Municipal engineering contract model
With the strengthening of people's legal awareness, the frequency of the use of contracts is on the rise, the contract is the best specification of the rights and obligations between the two parties. So what is the common contract book? The following is my collection of municipal engineering contract model, welcome to share.
Municipal Engineering Contract 1
Contractor: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
Party A and Party B based on the principle of "Chinese People's **** and the State Contract Law" and "Regulations on Contracting for Construction and Installation Works", combined with the specific circumstances of the project, the A and Party B fully negotiated the following agreement.
I. Overview of the project:
I. Name of the project:
II. Location of the project:
III. Scale of construction: the amount of work shall be subject to actual acceptance.
Second, the duration: the total duration of days, due to Party A caused by the delay in the construction period, the total duration of its extension.
First, the date of commencement of work: year month
Second, the date of completion: year month
Third, the project contracting:
Fourth, the contracting content
Party A, supervision, design and adjust the recognition of the actual situation. The content of the work.
V. Quality standards:
I. Qualified.
Second, when signing the contract, Party B must pay a quality deposit of yuan to Party A, the completion of the project after acceptance is returned.
Six, the project price settlement and payment:
According to the auditing department of the finalized cost, floating % of the final price for Party B.
VII, the rights and obligations of the two sides:
a. Party A supervise and check the quality of the project, safety, progress and so on, to assist Party B to deal with the problems arising from the construction of the project.
Second, Party A is responsible for assisting in coordinating the demolition and relocation of units along the line of housing, electricity, communications and various underground pipeline network.
Third, Party B needs to strictly according to the construction and acceptance of technical specifications promulgated by the state and the requirements of the design documents in the organization of construction, strict implementation of the State Council (No. 279) "Regulations on the Management of Quality of Construction Works" and other laws and regulations, to ensure that the quality of construction works, progress and safety. Properly record, organize and keep all project-related information, and submit all kinds of reports and project-related information according to the time limit and requirements. Complete the project tasks on time, in accordance with quality and quantity.
Fourth, Party B needs to strictly according to the engineering design documents and Party A's requirements for the organization of the construction, such as the need to change the design, must be agreed by Party A, supervision, design of the three parties before implementation.
Fifth, Party B in the project should be strictly managed, carefully organized, on time to complete the construction tasks, to ensure the quality and progress of construction, the establishment of a sound management system. Organize construction personnel to seriously study the safety of business knowledge and operating procedures, obey the command, civilized construction, barbaric construction is strictly prohibited, shall not be detrimental to the reputation and image of Party A.
VI.
Six, Party B shall accept Party A's supervision and inspection.
VII, Party B strictly implement the hidden works acceptance system, where hidden works are completed, (including all the works) must be Party A, supervision and acceptance of the visa, before entering the next process.
VIII, the project if there is a construction quality problems, Party B is responsible for reworking, the cost borne by Party B.
IX, Party B must conscientiously implement the "Labor Law", on time, full payment of workers' wages, shall not be owed, withholding workers' wages, if any violation, resulting in the full responsibility borne by Party B.
X. Party B is responsible for accidental injury insurance for direct construction workers and bear the cost. Party B is responsible for the safety and casualty accidents on the construction site.
XI, in the construction process, such as Party B damage to the construction scope of the national defense fiber optic cable, telecommunications, post and telecommunications, municipal facilities, etc., are responsible for Party B to restore their own, and Party B to bear all the corresponding responsibility.
XII, Party B from the date of completion and acceptance of the project, the warranty period of years.
VIII, other terms
First, such as the construction of major casualties in addition to pursuing the criminal responsibility of the responsible person, and give economic penalties.
Second, Party A, the project leader of the project phone, the site responsible person: phone.
Third, Party B, the project leader of the project telephone, the person responsible for the scene: telephone.
4.
Fourth, the two sides to negotiate to resolve any outstanding issues.
V. This contract in quadruplicate, A and B each two copies, signed by both parties, stamped and entered into force. After the completion and acceptance of the project, this contract expires.
