Factory contracting cooperation agreement sample (General 5)
In the real society, the frequency of the use of the agreement is on the rise, the signing of the agreement is the best specification of the rights and obligations between the two parties or several parties. Then how to write a letter of agreement in order to play its biggest role? The following is I help you organize the factory contracting cooperation agreement model (general 5), for your reference, I hope to help friends in need.
Factory Contracting Cooperation Agreement 1
Issuing unit (hereinafter referred to as Party A):
Contractor (hereinafter referred to as Party B):
In order to promote the internal reform of the enterprise under the new situation, improve productivity and enhance the competitiveness of the enterprise, the two sides in the lawful, fair, equal and voluntary, mutually beneficial, consensual, honest and trustworthy based on the party A agreed to the
First, the principle of contracting
1, this agreement in line with the principle of benefit *** enjoy, risk *** share, in the form of contracted production to determine the contracting party, contractors, employees, the three parties of the rights, responsibilities and benefits of the relationship, and according to the agreement on the distribution of benefits and risk bearing.
2, contracting period, Party A provides Party B with all the production resources and capital investment (all materials payable by Party A on behalf of the payment, without the consent of Party A, Party B shall not pay cash), Party B is responsible for the production management and implementation of the completion of the production goals.
3, the contract period of the workshop ownership, administrative affiliation and tax, financial and other channels remain unchanged.
Second, the duration and project of the contract
1, the contract period of this agreement is 1 year, that is, from February 22, ____ to December 31, ____.
2, the main items of contracting: Party B contracting the workshop (including but not limited to), employee wages, the cost of raw materials and auxiliary materials required to produce products, office expenses and rent of sites and rent, and other costs necessary for the operation of all production.
3, during the contracting period, Party B shall not privately purchase equipment, scrap equipment, and shall not arbitrarily develop supply vendors.
Three, profit distribution and risk-taking
1, A and B profit distribution: 80% of Party A's profits, 20% of Party B's profits.
2, Party B's profits settled once a month, Party A monthly advance on Party B's salary, the remaining part of the profit dividend in May of the following year, a one-time payment.
3, the medical costs of work injuries and customer claims due to delivery or quality and other reasons by the A and B parties **** with the same commitment, Party A 40%, Party B 60%. In the production process for various reasons caused by the replenishment costs borne by Party B, such as delivery and quality and other reasons lead to changes in the order or canceled, the two sides in accordance with the actual situation to determine the responsibility.
Four, A and B rights and obligations
(a) the rights and obligations of Party B
1, Party B on the supervisor of the following employees have the right to appoint or remove personnel, supervisors above the right to suggest employees.
2, Party B has the right not to violate the rules and regulations formulated by Party A under the reward and punishment, dismissal of disciplinary employees.
3, Party B's existing workshop staff, the right to mobilize and use their own.
4, Party B must be on time to complete the quality and quantity of Party A contracted production tasks.
5, contracting period, Party B shall accept Party A's administrative management, cost control, quality assurance, production planning and other projects for performance assessment, assessment of the specific implementation of the program separately.
6, contracting period, Party B should ensure that Party A provides the plant, equipment in good condition, all the man-made damage, Party B is responsible for the maintenance costs or at the original price of compensation.
7, consciously abide by Party A's factory rules and regulations, accept Party A and the supervision of employees, respect and protect the democratic rights of employees, listen to the views and suggestions of employees.
(B) the rights and obligations of Party A
1, Party A has the right to the provisions of the agreement to Party B issued production tasks, and supervise Party B on time, quality and quantity to complete the case of failure to complete the corresponding penalties.
2, Party A has the right to Party B's administrative system implementation, cost control, quality assurance, production indicators to achieve the performance assessment, such as failure to achieve the indicators required by Party A, Party A has the right to deduct the corresponding profit from the rate of Party B ____%.
3, Party A has the right to Party B financial supervision, audit and product quality inspection.
