous Region.
Article 1 Scope of contracted projects
(1) Project name: demolition, earthwork excavation and backfilling.
(2) Project location:
(3) Scope and content of the project: all attachments on the ground shall be removed, removed, excavated, transported and backfilled.
(four) the total project contract cost:
1. All ground attachments of this project (including all attachments and piles in two buildings and all surrounding bungalows and other sites, etc.). ), the demolition amount is about 8,000 square meters, and the demolition contract price is 80,000 yuan.
2. The unit price of earthwork excavation in this project is per cubic meter 1 1 yuan, and the total price is finally calculated according to the actual excavation amount confirmed by Party A. ..
3. The unit price of earthwork backfilling in this project is per cubic meter 1 1 yuan, and the total price is finally calculated according to the actual backfilling quantity confirmed by Party A. ..
4. The project price in the above-mentioned paragraph 1 ~ 3 is lump sum price (including the costs of removing ground attachments, construction waste, garbage removal, excavation, backfilling, transportation and stacking, and the costs of urban management, municipal administration, environmental protection, sanitation, demolition permit and other relevant departments). ). At the same time, this price includes all expenses such as machinery, fuel and garbage disposal, excluding other expenses.
Article 2 the construction period
Commencement and completion date: The commencement time of the above three projects shall be decided by the director of Party A. Party A shall send the bills and drawings to Party B, and Party B shall complete them on schedule in strict accordance with Party A's requirements.
Article 3. Both sides are responsible for each other.
(1) Party A's responsibilities:
(1) Party A guarantees that the construction land has the legal right to use.
(2) Organize the examination and approval of the construction organization design or scheme, handle the intermediate completion acceptance formalities, be responsible for the visa, supervise the project progress and quality, and organize the completion acceptance.
(3) Pay the project payment according to the contract.
(II) Party B's responsibilities:
(1) Party B shall not subcontract the project.
(2) Carry out the construction in strict accordance with the audited construction drawings, construction specifications and operation procedures, ensure the project quality and progress, and complete it within the time specified by Party A's scheduling ... The plane position, pit bottom size, slope gradient, elevation and bearing stratum of the foundation pit should meet the requirements of the design drawings, and the deviation should be controlled within the allowable range of the construction specifications. Party B must actively assist and cooperate with the general contractor of the project to reserve mm thick soil from the design basement before mechanical excavation. This mm thick soil will be sent by the general contractor to cooperate and transported by excavator. Overexcavation is strictly prohibited.
(3) Ensure to abide by the rules and regulations of the site and Party A's regulations on civilized construction, and obey the command of the site management personnel and the supervision and management of the superior department. The cleanliness of the construction site conforms to the relevant provisions of environmental sanitation management to ensure the smooth progress of road construction.
(4) Organize safe and civilized construction, and Party B shall be responsible for all work-related accidents caused by Party B and safety accidents of other units and personnel ... Before the construction starts, Party B shall do a good job in educating employees of this unit about safety thoughts and safety measures. Personnel without safety education shall not enter the construction site, and make disclosure records. Safety and civilized construction must be done in the construction of the site. Take necessary safety protection measures to eliminate hidden dangers of accidents.
Party B shall abide by the relevant management regulations and safety management system of project construction safety production, strengthen safety education for operators and improve their safety awareness. Implement safety construction rules, construction
Personnel must have the corresponding qualifications, the construction site must have the conditions for safe production, and the construction shall be carried out according to the requirements of mechanical operation. Organize the construction in strict accordance with the safety precautions and safety standards in the technical operation procedures of earthwork construction, and accept the supervision and inspection carried out by industry safety inspectors according to law at any time. Any uncivilized construction behavior (including barbaric construction, disobeying Party A's project management requirements, urinating and defecating everywhere, etc.). ) shall be deemed as breach of contract, and Party A shall pay a penalty of 2,000 yuan for each occurrence. If the construction period is delayed or economic losses are caused, Party A has the right to claim compensation until the contract is terminated. Liquidated damages and fines can be deducted from Party B's project payment.