Party A: Party B:
Project Manager: Project Manager:
Year Month Day Year Month Day
Municipal Engineering Contract 2Contractor (hereinafter referred to as Party A):
Contractor (hereinafter referred to as Party B):
In accordance with the "Chinese People's **** and the State Contract Law" and other relevant laws, regulations, and comply with the equality, Voluntary, fair, good faith principle, Party A will be Su Bei Road, the second section (Maoming Road East - Culture Road West), sidewalks, side stones, flat stones and other projects subcontracted to Party B, in order to ensure the quality of the project and the progress of the clear rights and obligations of Party A and Party B, by the consensus of Party A and Party B, the establishment of the construction contract for both parties to * * * the same Comply with the specific terms of the agreement is as follows:
First, the project overview and scope of the contract
First, the name of the project:
Second, the address of the project:
Third, the scope of the contract: to complete the project sidewalk pavement demolition of the original pavement and garbage out of the city, the pouring of concrete, paving of step bricks, side stone, flat stone laying, The former original asphalt old pavement cutting and other work.
Second, the contracting method
A package of quality, package progress, package safety, package civilization construction, package acceptance, package and other professional cooperation.
Second, the package of all work tools tools and machinery.
Third, the project payment
Project payment:
Party A according to the four payment, the first pavement cutting, demolition and garbage out of the completion of the payment of yuan. The second concrete pouring completed payment of yuan. The third side stone flat stone paving completed payment of yuan. The fourth walkway brick completed payment of yuan. After the completion of the project acceptance, Party A within one week with Party B for the completion of the project settlement, and pay Party B in full all the project funds.
Four, liquidated damages
The two sides especially agreed to pay in case of default default in addition to the provisions of the above to the party in default, the responsibility for breach of contract, but also additional to the party in default to the burden of 10,000 yuan / times of liquidated damages.
Fifth, the contract entered into force
First, the contract fulfillment process if there are disputes, the two sides should be proactive in negotiation to resolve or apply for mediation with the relevant departments, mediation fails to the People's Court of the seat of the project.
Second, the contract in duplicate, A and B each party.
Third, this contract is signed by the person in charge of the two parties, stamped after the entry into force, the completion of the settlement of the project payment is terminated.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ year ____ month ____ day _________ year ____ month ____ Day
Municipal Engineering Contract 3Construction unit (hereinafter referred to as Party A):
Construction unit (hereinafter referred to as Party B):
Party A according to the needs of the project construction of the Renaissance Fortune Project outdoor rainwater and sewage drainage network project entrusted to the construction of Party B, according to the "People's Republic of China **** and the State Law of Contracts" and "Regulations on Contracts for Installation and Contracting of Construction Works" and related provisions, combined with the specific circumstances of the project, the two sides in a spirit of equality and mutual trust. Project specific circumstances, the two sides in line with the principle of equality and mutual benefit, the two sides signed this contract through friendly consultation.
A project overview
1, project name: Renaissance Fude project outdoor rainwater and sewage drainage network project.
2, the project location: Jining City High-tech Zone.
3, project content: Renaissance Fude outdoor rainwater and sewage drainage network project materials procurement, pipe trench excavation, pipe well masonry, pipe laying, pipe pulling, etc. (see the scope of the project contract).
4, the contracting method; package materials, package quality, package construction period, package safety and civilization construction of the general contracting method.
Second, the scope of the project contract
1, the scope of the project contract for the outdoor rainwater and sewage drainage network project construction drawings signed by the Party confirmed the construction content, which:
1.1 construction drawings in the content of the equipment and materials (including manhole covers, pipelines, etc.) purchasing, trench and tube wells excavation, brick masonry wells construction, pipeline paving and installation, tube trench and tube wells backfill and compaction construction, installation of well covers, and other equipment and materials. compaction construction, installation of manhole covers, etc. are within the scope of this project.
1.2 This project does not include indoor piping and outdoor pipe network inspection wells connected and find, building out of sewage wells of cast iron, PVC, PE drain construction is not in the scope of this project, but the cast iron, PVC, PE drain will be synchronized with the construction, Party B should cooperate with the construction.
Third, the contract duration
1, the date of commencement of work: Party A written notice shall prevail.
2. Construction period: the construction period agreed in this contract is 20 calendar days.
3, the extension of the construction period: in the event of major design changes and increase the amount of work, or in the event of irresistible natural disasters, confirmed by the Party visa, to be postponed.
Fourth, the quality of the project
Project quality standards: acceptance of qualified engineering standards. Party B is fully responsible for the quality of the construction project, strictly according to the construction drawings and the current state construction technical specifications and acceptance standards issued by the organization of construction, to ensure that the quality of the project meets the requirements and meet the project quality acceptance standards.
Fifth, the contract price and settlement
1, Party B to complete the contract within the scope of the contract for all the construction content of the total lump sum price of three hundred and twenty-eight thousand yuan (328,000 yuan, including tax).