4, Party A has the right to maintain the legitimate rights and interests of employees in accordance with national laws and regulations, factory rules and regulations and the provisions of this Agreement.
Party B must advance the purchase of raw materials, auxiliary production materials, office supplies during the period of contracting costs (advances from the benefits of income deducted back to Party A).
5, Party A should be in accordance with the company's "payroll system" issued to Party B monthly wages.
6, shall not violate the provisions of this Agreement, interfere with the rights of Party B. And in accordance with the provisions of the Agreement to protect the Party B. And in accordance with the provisions of the agreement to protect the rights and interests of the party.
V. Contractor's internal distribution of benefits
Article 1 Contractor's internal distribution of profit: refers to the net profit after deducting all kinds of abnormal expenses from the profit earned by Party B.
The contractors shall be responsible for the management and administration of the business, and shall not interfere with Party B's rights and interests.
Six, the agreement change, cancel or terminate
1, this agreement after the entry into force of the legally binding, A and B shall not be changed or canceled at will. This agreement needs to be changed or canceled, the two sides shall reach a new written agreement by consensus, in the new written agreement has not been reached, this agreement is still valid.
2, Party B due to mismanagement or serious errors in decision-making, causing significant losses to Party A, Party A has the right to terminate the agreement, not liable for breach of contract.
3. If Party A violates the provisions of this agreement and interferes with Party B's production and management activities, so that Party B's production and management activities can not be carried out normally or Party B's. legitimate income can not be guaranteed, Party B will be entitled to terminate the agreement without breach of contract. Party B has the right to terminate this agreement and request Party A to bear the responsibility of breach of contract if Party B's legitimate income is not guaranteed.
4, the contract period specified in this agreement, the rights and obligations of Party A and Party B to fulfill the completion of this agreement will be terminated.
VII. Liability for breach of contract
1, Party A violates the provisions of the agreement, shall bear the responsibility for breach of contract, causing economic losses to Party B, compensation for direct losses, and deducted from Party A's profits ____% as liquidated damages.
2. If Party B violates the provisions of the agreement, it shall bear the responsibility of breach of contract and deduct ____% from Party B's profit as compensation for breach of contract.
3, the expiration of the agreement, Party B can not according to the quality of the equipment and other property provided by Party A, Party B shall compensate for the lack of or damage to the value of the number of losses, and from the profits of Party B deducted ____% as liquidated damages.
Eight, bylaws
1, after the expiration of this agreement, such as Party A still have to contract, Party B in the performance of this agreement in good condition, Party A shall give priority to Party B to renew the contract.
2. If either party needs to renew or terminate the agreement, it should propose to the other party 3 months before the expiration of the agreement. Within 3 months after the expiration of the agreement, Party A shall pay Party B the profits to which it is entitled during the contracting period.
3.
4. This agreement shall come into effect after it is signed by the representatives of Party A and Party B. The original copy shall be in duplicate. The original in duplicate, Party A and Party B each sign a copy.