If Party B has any personnel changes, it shall notify Party A in time. Party B shall bear the relevant responsibilities and expenses for mechanical damage or casualties caused by Party B's ineffective safety measures and illegal operation, and Party A shall not bear any responsibilities.
(4) Provide Party A with the notice of commencement in time, and prepare the construction organization design or scheme, construction progress plan, construction layout, engineering statistics report and engineering accident report.
(6) Demolition and excavation of construction waste shall be transported by Party B, and the stacking place shall be found by Party B (earthwork, gravel and garbage piled on the construction site shall be transported by Party B, and the engineering quantity shall not be calculated). The expenses incurred by dumping garbage and earthwork shall be borne by Party B, which has been included in the contract unit price and will not be calculated separately. If earthwork is needed for the project, Party B shall pile the earthwork to the designated place according to Party A's requirements.
(7) When Party B discovers groundwater or embeds pipelines and cables, it shall promptly notify the person in charge of Party A's construction site and take corresponding measures. If the building foundation and other obstacles cannot be excavated and transported, the person in charge of Party A shall be informed in time.
(8) After Party B's earthwork excavation, it will be qualified only after the design, construction (supervision), quality supervision station and Party A's inspection meet the requirements; Otherwise, you have to bear the cost of renovation and rework yourself.
(9) Party B shall immediately report to Party A the cultural relics and historic sites discovered during the construction.
(1 1) In the process of construction, if any event such as the third party (e.g. the demolished person) obstructs or hinders the construction, Party B shall be responsible for handling and bear the expenses, and Party A shall not bear any expenses.
Article 4 Project Price, Budget and Settlement Measures
(1) Party B shall submit the completion settlement documents to Party A for review within days after the project is completed and accepted.
(2) Party A shall pay off the project payment within the day after completion settlement.
Article 5 Construction and design changes
Party B must adhere to the construction according to the drawings. Party B shall bear the losses caused to Party A, such as rework, overstock of materials and components, relocation of construction forces and machinery, etc. , under the following circumstances:
(a) due to the needs of production and use, when the construction unit requests to change the design, it must obtain the consent of the original design unit and issue a notice of design change. The change can only be made after both parties have gone through the visa formalities.
(2) If there is any mistake or obvious irrationality in the design during the construction, Party B shall notify Party A in written form, and Party A shall negotiate with the original design unit within days, propose to modify or change the design documents, and the construction can only be started after being signed by both parties. ..
(3) In the process of construction, if the design change exceeds the original design standard or scale, and the investment needs to be increased, it should be submitted for approval again according to the examination and approval procedures before the project starts, and the project can only be started after the visas of both parties. Before both parties have issued visas, Party B shall not force the construction without authorization.
(4) In the process of construction, if the construction is stopped or postponed, Party A and Party B shall agree on the reasonable location of the project under construction. And put forward maintenance measures to minimize losses.
Article 6 Project Quality, Completion Acceptance and Warranty
(1) Party B must organize the construction according to the construction drawing and various technical requirements, specifications and regulations, and meet the quality requirements of this project: Party A has passed the acceptance.
(2) After the concealed works are completed and the acceptance records are made, the next working procedure can be started. For general concealed works, Party B shall check and record them by itself; for major or complicated concealed works, Party B shall notify Party A and the design unit in writing days in advance for acceptance and go through the acceptance procedures.
(3) The acceptance of the completed project shall be based on the construction acceptance specifications, quality inspection standards and construction drawings including instructions issued by the state. Party B shall submit the completion report to Party A days in advance, and Party A shall organize the acceptance within the day after receiving the notice. If the acceptance is qualified, Party B shall sign the acceptance certificate and hand it over to Party A within days from the date of signing the acceptance certificate.
(4) When the project is accepted, if it is found that the quality of the project is not in conformity with the regulations, Party B shall be responsible for free repair or rework, and complete it within the measures and time limit agreed by both parties. After the acceptance, the handover. If the delivery of the project is delayed due to this, Party B shall pay Party A a penalty of two thousandths of the contract amount every day.