2. The lump-sum price of this contract includes all the costs of material (equipment) procurement, transportation, packaging, procurement, installation, earth excavator backfill, pipeline laying, pipe well construction, pipe cover installation, safety and technical measures, construction insurance, transportation insurance, management costs, taxes, profits and other costs, and other costs are no longer taken into account.
3, the project to take the lump-sum package, construction drawings within the scope of omission and miscalculation of the offer Party A will not increase the cost.
4, Party B shall submit a settlement report and settlement information to Party A within 10 days after the completion and acceptance of the project, and Party A shall complete the settlement audit within 10 days after receiving the completion and settlement report and settlement information.
Sixth, the project (progress payment) payment
1, Party B materials into the field, Party A according to the total lump sum price of 60% of the progress payment to the project.
2, after the completion of construction to meet the conditions of acceptance, Party A within five days to pay Party B a lump sum of 30% of the lump sum price of the progress payment.
3, acceptance and for the project settlement within three months, Party A to pay Party B to the total amount of 95% of the total amount; the remaining 5% of the total amount of the total amount of money set aside for the project warranty, engineering warranty period expired within five days, Party A one-time return of the remaining warranty without interest. The project agreed warranty period of one year.
4, Party B received Party A's project payment should be provided within three days of the tax project invoice, otherwise Party A has the right to suspend the payment of project progress in the next project payment, resulting in the relevant responsibility of Party B is responsible for.
VII. Responsibilities and obligations of both parties
(a) Party A:
1. Party A shall provide Party B with 3 sets of complete construction design drawings.
2, send the person in charge of the project to supervise the quality and progress of Party B's construction, and handle the project visa.
3, according to the contract agreement and requirements, timely processing of visa, payment, acceptance and settlement.
4, Party A to assist Party B to coordinate the construction site related to the relationship with the unit.
5, the construction found not in line with the construction drawings and specifications of the project quality issues, Party A has the right to order stoppage or rework and timely rectification until it meets the requirements.
(B) Party B:
1, before the construction, do a good job in time to prepare for the construction.
2, strictly in accordance with the contract agreed materials and construction technology construction, and in accordance with the design drawings and specifications for construction, in order to ensure that the project is completed and accepted.
3, before the completion and acceptance of the project, is responsible for the materials, equipment and finished product protection, according to the requirements of civilized construction site to do a good job of construction site cleanliness and sanitation. Construction should protect the project site of the outdoor construction of finished products.
4, the project site installation and management personnel of the office, lodging, dining, etc. are responsible for by Party B itself.
5, to attend the party presided over the site construction coordination meeting, timely implementation of the work requirements of the coordination meeting.
Eight, materials (equipment) procurement and supply
1, the project by Party A procurement and supply of materials (equipment) None. Rainwater and sewage drainage pipes used in this project are used Donghong brand.
2, all check wells in this project using M5 cement mortar masonry environmental cement blocks, the main lane of the district (including fire lanes) are used (OD) 800 * 30 thick B250 cast iron manhole covers, but not the location of the tube well well covers (such as in the greenbelt) are used (OD) 800 * 20 thick cast iron manhole covers.
3, Party B purchased materials (equipment) must be reported to Party A to check and confirm compliance with the design, national standards (industry standards) and government departments issued by the relevant provisions of the requirements before they can be used in the construction of the project. Materials (equipment) must have production certificate, inspection reports and other valid documents, unqualified products are strictly prohibited in this project.
Nine, engineering changes and visas
1, Party A agreed to change the engineering changes in accordance with the changes in the design drawings of construction and visa. All engineering site visas must be signed by Party A to be valid. The visas occurring at the site of the project are based on the unit price agreed in the "Outdoor Rainwater and Sewerage Pipeline Network Project Volume Budget Quotation" (see attached) and the corresponding . The actual quantity of work will be visaed. The unit price of hourly labor days for visas outside the contract is calculated at 130 yuan per labor day.
2, in the event of Party A or force majeure reasons for delay in the work period, Party A will only implement visas for the duration of the work, Party B's construction period can be extended accordingly.
X. Acceptance of the project
1, after the completion of the project, Party B should organize its own acceptance, and do a good job of self-checking and rectification, and apply to Party A for completion and acceptance.
2, Party A in the receipt of Party B acceptance application within three days after the organization of the completion of acceptance. The project is strictly in accordance with the contract for completion and acceptance, if any rectification, the official completion and acceptance for the date of re-inspection.