Party A: (Signature) Party B Representative: (Signature)
____ Year ____ Month ____ Day
Factory Contracting Cooperation Agreement 2Party A:
Residence:
Contact:
Unified Social Credit Code:
Opening Bank and Account Number:
Legal Representative
Party B:
Residence:
Contact:
Unified social credit code:
Account bank and account number:
Legal representative:
Party A and Party B, after friendly consultation, on Party A's cleaning and sanitation work contracted to Party B, to reach the following unanimous agreement in order to capitalize on the *** with the observance of:
Party A and Party B have reached the following unanimous agreement on the contracting of Party A's cleaning and sanitation work to Party B, in order to capitalize on the observance of: < /p> First, the scope of cleaning Party A throughout the company's factory cleaning area, mainly including the factory road, the administrative building, the factory office, packaging room, warehouse and other areas. Second, the responsibility and obligation 1, Party A's responsibility and obligation (1) assigned ____ a person responsible for assisting Party B cleaning work. (2) Provide water and electricity necessary for cleaning work. (3) Provide a house for Party B to do daily cleaning machinery and supplies storage. (4) Payment of the contractor's fee on time. 2. Party B's Responsibilities and Obligations (1) Assign ____ skilled cleaners to perform cleaning work in Party A's factory. (2) Provide management, safety education and skill training to the cleaners, pay wages and social insurance premiums. (3) is responsible for the provision of cleaning work required mechanical equipment, supplies and maintenance (including hand sanitizer, toilet paper and cleaning bags), cleaning supplies should be in line with national or industry environmental standards. (4) is responsible for all cleaning projects in this contract cleaning technology and management. (5) Party A due to other activities or work, the need for Party B obligation to do cleaning work to assist, Party B agreed to Party A's requirements to complete. Third, the contracting money 1, the cleaning work contracting money for the monthly RMB ____ yuan (lowercase: ￥ ____), a year total of RMB yuan (lowercase: ￥ ____), the above contracting money, including the wages of the cleaner, cleaning tools, supplies, taxes and other costs. 2, in view of the two sides of the original administrative building cleaning contract has been in ____ ____ month ____ expiration, the two sides of the friendly negotiation, Party A administrative building in ____ ____ month cleaning contract payment according to the RMB ____ yuan (lowercase ￥), since the date of the two sides of the cleaning contract according to the contract agreement. Fourth, the deposit l, Party A delayed payment to Party B of one month's cleaning contracting payment of RMB ____ yuan (lowercase: ￥ ____) as a security deposit, and retained by Party A. 2. Party B agrees that Party A has the right to use the deposit directly for one of the following cases. (1) due to Party B's staff fault, resulting in Party A's doors, windows, glass, lamps, air conditioning, computers, vehicles, water pipes, wires and other office facilities and mechanical equipment damage, loss and other losses; (2) due to Party B's staff fault, resulting in damage to vehicles of outsiders, items, loss, resulting in Party A to pay, compensation, advances; (3) due to the Party B employee Occurrence of work-related injuries, or Party B's employees causing physical injuries to Party A's employees or outsiders, Party B is not responsible for, resulting in Party A's payment, compensation and advancement of medical expenses; (4) Due to Party B's or its employees' violation of laws, regulations or discipline, and they are punished or prosecuted, or there is a legal dispute with the third party, resulting in Party A's payment, compensation and advancement of all the expenses; (5) Due to Party B's non-performance of the obligations of this contract or fulfillment of the obligations of this contract, Party B will not be liable to the employees. fulfill the obligations of this contract, or the fulfillment of the obligations of this contract is not in accordance with the agreement, resulting in Party A commissioning a third party to perform the cleaning work and all the costs incurred. 3. If the deposit is insufficient for Party A to pay, compensate or advance the expenses for Party B, Party B shall pay, compensate or advance the insufficient part of the expenses by itself. 4, the validity of this contract expires, the two sides agreed to renew the contract, if the deposit has not been offset for the payment of the costs of this treaty, the deposit will continue to be retained by Party A; if the deposit has been offset partially or completely for the payment of the costs of this treaty, the deposit will be replenished by Party B to the full amount of ____ yuan (lowercase: ____ ￥), and continue to be retained by Party B in the Party A. 5. If both parties perform this contract to the expiration of the term, or by mutual consensus, or the emergence of legal reasons, must be early termination, termination of this contract, in this contract is canceled, terminated within ____ days after the Party A one-time return the remaining deposit to Party B. Party B is not required to pay all the fees stipulated in this contract. V. Payment 1. Party A will pay Party B the previous month's deposit by bank transfer on the first ____ day of each month. 