(5) After the project is completed, Party B shall draw the as-built drawing. If the project changes slightly, Party B shall explain it on the original construction drawing and submit it to Party A. ..
Article 7 Liability for breach of contract and dispute settlement
(1) If Party B fails to complete the project according to the content and date stipulated in this contract (subject to the completion acceptance date), it shall pay Party A RMB/day (times) as penalty for each day overdue. Party B shall evacuate all personnel and equipment from Party A's site within days after the project passes Party A's acceptance (counting from the date of completion acceptance), otherwise, Party A has the right to clean up Party B's relevant personnel and equipment by itself. Party B shall pay a penalty of RMB/day (times) to Party A for each overdue day.
(2) Party A and Party B shall not make an excuse to default on various payables. If it is not paid in time, it shall pay one ten thousandth of the daily penalty to the other party according to relevant regulations.
(3) In case of contract dispute, both parties can settle it through negotiation or mediation. If negotiation or mediation fails, a lawsuit shall be brought to the People's Court of xingqing district, Yinchuan.
Article 8 Supplementary Provisions
(a) the number of copies of the contract and the validity period:
(1) This contract is made in sextuplicate, with each party holding three copies.
(2) This contract shall come into effect as of the date of signature and seal by both parties; After all the projects are completed, accepted and settled.
Automatic termination after final payment.
(2) Supplementary clauses:
1. Party B is responsible for coordinating the expenses incurred by urban management, environmental protection, city appearance, traffic police, road administration and other management departments in the construction process, and Party A will not bear any expenses.
2. If the sand left on the ground is removed by Party B, it will not be included in the total project price, and Party A will not pay any extra fees.
3. After Party A organizes the completion acceptance or process acceptance, Party B cannot be exempted from the responsibility for quality and compensation for losses to Party A or users.
4. During the performance of this contract, if Party B fails to perform its obligations as agreed in this contract and fails to fully perform it within the specified date notified by Party A in writing, Party A has the right to terminate this contract.
Party A: Party B:
Legal representative:
Authorized Agent: Authorized Agent:
Year, month, sun, moon, sun.
Standard earthwork contract 2
Party A:
Party B:
According to the national laws and regulations and the principles stipulated in the Regulations on Contract of Construction and Installation Projects, Party A will contract the earthwork excavation and transportation to the place designated by Party B for construction according to the construction needs, and this contract is signed by both parties through consultation for mutual compliance.
Article 1: Contracted Projects, Contents and Duration:
Carry out excavation and earthwork transportation according to the scope and requirements provided by Party A, including contents: (1) Excavation works include. (2) Party B shall be responsible for fines imposed by relevant units, including soil scattering during excavation and transportation. (3) Obstacles during excavation shall be removed by Party B. ..
Article 2: Contracting method: lump sum (including mechanical import and export fees).
Article 3: Time limit for a project: the excavation starts on, and ends on. Party B must make efforts to complete part of earthwork transportation according to the determined construction period, otherwise, it will be fined 1 000 yuan for each day of delay, and the Qinjiang Town Government will supervise and assess it.
Article 4: Settlement and payment methods:
3 1. contract unit price: according to the actual situation, the earthwork excavation will be transported to the designated place for settlement (including mechanical entrance and exit fees). After the earthwork is buried and compacted by construction machinery, it will be measured by Party A and Party B and confirmed by calculation (the height after landfill and compaction is 3. 14m higher than the existing ground height).
2. According to the actual earthwork contracting workload completed by Party B, Party A will issue a task list by the builder, which will take effect after being reviewed and signed by the management personnel and submitted by the project department manager to the engineering company for review and approval. If the signature is incomplete, the settlement will be invalid
3. Settlement method: Before Party B enters the site, it can start construction by paying 65,438+00% of the total project cost to Party A, 30% of the completed project will be returned to 65,438+00% of the total performance bond, 60% of the completed project will be paid to 40% of the total project cost, 90% of the total project cost will be paid within one month from the project completion acceptance date, and it will be paid within six months from the project acceptance date.