XI, project quality warranty
1, the warranty scope of the quality of the project for the scope of the project contract for all construction content.
2, quality warranty period:
2.1 quality warranty period from the date of actual completion of the project.
2.2 The quality warranty period of the project is 1 year.
3. The payment and return of quality warranty shall be carried out according to the agreement of paragraph 3 of Article 6 of this contract.
XII, breach of contract and disputes
1, Party B can not be completed according to the contract period (including visa deferred period).
2, such as materials or construction quality does not comply with the contract, Party B is responsible for the specified time to replace and install without compensation, and bear all the resulting economic losses.
3, such as Party A did not pay the project according to the contract, each day of delay in accordance with the project owed payment of 2 to pay liquidated damages.
4, the two sides agreed, in the performance of the contract in the process of dispute, the first consultation to resolve the consultation fails, can be referred to the people's court where the project litigation.
5. Other defaults agreed in this contract shall be implemented according to the relevant agreements in this contract.
13, other
1, this contract is attached to the "outdoor rainwater and sewage network project volume quotes", Party A confirmed construction drawings, and this contract has the same legal effect.
2, this contract, the two sides to resolve any outstanding issues through separate negotiations.
3, the contract in one copy, A and B each two copies, effective from the date of signing, to the warranty period expires after the settlement of the warranty itself terminated.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): _________ Legal representative (signature): _________
_________ year ____ month ____ day _________ year ____ month ____ Day
Municipal Engineering Contract 4Contractor: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
Based on the principle of equality, good faith, mutual benefit, and voluntariness, Party A is now contracting the installation of pipeline network engineering for the municipal landscaping road project of the Canal Core Area of Beibei Ten Mile Hot Spring City of Chongqing Municipality (Phase I) to Party B. Combined with the actual situation of the project, the following agreement was reached through the two parties **** The same consultation, reached the following agreement:
First, the contracting method: Party B package materials, Party A provides accommodation; Party B living expenses). Party B is responsible for all the tools, implements and equipment there (tamping machine, helmet, etc. need to be carried or purchased by Party B sporadic materials, tools), water and electricity costs and pit excavation by Party A is responsible for.
Second, the contract content:
1, sewage inspection wells, rainwater inspection wells construction;
2, by Party A mechanical excavation to the design base, Party B is responsible for pit slagging, tamping (tools provided).
3, Party B to buy their own check well construction of blocks, sand, stone powder, climbing ladder, and provide qualified information on related materials (except well cover, purchased by Party B is responsible for the installation)
Third, the contract unit price and payment:
1, the contract unit price: $ 520.00
(1) the above unit price all contain labor costs, tools, material fee, night overtime fee, various safety and technical measures to deal with the fee, labor insurance fee, material transfer fee. Labor team insurance, medical and pension fees, management fees, taxes. Party A will not bear the cost of material transportation and other costs during the construction.
(2) In addition to large structural changes and wide-ranging architectural changes (each change in the labor cost of more than 2,000 yuan), the rest of the design changes resulting in cost increases or decreases will not be adjusted.
Note: The prices of the above clauses include: all the work content of this contract (all incidental work volume, etc. are implemented in this unit price) and the agreed conditions (including tools, cleaning, etc.), i.e., there is no any hourly labor (except outside the scope of the contract) and the completion of the contract content of the direct costs, indirect costs (such as management fees, profits, labor and insurance costs, various subsidies, taxes, machinery and equipment, safety and civilization of the construction costs, profit, risk, etc.).
2. Payment method:
Fourth, quality requirements
Strictly according to the design drawings, construction specifications, the company's quality standards and related requirements for the operation, a variety of deviations must be within the allowable range. If the increase of Party A's concrete quantity is caused by failure to pass, the loss will be responsible by Party B, and Party A will deduct the actual loss amount in the project payment.
Fifth, safety requirements
1, Party B must comply with the company and project management of the various safety systems, regular workers for safety, legal education, Party A of the violation of the provisions of the system of fines, such as repeated violations of Party A has the right to clean up the field.
2, after entering the field will be the basic situation of the workers list reported to the project department for the record. All the workers must sign a safety responsibility before they can work construction.
3, Party B personnel are strictly prohibited in the construction site fire, smoking and other safety management requirements, violations of the consequences caused by Party B is responsible for.