2, Party B designated the name of the head of household, account bank, bank account number changes, withdrawal and other matters, should promptly notify Party A in writing, and Party B reconfirmed the name of the head of household, account bank, bank account number shall prevail. 3, Party A will be contracted to remit money to the bank account designated by Party B that Party A has fulfilled its payment obligations, due to the bank or Party A's fault, resulting in the rent can not be drawn, acceptance, or delay in drawing, Party A is not responsible. 4. Before ____ of each month, Party B shall provide Party A with the legal and valid official invoice and reminder of the previous month's rent, as the settlement proof. Sixth, acceptance 1, by Party A to appoint a person every ____ week to Party B that week's cleaning work acceptance. 2, acceptance criteria: Party A's cleaning requirements shall prevail. VII, the contract change, cancel 1, change the content of this contract or have the end of the matter, by the two sides to solve the problem by negotiation or sign a supplementary agreement. 2, either party to terminate this contract, must be ____ days in advance to the other party in writing, the two sides agreed to terminate. Eight, the responsibility for breach of contract 1, such as Party B cleaning does not meet the acceptance criteria, Party B agreed to rework without compensation until it meets the acceptance criteria. If Party B rework still can not meet the acceptance criteria, Party A has the right to deduct the month of the contract as liquidated damages, and has the right to arrange for other cleaners to complete the cleaning work, the resulting costs borne by Party B. If Party B refuses to rework the work, Party A will not be able to meet the acceptance criteria. If Party B refuses to rework, Party A has the right to refuse to pay the month's contract. 2. If Party B's property is damaged due to the fault of Party B's cleaner, Party B will compensate unconditionally. 3. If Party A does not pay the monthly contracting fee on time for more than ____ days without justifiable reasons, Party A will pay interest to Party B at the same period of the bank loan interest rate from the first ____ days to the payment date. 4, without the agreement of both parties, either party unilaterally terminate the contract, shall pay the other party ____ times of the monthly contracting fee as liquidated damages. IX, dispute resolution A, B disputes in the performance of the contract, should be resolved by way of friendly consultation, the negotiated settlement fails, either party may be to the people's court with jurisdiction. X. Validity period 1, this contract is valid for ____ years (from ____ year ____ month ____ to ____ year ____ month ____ date) 2, in the validity of this contract in the first ____ months for the probationary period, in the probationary period, such as Party B cleaning quality Failure to meet Party A's standards, Party A has the right to unilaterally terminate this contract at any time. XI, this contract is a ____ copy, A and B each of the ____ copies, each with the same legal effect. Party A: Party B: Legal Representative: Legal Representative: ____ Year ____ Month ____ Day ____ Year ____ Month ____ Day Location: Location: Party A: Party B: (owner) The two sides agreed by Party B to bring their own small four-wheeled van with a license plate number: ____ send a driver, general contracting to rent to Party A for the use of the factory car for the following terms: (Driver's name:) 1, Party A agreed to contract for the rental of a Party B van (package driver) rental period from ____ year ____ month ____ to ____ year ____ month ____ day, the probationary period of three months, the contract period if Party A has a request Party B need to replace the driver, Party B need to immediately replace the driver to Party A. 2, Party B with a car and driver, including legal formalities: including vehicles, road maintenance fees, car tax, maintenance fees rented to Party A to use, the monthly rental fee of RMB: yuan whole, vehicle insurance paid annually by Party B; 3, in the rental period of all traffic accidents, violations of traffic laws and economic responsibility borne by Party B; 4, in the rental period, Party A is responsible for public ***** use of the car. Party A is responsible for the public **** car, car expenses, tolls, parking fees according to the actual payment to pay expenses reimbursement; 5, Party B in the contract period of 24 hours a day (at any time to wait for Party A's notice of the use of the car), 365 days a year, can not be used as a private car, in and out of the tank to ensure that the tank of fuel is full, so that the management of the car. Communication costs, food costs paid by Party B, that is, paging that car service. 