Article 5: Project Quality:
Party B must carry out the construction in strict accordance with the current construction acceptance specifications and design requirements promulgated by the state. And do a good job of self-inspection, mutual inspection and handover inspection to ensure the quality of the project. If Party B fails to carry out the construction according to the construction plan and technical disclosure, resulting in quality accidents, or all economic losses affecting the quality of the project due to improper operation and violation of operating rules, Party B shall bear ... Any engineering, maintenance and warranty expenses contracted by Party B shall not be paid separately.
Article 6: Safety Management:
1. During the construction period, Party B shall establish and improve the safety production responsibility system, safety management organization and guarantee system. The contractor is the first person responsible for Party B's safety production and is fully responsible for safety production.
2. During the construction period, Party B shall prepare a special safety construction plan in combination with the actual project, clarify the responsibilities of safety production management, take safety measures, designate full-time safety management personnel, submit the list of safety personnel to Party A, regularly supervise, inspect and coordinate the contracted civilized construction of safety production, and eliminate the hidden dangers of accidents in time.
3. In the process of construction, Party B must abide by the national safety laws, regulations and industrial safety technical specifications and standards, improve the safety production system, operate in strict accordance with safety technical operating rules, safety technical measures and special safety construction plans, and do a good job in safety education for employees entering the site, safety technical disclosure of teams and groups and safety group activities. When there is a contradiction between safety and production, first implement various protective measures to meet the needs of safety production.
4, adhere to the policy of safety first, prevention first, do a good job in the control of dangerous sources, and in accordance with the provisions, equipped with and correct use of safety protection articles. Personal protective equipment shall be purchased by Party B. ..
5. All personal, mechanical and traffic accidents caused by reasons not attributable to Party A during the construction shall be borne by Party B..
6. During the construction period, casualties caused by illegal operation, illegal command, violation of labor discipline and improper use of safety protection articles shall be reported to the competent department of the enterprise immediately according to relevant regulations. Party A has the obligation to assist in the rescue and actively cooperate with the government and relevant departments in the investigation and handling of the accident. All economic expenses and losses such as medical expenses, living expenses, subsidies and pensions shall be borne by the party responsible for the accident. If a serious accident constitutes a crime, legal responsibility shall be investigated in accordance with relevant laws and regulations.
Article 7: Rights and obligations of Party A:
(1) Rights:
1. Supervise and inspect the progress, quality, safe production, civilized construction and site management of Party B's construction according to the standards issued by the Ministry. If the contracted project is delayed, the quality is poor or Party B takes risks in violation of regulations due to Party B's poor management, Party A shall instruct Party B to make corrections within a time limit. If Party B does not obey the supervision and command of Party A's management personnel, Party A has the right to hold Party B accountable, and all economic losses caused thereby shall be borne by Party B..
2. According to relevant national laws and regulations and enterprise rules and regulations, Party A has the right to punish Party B's illegal behavior in the construction process or terminate the contract.
3. During the contract period, if Party A discovers that Party B's employees have stolen construction facilities and materials, they will be fined twice, which will be deducted from Party B's settlement. If the case constitutes a crime, it will be handed over to the public security organ for criminal responsibility according to law.
(2) Obligations:
1. Provide and create construction conditions for Party B. ..
2. Assist Party B to solve specific problems in construction in time.
Article 8: Responsibilities, Rights and Obligations of Party B:
(1) Responsibilities:
1, fully responsible for the management of technology, quality, safe production and civilized construction in the whole process of subcontracting construction projects within the scope of the contract.
2. Establish and improve the safety production responsibility system and safety management organization, and the contractor is solely responsible for the safety production management of the contracting team.
3, formulate safety management system, preventive measures and emergency measures, adhere to the people-oriented, do a good job in employee safety training and education and special operations related certificates.