6, Party B must attend the regular meetings of the project department on time. In the construction process, Party B, regardless of what happens (force majeure factors, and Party A requirements, except) shall not stop work and deliberately delay the schedule. Such as stoppage, Party B has completed the workload of 50% of the amount of Party B to pay the project and the right to clean up the Party B out of the deposit is not refundable; Party B must ensure that the progress of the project required by Party A. If the progress of Party A can not be achieved in the middle of the progress of Party A's requirements, Party A has the right to replace the team, and according to the 80% of the project to pay the project, 50% of the deposit refunded, the Party unconditionally withdrawn from the scene.
7, Party B in the construction process, the occurrence of safety accidents caused by losses and compensation each time within 10,000 yuan by Party B is responsible for its own, which taxes, subsidies, insurance benefits and profits are included in the above unit price, Party B shall not require Party A to pay any other amount for any reason. More than 10,000 yuan by Party A is responsible for 70%, Party B is responsible for 30%.
V. Margin and payment
Party B paid Party A 20,000 yuan to do the deposit when entering the site, the completion of the project by Party A acceptance within 20 days of Party B and pay Party B 80% of the total amount of the project, the balance of the completion of the basic engineering within two months after all paid off.
Six, if the project occurs outside of the above work needs to be completed by Party B sporadic work, Party B should be under the guidance of Party A to actively cooperate with the completion of Party A to open the work order to confirm the amount of work or unit price, must be signed by the project manager, builder, the company designated the person in charge of the site to sign the approval, otherwise the checkout is considered null and void, except in special circumstances.
VII, the duration of the requirements
This project is scheduled to be completed within 88 days.
VIII, A and B responsibilities
(a) A responsibility
1, responsible for the construction site of the coordination between the construction team;
2, to provide the construction work surface and construction technology guidance, instructions, supervision;
3, quality acceptance of the project, safety supervision, inspection, settlement of the amount of work;
4, to provide the construction site Water, electricity and workers accommodation;
5, such as Party B to catch up with the schedule overnight overtime work, Party A is responsible for solving the overtime life.
6, such as Party A reasons or other factors, resulting in water and power outages, the site of Party A signed the recognition of the work period postponed.
(B) Party B's responsibility
1, according to the approved construction program and the instructions issued by Party A to organize labor operations, comply with Party A's rules and regulations, and listen to Party A's construction management personnel of the unified management and reasonable deployment. Participate in the regular meeting of the project department on time.
2, the completion of the labor agreement should be carefully in accordance with the standards, specifications and design requirements and instructions issued by the Party to carry out the work, ready to accept the Party and the departments at all levels of inspection and acceptance, and bear their own reasons for reworking the project, the cost of modification.
3, is responsible for the new workers for production safety education, strictly according to the safe production of operating procedures for the organization of construction, quality and quantity to complete the construction task on schedule.
4, such as Party B default, bear the corresponding responsibility for breach of contract.
Nine, other and breach of contract:
1, Party B, such as not seriously fulfill the terms of the contract, in the process of construction without reason, stopping work, unreasonable or unjustified request for the termination of the contract, the total amount of work completed by Party A to pay Party B 50% of the resulting losses borne by Party B; and the relevant deposit will not be refunded to the Party B.
2, Party B is not a party to the construction of the project, the construction of the project will be completed in a timely manner.
2, Party B must ensure that the number of construction workers in 3 days each hole must be excavated every day, if the hole pile is not excavated for 2 consecutive days, Party A has the right to terminate the contract and do not pay any fees to Party B.
3, Party B will pay 50% of the total amount of completed works.
3, such as Party B delayed construction period by 1000 yuan / day at liquidated damages. (Force majeure factors, and Party A except for reasons)
4, Party B in the construction must be subject to Party A, the construction unit management, the evening of the overtime Party B unconditionally work overtime, do not repeat from the arrangement of Party A penalty 500 yuan - 1000 yuan / time.
5, construction, such as Party B in the site of theft, Party A will be 10 times the value of the stolen materials on Party B for punishment, the serious cases reported to the public security organs.
6, Party B in the receipt of wages, must be in accordance with the relevant financial requirements of Party A to create the appropriate amount of artificial wage table.
7, this contract is not exhaustive, the two sides signed a supplemental agreement to negotiate separately, by the A and B signatures and stamps to take effect.
X. This contract is in duplicate, each party has a copy, after signing the effective settlement of the final payment after the natural lapse.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ year ____ month ____ day _________ year ____ month ____ Day
;