6, in order to ensure the safety of the Japanese, if Party B midway maintenance or traffic accidents, resulting in Party A no car to use, Party A has the right to terminate this agreement, and lease other vehicles to use, in addition to the driver can not interfere with the operation of the factory work; drivers have illegal behavior Party A immediately notify to Party B; 7, this agreement in duplicate, signed and sealed by representatives of both parties to take effect. Each side of the two sides to implement a copy, have the same legal effect, if there are outstanding matters, through the two sides of the friendly negotiation to solve; Party A: Signed on behalf of the: Party B: Signed on behalf of the: Party A (contracting): Party B (contracting): In order to better To better manage the production workshop opening group, improve production efficiency, improve the utilization rate of sheet metal. By the A and B **** the same consultation, decided to open the material group by party B contracting. In order to clarify the rights and obligations of both parties, this contract is concluded: First, the contracting method Party A will be the right of Party A's production workshop to open the material group contracted to Party B for the Party A processing. Contract period, Party A to provide sites, equipment and production lines; all expenses including raw materials, equipment, supplies, auxiliary materials, water, electricity, equipment maintenance costs are responsible for the payment of Party A, Party B only bear the labor wages. Second, the contract period The contract period for one year, from ____ ____ month ____ day to ______ ____ month ____ day. Third, the price of contracted products Monthly cutting boards _____, guaranteed ______ yuan, exceeding the number of square feet, paid at ____ yuan per square foot. Fourth, Party A's authority: 1, Party A has the right to carry out a variety of administrative management of Party B, such as health, safety and so on. Prohibit smoking in the workshop, to avoid the occurrence of fire, such as the result of accidents, by Party B to cover all losses. 2, Party A has the right to supervise Party B's production environment, labor protection, Party A found that Party B has violations, the right to terminate the contract or give economic sanctions. 3, Party A gives Party B production tasks every day, Party B should be required by Party A quality and quantity, on time to complete the production task, Party A has the right to Party B due to the delay in the delivery of economic penalties, affecting the progress of the production of each delay in the deduction of the Party _____ yuan, caused by the Party A postponement of all the costs borne by the Party. Fifth, Party B's responsibility: 1, Party B in the production and operation, must obey the Party's management, timely completion of the Party's production tasks, according to all the Party's rules and regulations of the production, 2, Party B has the responsibility of Party A to provide the equipment, facilities for regular maintenance, maintenance, abnormalities of equipment should be reported as soon as possible, due to the operation of Party B, the Party's equipment, facilities for the regular maintenance of equipment, facilities, equipment and equipment. Should be reported as soon as possible, due to Party B operating errors caused by equipment damage, the responsibility borne by Party B. 3, Party B must provide the daily production report data to Party A, Party A's accounting department according to Party B's production to account for processing fees. Party B shall not privately undertake outside units, once found, each time deductions and penalties _____ yuan. 4, the personal safety of all the staff of Party B's opening group, such as accidents, by Party B, Party A does not bear any responsibility. 5, Party B shall not subcontract the workshop to others during the contracting period. Sixth, settlement and issuance 1, settlement: Party B will be the month of the production statement to the Party A accounting department, accounting by the Party A accounting department accounting to the Party A financial. 2, issued by the time: the month of processing fees in the third month of the 10th issued to the card of the party B (such as March processing fees, issued on May 10), if encountered on weekends, postponed to the office hours issued 3, the cooperation deposit: processing fees issued, deducted from the processing fee of 10% of the month as a cooperation deposit, the cooperation deposit every six months to send Other matters strong> 7, other matters 1, A and B signed, this contract is not subject to market conditions and any other factors, the contract period, any party unauthorized suspension of the contract (including party B halfway out of the field, etc.), will be dealt with as a breach of contract. 2, the expiration of the contract period whether to renew or terminate the contract, A and B should be 2 months in advance to notify each other 3, such as the two sides of the contract dispute, shall be in the location of Party A's factory that is ____ filed a lawsuit. 4. Matters not yet resolved, by the A and B parties to negotiate a separate solution. 