4, equipped with full-time production safety supervision and inspection personnel, responsible for the contractor's production safety civilization construction management and supervision and inspection.
5, safety accident frequency control within 2‰, put an end to serious injury and death accidents.
(2) Rights:
1, have the right to refuse illegal command and force risky operation.
2. Have the right to propose behaviors that endanger life safety and personal health.
(3) Obligations:
1. Before signing this contract, Party B shall voluntarily submit the business license, enterprise qualification and valid documents to Party A for review, and keep one copy for Party A's file.
2, in strict accordance with the safety operation procedures and norms of construction, in the process of subcontracting construction, care for safety facilities shall not be arbitrarily removed mobile safety protection facilities and safety signs. No child workers or disabled people shall be used, and no old workers over 50 shall be used for special operations.
3. Fully perform the contents of the contract, obey the leadership and command of Party A, conscientiously implement the management system and unified arrangement of Party A's construction site, ensure safe production and civilized construction, and complete the construction tasks in the subcontract with good quality and quantity on schedule.
Article 9: Others:
1. This contract is made in quadruplicate, three for Party A and one for Party B. ..
2. For matters not covered in this contract, both parties shall negotiate and sign a supplementary contract in time, and the supplementary contract shall have the same effect as this contract.
Party A:
Party B:
On behalf of:
Year month day:
Standard Earthwork Contract 3
Employer:
Contractor:
According to the Contract Law of People's Republic of China (PRC) and relevant laws and regulations, in order to clarify the rights, obligations and responsibilities of both parties in the project contracting and ensure the comprehensive completion of the project tasks, Party A and Party B sign this contract on the principle of voluntariness, equality and mutual benefit through consultation.
I. Overview of the Project
(1) Project name: Earth and stone works for expansion of Shankannongji, Zongzhen Town, Jialing District, Nanchong City.
(II) Project Location: Kannongji Mountain, Zongzhen Town, Jialing District, Nanchong City.
(3) Project content: earthwork excavation, transportation and backfilling.
(4) Engineering quantity: The total excavation volume is about 40,000 cubic meters.
Second, the construction period
Commencement date: the construction period is YY to YY.
Party B has fully considered the environmental impact, road conditions, vehicle transportation, management, construction inspection, policy changes and all factors that may affect the construction progress during the construction period. In addition to force majeure factors such as natural disasters, if there are other factors, the construction period will not be adjusted. After the contract comes into effect, Party B will actively organize machinery to enter the site and start construction within 3 days.
Third, the project quality
1, the project quality should reach the first level of national quality inspection and evaluation standards.
2. Party B shall carry out the construction according to the drawings and materials provided by Party A to ensure the project quality. When the project is accepted, it shall be accepted according to the measured quantities (subject to the settlement of GPS grid data).
Fourth, the project price and settlement
(1) Comprehensive unit price:
1. Comprehensive unit price: 8.8 yuan /m3. This project adopts the comprehensive unit price lump sum based on the excavation quantity, including earthwork excavation, slag transportation, loading fee, site leveling, sanitation fee and other related expenses. Both parties shall not change the contract price without authorization. (If there is any change in other geological conditions, such as hard rock or bluestone, Party A and Party B shall settle it through negotiation. )
2. This comprehensive unit price is the amount of spoil in the place designated by Party A (if it exceeds the designated transportation scope, the project cost will be increased, which shall be settled by both parties through negotiation. )
3. This price has included the cost of price changes and policy price adjustment factors, as well as overtime expenses incurred according to the contract time limit requirements and related time limit instructions.
(two) the project settlement shall be handled in the following ways:
1. The quantities in this contract are tentative quantities, which will be used as the basis for final settlement after being signed and sealed by both parties. If the drawings and instructions provided by Party A are inconsistent with the actual situation, the settlement shall be made according to the actual visa or actual engineering quantity.
2. Before entering the construction site, Party B shall provide Party A with the list of site management personnel and the construction organization plan, and the construction can only be started after Party A agrees.
3. Party B shall seriously abide by the requirements of design drawings and specifications and the instructions issued by Party A according to this contract, and accept the inspection and inspection of Party A at any time. If the project quality fails to meet the agreed standards, Party B shall unconditionally rebuild the project, and the expenses shall be borne by Party B. ..
(III) Settlement of project price
After the project is completed and accepted by Party A, Party A shall pay all the settlement project funds to Party B within 3 working days.
(4) Payment method of the project price: bank transfer payment or cash.
Five, the way of project contracting
(1) This project is subject to general construction contract. Party B shall not subcontract the works agreed in this contract to other construction units for construction. After the project starts, if Party B fails to perform the contract, Party A has the right to terminate the contract, and all consequences arising therefrom shall be borne by Party B. ..
(2) Party B shall abandon the soil in the designated spoil ground as agreed in the contract, and shall not transport the earthwork outside for any reason without Party A's consent, otherwise, Party B shall pay Party A a fine of 65,438+00 times the amount of earthwork transported every time, and not less than 5,000 yuan.
The responsibility of both sides of intransitive verbs
(I) Party A's responsibilities
1. Provide Party B with the backfill scope and elevation marks of the construction site.
2. Party A shall send representatives to the construction site for technical and quality supervision and inspection, handle relevant construction visas and acceptance procedures, and solve problems that should be solved by Party A;
3. If Party B's construction machinery and transport vehicles are delayed or stopped due to Party A's reasons, Party A shall be responsible for the stop and shift fees and the corresponding actual losses. (If farmers and relevant law enforcement departments stop working due to coordination, Party A shall be responsible. )
4. Engineering change: Party A shall notify Party B in writing 7 days in advance and sign a supplementary contract or re-apply for a construction visa. Otherwise, the economic losses caused thereby shall be borne by Party A, and the construction period shall be postponed accordingly.
5. After the project is completed and Party B's written application is received, Party A shall organize a special person to conduct acceptance within 3 days, and shall not shirk it for any reason.
6. Party A has the right to ask Party B to dismiss any member of Party B whose ability or behavior is no longer competent for the work related to this project.
7. Other work agreed by both parties to be completed by Party A. ..
(II) Party B's responsibilities
1, provide relevant information and documents required for site construction, and prove that it has the ability to undertake relevant information of engineering qualification. And provide Party A with the project schedule, corresponding statistical statements and accident reports.
2. Obey the unified dispatching management of Party A, implement the technical quality instructions issued by Party A, organize the construction according to the design drawings, construction scheme and requirements of this contract approved by Party A, and ensure that the undertaken projects are completed according to the contract time limit and quality requirements.
3. Safe construction
(1) Party B shall strictly implement the safety operation regulations, provide necessary safety education and technical disclosure to the personnel entering the site, and abide by the safety production rules and regulations formulated by Party A. ..
(2) Party B shall do a good job in the safety protection of the operation area, and provide sufficient safety labor protection articles such as safety helmets, rubber shoes, safety belts and safety shoes for the on-site operators to protect the personal safety of the operators.
(3) Responsible for the safety protection of the construction area, formulate corresponding construction safety measures, and bear the economic losses and responsibilities caused by poor safety protection measures. Party B must carry out the construction in strict accordance with the construction safety operation regulations and set warning signs as required; Party B shall be responsible for the safety of its own personnel. All personal injuries and property losses caused by Party B to pedestrians, passing vehicles and the surrounding people shall be handled by Party B, and Party B shall bear corresponding responsibilities and expenses. Personal injury caused by Party B to a third party shall be borne by Party B. ..
4. Party B shall take effective measures to protect underground pipelines, adjacent buildings, public facilities and landscaping facilities on the construction site. In case of any damage, Party B shall promptly repair and compensate. If Party B fails to repair or compensate in time, Party A will repair or compensate as required by the other party, and all expenses will be deducted from Party B's project payment;
5. Before the completed project is delivered to Party A, Party B shall be responsible for the protection of finished products, and if there is any loss, Party B shall be responsible for the repair at its own expense; Party B shall strengthen the management of its own machinery, equipment, materials and materials, and be responsible for any loss or damage.
6, civilized construction, ensure the construction site clean and tidy. During the construction period, you must obey the municipal city management and bear the losses and fines caused by violating the relevant regulations.
7. All construction personnel must strictly abide by the relevant provisions of the construction site and formulate corresponding internal management measures. Party B shall bear all consequences arising from violation of the regulations.
8. Party B must closely cooperate and coordinate with the project management personnel. If Party B fails to submit the application for material supply plan in time or the expenses such as loss, loss and secondary handling caused by improper stacking of materials shall be borne by Party B. ..
9. Party A shall be responsible for coordinating local mass relations involving material transportation and employment, and bear all expenses arising therefrom.
Seven. responsibility for breach of contract
(1) Party A breaches the contract.
In other cases where Party A terminates the contract without reason or fails to perform its obligations as agreed in the contract, Party A shall bear the liability for breach of contract, compensate for the economic losses caused to Party B due to its breach of contract, and pay 20% of the total project amount to Party B, and the delayed construction period shall be postponed accordingly.
(2) Party B breaches the contract
1. If the project quality fails to meet the quality standards agreed in this contract due to Party B's reasons, Party A has the right to require Party B to rework. If Party B still fails to meet the quality standards agreed in this contract after re-construction within the time limit specified by Party A, Party A has the right to terminate the contract unilaterally, so the completed project will not be settled, and Party B shall pay 20% of the total project price to Party A as liquidated damages.
2. In other cases where Party B fails to perform its contractual obligations or fails to perform its obligations as agreed in the contract, Party B shall bear the liability for breach of contract, compensate Party A for the economic losses caused by its breach of contract, and pay Party A a penalty of 5% of the total project price. If Party B still fails to perform the contractual obligations or fails to perform the contractual obligations after being urged by Party A, Party A has the right to unilaterally terminate the contract, and the completed project will not be settled, and Party B shall pay Party A a penalty of 5% of the total project price.
3. When one party breaches the contract and the other party requests the breaching party to continue to perform the contract, the breaching party shall continue to perform the contract after assuming the above liabilities for breach of contract;
4. Project termination: Party B's continuous stoppage for more than 5 days due to force majeure shall be deemed as project termination. Party A shall calculate the project price according to the actually accepted project, deduct 5% from the qualified project price as a fine, and terminate the contract. Where losses are caused to Party A from this, Party B shall bear them.
6. Party B must arrange specific personnel to be stationed at the construction site for a long time. If Party B is absent from the construction site for three consecutive days or fails to serve this project, it will be fined 65,438+0,000 yuan per day.
Eight. dispute over a contract
All disputes arising from the performance of this contract shall be settled by both parties through consultation on the premise of not affecting the normal progress of the project. If negotiation fails, both parties agree to solve the problem step by step in the following ways.
1, mediation;
2. Bring a lawsuit to the People's Court of Jialing District, Nanchong City according to law.
Nine. any other business
(1) This contract shall come into effect after being signed and sealed by both parties, and shall automatically become invalid after the obligations of both parties are fulfilled.
(II) If there are matters not covered in this contract, both parties may sign a supplementary agreement separately according to the specific circumstances.
(3) This contract is made in quadruplicate, with the same legal effect, with Party A holding two copies and Party B holding two copies.
Party A (seal) and Party B (seal)
Legal representative (signature) Legal representative (signature)
Date of signing the contract: year month day.
Contract signing place:
Detailed version of earthwork contract template related articles:
★ Model earthwork contract
★ Standard Edition of Earthwork Contract
★ Earthwork Contract Agreement
★ Earthwork Contract Agreement
★ Model earthwork contract
★ Model earthwork contract agreement
★ Earthwork contract sample
★ Earthwork Contract Template (2)
★ 3 Model earthwork contract.
★ Model essay on earthwork contract