5, this contract in duplicate, A and B each hold a copy of the same legal effect, the signature takes effect and implementation. Party A (seal): Party A representative (signature): Party B (signature): Date of signing Party A: Party B: By the consent of all the partners of the Party A, Party A and Party B in a fair, impartial and friendly consultation, will be all the Shunda stone processing plant. Fixed assets (____ construction and add the amount of all assets, *** counted one million eight hundred thousand yuan) the use of the right to use the right to contract to party B is responsible for the operation, the two sides reached the following agreement: First, the content of the contract Party A in the contract signed on the date of the right of use of the Shunda stone factory fixed assets contracted to party B is responsible for the operation, party B independent operation of self-sufficiency. Party B independent management of its own profit and loss, Party A has no right to interfere. Second, the contract period: The contract period of years, from ____ ____ month ____ day to ____ ____ month ____ day. III. Contracting Amount and Payment Method 1. Contracting Amount: Party B shall pay Party A the contracting amount of ____ Yuan per year. Party B pays Party A a contracting deposit of ____ million dollars. 2. Payment method: Party B pays the contracting amount in the first five days of each quarter. Party B fails to pay the contracting payment on time. B in the failure to pay the money on time, did not delay a day, Party A has the right to Party B to increase the amount owed 1 ℅ of the late fee, more than one month, Party A has the right to stop stop Party B's normal production. Fourth, the responsibility of both parties 1, Party B is responsible for the management of Party A's property during the period of contracting, timely maintenance of property, maintenance, shall not be transferred, sold, shall not be Shunda stone factory assets for any mortgage. If this behavior, Party A has the right to stop, the consequences arising from Party A bear. 2, the expiration of the contract period Party B should ensure that Party A's original equipment can operate normally. 3, such as Party A's original old machine aging Party B can replace the original machine, the cost of Party B. 4, Party A allows Party B in the contracting period, the right to purchase new production equipment, expand productivity, in the contracting period by Party B's equipment by Party B to deal with their own, not discounted against the contract payment. 5, Party B is responsible for the relevant departments during the package collection of various taxes and fees related to production. 6, stone factory procedures are not completed or the relevant departments collected not in the production of other taxes within the scope of mediation between the two sides responsible. 7, contracting period if there is a major incident Party A should be mediated. 8, in the contracting period, all debts and liabilities by Party B to enjoy, bear, and Party A has nothing to do. During the contracting period, Party B should strengthen the management of production safety, and eliminate potential safety hazards in a timely manner, in the event of safety accidents, Party B is solely responsible for, Party A is not responsible for any economic and legal responsibility, but Party A should coordinate the processing. 9, contracting period, such as the relevant departments require the stone factory rectification (such as plant site hardening, workshop noise isolation, the construction of workers' dormitories, office buildings and fences, etc.). Its investment should be funded by Party A, the increase in property for Party A, the amount of investment in five years to increase the Party B contracting (such as rectification of the total investment of one million yuan, then Party B should be increased each year to the Party A contracting amount of two hundred thousand yuan) to increase the right to operate the assets for all of the Party B, during the rectification period, such as the Party can not be produced, then the proportion of the time to reduce the contract payment. V. Other 1, such as national policy adjustments, the government forced to move into the industrial park or manpower irresistible natural hazards, by the partners can cancel the contract. 2, liability for breach of contract: A and B should strictly abide by the contract, Party B contracting, Party A shall not intervene, due to Party A's reasons affecting the normal production and operation of the Party B, Party A should be contracted by the annual contracting amount of ____ ﹪ to pay liquidated damages to the Party B, Party B, such as breach of contract, should be contracted by the annual contracting amount of ____ ﹪ to pay liquidated damages to the Party. 3. The two sides will discuss the outstanding matters of the contract separately. 4, with the A and B representatives and all partners of Party A signed and stamped immediately effective, A and B and Party A partnership each sign a copy. Party A: (seal) Party B: (seal) Date of signing: Date of signing: