The main right of the contracting party is to inspect and supervise the contractor's production and operation activities; the main obligation is to safeguard the legitimate rights and interests of the contractor in accordance with the provisions of the contract, and to help coordinate and solve the problems of the contractor in the production and operation according to the scope of its joint responsibilities. difficulty. For more contract contract templates, click "Contract Template" to view.
Universal contract agreement template 1
Party A: (referred to as Party A)
Party B: (referred to as Party B)
Party A outsources the plumbing, heating, electricity and fire protection engineering of Project >
Project name: Project Structural form: frame cut.
2. Contracting method: including labor costs, quality, fixed quota of auxiliary materials, construction period, machinery and tools, etc.
3. Project contracting scope:
Contracting scope: water supply and drainage, strong and weak electricity, indoor and outdoor fire protection, and ventilation (see attachment 1 for details of the work content).
4. Project contracting costs and settlement methods:
1. Pricing method:
(1). The pricing unit of this project is calculated based on the building area. After completion Settlement will be based on the actual amount of work completed by Party B (see Appendix 1 for details).
(2) Payment method: Party B will advance funds for three months. After review, Party A will pay 80% of the completed project amount, and then pay 80% of the monthly progress amount. Payment (calculated according to Appendix 2), 95% will be paid after the project is completed and accepted, and 5% will be left as project quality maintenance fund, which will be paid in one lump sum after the warranty is completed within two years.
5. Others:
1. If Party B delays the construction period, the quality of the project does not meet the requirements, and does not obey Party A’s management, Party A has the right to terminate the contract and complete the project 50% of the amount shall be paid to Party B (settlement shall be carried out according to Appendix 2).
2. Party B does not provide relevant qualifications, but needs to pay a qualification fee of 10,000 yuan.
3. Party A is responsible for fire inspection fees and related expenses of the fire department.
4. This agreement is made in duplicate, with Party A and Party B each holding one copy, signed by both parties to the contract.
5. For matters not covered in the contract, both parties shall negotiate and sign a supplementary agreement.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): ________ Legal representative (signature): _________
< p> _________year____month____day_________year____month____dayGeneral version contract agreement template 2
Party A:
Party B:
In accordance with the provisions of the "Contract Law of the People's Republic of China" and relevant laws and regulations, Party A and Party B hereby entrust Party A to Party B for water and electricity installation contract work and materials, After reaching an agreement through negotiation, we sign this contract and agree to abide by it.
Article 1 Entrustment Matters
Due to the needs of project progress, Party A plans to entrust Party B to contract the construction of the water and electricity installation project in the form of package installation, tools and materials.
Article 2 Party B’s work content
1. Cover material loss (loss shall be based on quota).
2. Includes reserved casings, pre-buried water supply pipes, and installation of water supply and drainage materials (excluding the installation of all secondary boosting equipment, air-conditioning condenser pipes and outdoor rainwater pipes.)
< p> 3. Electrical construction work, piles under the electrical cabinet and other projects behind the meter shall be constructed according to the drawings. Lightning protection connection, weak current buried in advance. (Does not include fire-fighting weak current piping and wiring, installation of fluorescent lamps, and installation of other lamps, equipment power, transformers and generator sets, various distribution cabinets, and all meter materials.)4. All For hydropower projects, the outer axis of the building is 1.5 meters as the standard. (Excluding fire protection.
)
Article 3 Construction Period
1. Party B shall organize the construction strictly according to the construction period required by Party A to ensure the smooth realization of the construction period target.
This contract stipulates that the total construction period of this project is days; the start date is: year, month, day, and the completion date is: year, month, day.
2. In case of the following circumstances, the project can be postponed after being approved in writing by the representative of Party A.
(1) Party A cannot provide the conditions for starting construction as agreed in the contract;
(2) Changes in project quantities and design changes;
(3) Reasons not caused by Party B More than 4 hours (including but not limited to) water outage, power outage, etc.;
(4) Project payment not paid on time;
(5) Force majeure (such as earthquake, typhoon, fire) wait).
3. If the construction period is delayed due to Party A’s responsibility, Party A shall pay the delay in work and other additional expenses caused to Party B, and the construction period shall be postponed accordingly.
Article 4 Total Project Cost
Water supply project, electrical project.
The settlement basis is yuan per square meter of building area;
Total price:
The total project area is square meters, and the total project cost is RMB in uppercase yuan and lowercase yuan. .
Article 5 Payment Method
Payment will be made in batches according to different periods of project construction, specifically:
1. Output plus or minus zero and pay the total cost in yuan;
2. For every two floors completed above plus or minus zero, Yuan of the total cost will be paid;
3. The main body is capped, and the amount paid by Party A to Party B shall not be less than RMB 10,000 of the total construction cost;
4. After the water drainage is completed, RMB of the total cost shall be paid;
5. After the wiring installation is completed, RMB of the total cost shall be paid;
6. Upon completion acceptance, the total cost will be paid in RMB 7; the remaining 3%, RMB, is the maintenance warranty deposit, which will be paid upon expiration of the warranty period.
Article 6 Responsibilities and Rights of Both Parties
(1) Party A:
1. Provide water sources, power supply and construction roads on site, provide construction drawings, and dispatch Professional construction workers manage the site and solve project-related problems.
2. Responsible for handling project change procedures and promptly notifying Party B of construction changes.
3. Organize the acceptance of concealed projects at each level, promptly raise existing problems and issue rectification notices, and monitor the quality of the project.
4. Pay the project payment on time according to the contract.
5. Organize the arrival of relevant materials in a timely manner.
6. On the premise that Party B completes the task as scheduled and delivers it to Party A for normal use, Party A must immediately organize completion acceptance to ensure that the work is completed and delivered to the owner for use as scheduled. If Party A has not organized completion acceptance within Party B's completion days, both parties will regard it as acceptance and pay Party B the balance of the project and enter the warranty period of the project.
7. Party A must pay the project payment on a per-node basis. If the project progress is affected because the project payment is not released on time, the construction period will be extended accordingly, and Party A will bear a penalty of 5% of the total daily project payment.
8. After Party B completes Party A's project, Party A must settle the balance in accordance with this contract. If it cannot settle the balance, Party A will not only bear the obligation to pay the balance, but also bear the daily project payment. Liquidated damages of 5% of the total amount.
(2) Party B:
1. Carry out construction according to the design drawings, Party A’s requirements and project progress.
2. Prepare construction plans and construction plans, submit the list of construction personnel and organizational structure table, and attend safety learning and regular engineering meetings on time.
3. Responsible for product protection of completed products. If the damage is intentional by Party B, Party B will be held legally responsible and claim compensation. If the damage is not intentional by Party B, Party B can assist Party A in repairing it, and Party A will only pay the average salary for normal construction.
4. Construction shall be carried out in strict accordance with the relevant construction specifications and mandatory provisions. If it is deemed necessary to make changes to the drawings, a written application shall be submitted to Party A. Otherwise, Party B shall be fully responsible for the consequences.
5. Carry out civilized construction and safe production in accordance with regulations. If Party B intentionally violates regulations and causes safety accidents, including injuries to others, Party B will be responsible for all responsibilities and compensation.
6. Implement the management system of the project department, and Party A will punish Party B for violations according to regulations.
7. Party B guarantees that the modification labor for this project shall be within RMB, and any excess will be subject to visa adjustment.
8. Party B has the right to ensure its own legitimate rights and interests and reasonable requirements, and to object to illegal instructions.
Article 7 Management Measures
1. Workers must wear safety helmets when entering construction sites.
2. All machines and equipment that Party B enters must be registered and handed over to Party A for archiving when entering the site. When the machines and equipment leave the site, Party A’s project manager will open a ticket to release them. Otherwise, they will not be released.
3. Organize new workers to participate in safety learning when entering the site according to regulations.
4. Party A’s personnel are not allowed to be invited for entertainment, banquets, leisure, gifts, etc. without authorization. Violators will be fined 1,000 yuan each time.
Article 8 Quality Responsibility
1. Party B must be familiar with the drawings and must construct strictly according to the drawings, design requirements and relevant construction specifications. Party B's violation of the above requirements will cause economic losses to Party A Party B will be responsible for compensation for any losses incurred during the construction period, and Party B’s employees must take exams to take up their posts.
2. If the acceptance form is 80% excellent, it will be considered excellent, and if it is insufficient, it will be deemed qualified.
Article 9 Safety Responsibilities
1. Party A must purchase accident insurance for the construction crew.
2. If Party B does not purchase accident insurance and causes a work-related injury to Party B’s personnel, Party B must be responsible for all compensation for the work-related injury; if Party A advances expenses for Party B in the accident, it will be included in the future settlement of the project. Relevant expenses will be deducted from Party B’s project payment.
Article 10 Contract Effectiveness and Others
1. Warranty period: One year, calculated from the date of comprehensive acceptance of the building.
2. All disputes arising out of or related to this contract will be resolved through friendly negotiation between the two parties. If the two parties cannot resolve the dispute through friendly negotiation, either party may bring a lawsuit through the people's court with jurisdiction where Party B is located.
4. This contract will come into effect after being signed by representatives of both parties and stamped by Party A. It will be invalid upon completion and expiration of the warranty period. This contract is in two copies, with Party A and Party B each holding one copy, and has the same legal effect.
Party A: Party B:
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): _________ Legal Representative (Signature): _________
_________year____month____day_________year____month____day
General version contract agreement Template 3
Party A: Party B:
In order to promote fruit production, improve land management levels, and increase collective and individual economic income, in accordance with the provisions of superior documents and in a fair, just and reasonable manner In principle, upon negotiation and agreement between Party A and Party B, a local land contract contract is signed with the following terms:
1. Basic information on contracted land
2. Party A contracts acres of land to Party B for management and management . The contract period is years, starting from the year, month, day and ending on the year, month, day.
3. Quantity and time of contracting fee payment:
The contracting fee is RMB per mu, and the contracting fee for the next year must be paid before December 30 of each year.
IV. Rights and Obligations of Party A
1. Party A shall formulate annual management standards and inspection systems in accordance with the requirements of the technical department, and promptly urge Party B to do a good job in land management according to the standards. Work.
2. For those who intentionally damage fruit trees, do not operate and manage them according to the technical requirements of the fruit tree department, or change their uses (such as farming, building factories, etc.), Party A has the right to take it back to the collective and re-contract according to law.
3. Party A will cooperate with relevant departments to conduct irregular inspections of land management every year, and impose certain economic penalties on those who do not manage the land according to the standard requirements or destroy the land in disguise. In serious cases, they will be punished according to the "Forest Law" Relevant provisions impose criminal penalties in accordance with the law.
4. Party A has the right to supervise Party B’s timely fertilization, watering, pesticide application, pruning and other land management work. 5. Party A should actively organize learning and training on new technologies according to Party B’s requirements, and provide information services for Party B to improve fruit tree production.
5. Party B’s rights and obligations
1. Party B shall manage the land in strict accordance with Party A’s standards and strive to improve fruit production and quality. 2. With the consent of Party A, Party B can transfer part or all of the land during the contract period, and the subcontractor must bear all the obligations borne by the original Party B.
3. Party B must obey the state, collective construction project land and other public facilities and other project land, and compensation shall be implemented in accordance with relevant national regulations.
4. After the expiration of the contract, if Party A continues to issue contracts, Party B will have priority in contracting under the same conditions.
6. Liability for breach of contract,
1. Party A shall not arbitrarily change Party B’s land contract rights during the contract period. If there is any violation, Party A shall bear corresponding economic, civil and legal liabilities.
2. During the contract period, if Party B does not manage according to standards or intentionally damages fruit trees, Party B will compensate 100 yuan for each damaged tree, and Party B will replant it in a timely manner. If it is abandoned for a long time or its use is changed, Party A has the right to The party has the right to terminate the contract and contract another one, and the contracting fee paid in advance will not be refunded.
3. After the expiration of the contract, Party B shall compensate Party A 100 yuan for each fruit tree lost. , dry disease rate within 5%, etc.), corresponding economic penalties will be imposed according to the specific circumstances.
7. This contract will not be changed due to the change of Party A’s representative. No party shall terminate the contract or change the content of the contract without authorization, otherwise it will bear legal liability.
8. This contract shall take effect from the date of signing. If there are any unsettled matters, Party A and Party B shall negotiate and make supplementary provisions in accordance with national laws and policies, and submit them to the contract authority for approval before they become effective. The supplementary provisions have the same legal effect as this contract.
9. This contract is made in triplicate. Party A and Party B each hold one copy, and the management station keeps one copy.
10. This contract shall take effect from the date of signing.
Contract issuing party (chapter):
Legal representative: Contractor (chapter):
Year, month and day
General version of the contract Agreement Sample 4
Party A contracts the canteen to Party B for operation and management according to needs. This agreement has been signed through friendly negotiation between Party A and Party B. Party A and Party B agree to abide by and implement it:
1. The parties to the contract
The contract-issuing party: ____________________ (hereinafter referred to as Party A)
The contractor: ____________________ (hereinafter referred to as Party B)
2. Contracting Term
The term is from ______year______month______ to ______year______month______day.
3. Specific content
1. Party A has ______ employees, each of whom has ______ meals every day, breakfast is RMB ______ yuan, and lunch is RMB ______ Yuan Dinner is RMB ______ Yuan, and midnight snack is RMB ______ Yuan. Party B will be provided with meals.
2. Party A provides Party B with kitchen, kitchen utensils, tableware, etc. free of charge.
3. Party A’s General Affairs Department will notify Party B’s canteen supervisor of the number of people eating the next day every day, and Party B will prepare meals according to this number of people.
4. Party A will take inventory before Party B hands over, and Party B will receive the remaining grain, oil, and non-staple foods at a price. When the contract is terminated, Party A must receive Party B's remaining grain, oil, and non-staple foods at a price.
5. Party B prepays Party A's half-month meal expenses. During settlement, Party B will issue a half-month meal schedule and check it with Party A. Party A shall pay the full amount in cash within three days. Party B’s food expenses shall not be in arrears.
6. During the operation period, both parties should cooperate and cooperate with each other in accordance with the terms of the contract. Both parties should not terminate the contract rashly without reason.
IV. Responsibilities of Party A
1. Provide equipment maintenance.
2. Provide accommodation for Party B’s staff, including water, lighting and electricity charges.
3. Party A provides fuel, water and electricity for the kitchen free of charge.
4. Contracting shall not be stopped at will and charging items shall be increased accordingly.
5. Party A must predict the number of people dining in advance. Party A will be responsible for the consequences of any mistakes.
5. Authority of Party A
1. Party A has the right to carry out various administrative management of Party B, such as: health, safety, public security, fire protection, comprehensive management, supervision, etc., especially Food poisoning accidents should be prohibited. Once a similar accident occurs, Party A has the right to hold Party B accountable.
2. If Party B affects Party A’s normal work due to the canteen staff’s negligence (except under special circumstances), Party A has the right to hold Party B accountable.
3. Party A has the right to supervise and inspect the quality, quantity, and health services of the meals. If Party B fails to meet the quality of the meals, Party A has the right to demand appropriate compensation or terminate this agreement.
4. Based on the working conditions of the canteen and the opinions of employees, Party A has the right to adopt other methods for canteen management.
5. When the contractor breaches other obligations, Party A must immediately notify Party B. Party B shall investigate and implement the violation as soon as possible and inform Party A of the results.
6. Unless Party B misses or stops meals due to special circumstances, Party A has the right to impose appropriate financial penalties on Party B.
7. If Party B breaches the contract, Party A has the right to terminate the contract. If Party A suffers losses, it shall be reported to the ______ court or ______ arbitration agency for handling.
6. Party B’s responsibilities
1. Do a good job in accordance with Party A’s fire protection, factory regulations, and public security.
2. Canteen staff shall conduct physical examinations in accordance with the regulations of the health department at their own expense.
3. Regularly conduct rodent and fly control at the business premises.
4. Strictly implement various canteen management systems and implement them in strict accordance with canteen operating procedures and health management systems.
5. It is necessary to ensure the quality of food, control the purchase channels and purchase quality, strictly prohibit the purchase of spoiled and moldy food, ensure the hygiene of meat, ensure food hygiene, internal and environmental hygiene, and withstand The superior department will inspect and pass the inspection.
6. Party B’s staff must wear uniform work clothes and sanitary products and bear their own expenses.
7. Host B must work and rest according to the time specified by Party A, and have meals on time. The meal time shall be stipulated by Party A. If there is any change, Party B shall be notified in advance.
8. Party B’s kitchen staff must abide by Party A’s rules and regulations and are not allowed to enter or leave Party A’s workshop and other restricted areas at will. Party A may impose penalties on violators in accordance with the regulations.
9. Party A’s existing kitchen equipment and tableware shall be used reasonably by Party B, properly kept and strictly managed, and shall not be damaged or lost artificially, otherwise they will be compensated at a discount.
10. The business operation is limited to catering services for the convenience of Party A’s service personnel.
11. Party B is responsible for the material costs during the operation period, and the labor and labor insurance expenses of the required canteen staff.
7. Permissions of Party B
1. Have the right to operate independently and be responsible for its own profits and losses.
2. The right to hire and call staff independently.
3. If Party A breaches the contract, Party B has the right to terminate the contract and report it to the ______ court or ______ arbitration agency.
4. If market prices rise too high, causing Party B to suffer losses for two consecutive months, Party B has the right to ask Party A to increase food expenses. Party A should conduct a market survey as soon as possible. If the situation is true, , food expenses should be increased appropriately.
8. Others
1. When losses are caused by force majeure, Party B will not be responsible for the economic losses of Party A’s properties and facilities.
2. Employees of Party A and Party B should maintain mutual respect and try to avoid friction, let alone fights. If any injuries occur, the unreasonable Party B will be held responsible.
3. During holidays, Party B will serve Party A’s employees as usual. If extra meals are needed, Party B will be responsible for processing, and Party A will buy vegetables or entrust Party B to purchase them.
4. During the contract period, Party B must obtain the consent of Party A before purchasing the kitchen utensils and tableware that belong to Party A and reimburse Party A for reimbursement.
5. At the end of the contract, Party B shall return all the venues, facilities, equipment, tools, etc. provided by Party A to Party A, and cooperate with Party A to complete the liquidation work.
6. When the contract period expires, both Party A and Party B shall notify the other party one month in advance whether to renew or terminate the contract.
7. If there are any outstanding matters in this contract, they will be resolved through negotiation between representatives of both parties.
8. This contract is made in two copies, with each party A and B holding one copy:
Party A’s representative (signature): __________________ Party B’s representative (signature): __________________
p>
Unit (seal): ____________________ Unit (seal): ____________________
Phone: ____________________ Phone: ____________________
Date: ____year____month Date of ____:____month____year____
Universal contract agreement template 5
Contract issuing party: (hereinafter referred to as Party A)
p>
Contractor: ID number (hereinafter referred to as Party B)
In order to clarify responsibilities, protect the rights and interests of both parties, and ensure the smooth progress of production project development and contracting work, according to the specific conditions of this project, This contract is entered into after full consultation and consensus between Party A and Party B. This contract is an expression of the true intention of both parties, and both parties agree to execute it in accordance with the terms of the contract.
1. Project name:
2. Project location:
3. Contract scope:
4. Project content: Cutting , pipe bending, plate bending, integral riveting, welding, cleaning and grinding, shaping, assembly, and the transfer of raw materials, in-process products, and finished products are within the scope of the contract.
5. Contracting method
1. Party A’s contracting form is labor fee (service fee) clear contract.
2. All projects within Party B’s contract scope include labor, construction period, quality, safety, and warranty.
6. Contract price
The final settlement will be based on the number of working hours and the number of batch production delivery units actually approved by both parties. The unit price of working hours is 160 yuan/day. The unit price for delivery of the entire unit is RMB/unit. Labor costs include wages of Party B’s employees, product quality rework costs, transportation and accommodation, insurance, Party B’s management expenses and other expenses specified by both parties.
7. Construction start date and delivery
Construction start date: 20x year month day, the project must be fully produced and qualified to be delivered on 20x year month day. Party B must abide by the stipulated delivery date. If there is a delay or the product is returned due to non-compliance with specifications or poor quality, Party B shall calculate liquidated damages and pay Party A according to the following method.
(1) Within 2 days of the expiration date, Party A will be punished at 1% of the total price of the unpaid portion for each day beyond the due date.
(2) If the payment continues to be overdue for more than 3 days and within 5 days, Party A will be punished by Party A at the rate of 2% of the total price of the unpaid portion.
(3) If the payment continues to be overdue for more than 5 days and within 10 days, Party A will be punished at 3% of the total price of the unpaid portion.
(4) If the payment continues to be overdue for more than 10 days, according to the theory of breach of contract, regardless of the unpaid amount, liquidated damages will be calculated at one time of 5%.
8. Payment method
1. After the production is completed and accepted, settlement will be processed within 30 days, and 80% of the general contract price will be settled. Within 15 days after the settlement is completed, Party A will pay the remaining 15 % of the project payment (it can also be paid simultaneously with Party A’s salary payment to the company’s employees in the next month after passing the acceptance inspection in the current month).
2. The remaining 5% of the warranty shall be paid within 10 days after 60 days from the date when the project is completed and accepted.
3. In principle, no labor cost settlement will occur during the production period. However, since Party B’s personnel do have medical expenses, they can be settled with the consent of Party A’s general manager in advance.
9. Project Quality
The quality of Party B’s products must meet the various qualification standards stipulated by the company. Party B shall produce in strict accordance with the design drawings, company acceptance specifications, and company production plan requirements (excluding trial products). Otherwise, Party B shall bear all the resulting quality problems and liability losses.
If the goods that have passed the inspection are found to be defective when they are reprocessed by Party A or delivered to customers (except those that are obviously wear and tear after reprocessing by Party A), Party A may demand compensation from Party B or return the goods to Party B for reprocessing.
10. Project Progress
During production, Party B shall dispatch labor in strict accordance with Party A's "Production and Employment Plan" and shall not require more working hours for any reason, which will affect the production progress. If non-human-operated equipment malfunction repairs, water and power outages, or production materials not arriving at the factory as planned result in delays in work and time, Party A will verify and adjust the "Production and Employment Plan" only after approval by the general manager.
11. Party A’s work
1. Provide design drawings to Party B before starting work, and Party B shall use and keep them properly.
2. Party A has the right to supervise Party B’s project progress, quality, and production safety during the production process. If the requirements are not met, requests for rectification will be made until they are ordered to leave. Party A will deduct the resulting economic losses from Party B's completed project payment and reserves the right to recover.
3. Responsible for the installation, disassembly, debugging and maintenance of the production equipment provided. If Party B changes the setting of electromechanical equipment without permission or improperly operates it, resulting in a safety accident, Party B will be fully responsible for the liability and economic losses.
12. Party B’s work
1. Party B is responsible for the use and maintenance of the production site equipment and facilities, and reporting equipment failures for repair.
2. If Party A believes that any of Party B’s staff members are seriously incompetent during the production process, affecting product quality and work progress, Party A may request Party B to replace them.
3. Production shall implement a daily report system. Party B shall inform Party A of the production progress, plan completion status, existing problems and today's production plan during working hours every morning.
4. Party B shall be responsible for the protection of the finished and semi-finished products of this project before handover.
5. In order to ensure production quality, Party B should report production difficulties to Party A's company first, and batch production can only be carried out after Party A's confirmation. Otherwise, Party B will be responsible for all the resulting responsibilities.
6. Party B’s management personnel must be on duty full-time during the production period (including preparation and closing stages). Production project managers must be equipped with mobile phones and keep them on 24 hours a day to ensure smooth communication during production (especially in emergencies), and also arrange for holidays and night production duties.
7. The person in charge of production of Party B must attend the production meeting held by Party A, and Party B shall implement all matters decided at the meeting.
8. Garbage, scraps and waste materials generated during Party B’s production process should be cleaned up and transported to the designated location in an organized manner at any time according to Party A’s requirements.
9. After the completion of production, Party B shall be responsible for restoring the equipment and facilities that were artificially damaged due to Party B's fault. If Party B is unable to restore it or fails to restore it within the specified time, Party A will send someone to repair it at a cost of Party B shall bear it.
10. The contract stipulates that Party B completes or provides cooperation with the work (including the content agreed in the meeting). If Party B refuses to complete or cannot complete it as required by the contract, Party A has the right to arrange for other units to complete it. The cost will be deducted from Party B's project payment, and the responsibility for affecting the construction period shall be borne by Party B.
11. After product acceptance, Party B’s personnel and its own equipment and facilities shall be cleaned and evacuated within a day to ensure that the site is cleared and the relevant expenses shall be borne by Party B.
12. Party B is responsible for the organization, deployment and management of the production labor force at its own expense. Party A is not responsible for the wages, social security and other labor relations of Party B's production personnel.
13. Party B shall keep Party A’s business secrets during the execution period of this contract and shall not disclose relevant information to any third party. Party B shall educate its employees to keep Party A's business secrets. If Party A's business secrets are leaked due to Party B's employees, except with Party A's permission, Party B shall bear corresponding legal liability.
13. Supply of materials and equipment
1. Party A is responsible for supplying production materials and production tools. If Party B temporarily needs to purchase materials, it must submit a written submission to Party A in advance and within one day. For materials, both parties A and B must perform strict handover procedures. Party B must designate personnel to count the quantities and fill in the handover list. Party B must sign the designated representative.
2. When Party B uses Party A’s equipment and measuring tools in the production process (excluding scales and natural damage), Party B shall be responsible for repairs and maintenance. Any damage is strictly prohibited. If there is any damage, Party B shall report it to Party A will compensate for the losses and Party A will deduct the amount during settlement.
3. Materials shall not be transported out of the production site without authorization after entering the factory. If found, Party A will impose a fine of double the value of Party B’s materials. In serious cases, they will be sent to the judicial department for processing.
14. Safety in Production
Party B must strengthen management during the production process and take various safety assurance measures in accordance with relevant regulations to ensure production safety. Otherwise, all accidents caused by Party B Party B is responsible for all responsibilities and losses involved in safety accidents. All personnel of Party B must proactively implement the "Safety Equipment Operating Procedures" issued by Party A and participate in safety training organized by Party A.
15. Project handover
Party B shall make rectifications according to the rectification content proposed by Party A within the specified days after product acceptance. After the contract content is completed, Party B shall make rectifications within the specified days according to Party A’s stipulations. If Party B withdraws all production personnel (except those required for closing the project) and fails to complete the handover to Party A within the time limit, it will be deemed that Party B has delayed the construction period and shall bear the liability for breach of contract for delaying the construction period.
16. When Party B’s personnel miss work or stop work due to Party A’s untimely supply of materials, changes in production plans, or reductions in output, Party B shall immediately adjust the part of the personnel (30% to 40%) that will be separated from the workforce. Party A shall organize the work content and pay daily wages for the remaining personnel.
17. Contract Disputes
In the event of losses caused by force majeure, war, natural disasters, etc., they shall be resolved by negotiation between Party A and Party B. If negotiation fails, a lawsuit can be filed with the court where Party A's company is located.
18. Others
This contract is made in two copies. Party A and Party B each hold one copy. It will take effect after being signed by Party A and Party B. The two contracts have the same legal effect. Attached is the "Production and Employment Plan". Matters not covered in the contract shall be resolved separately in writing by both parties based on the actual situation. Party A:
Person in charge:
Contact number:
Date of signing:
Party B: Person in charge: Contact number: Date of signing : Contract Change Agreement
Party A:
Party B:
Party A and Party B follow the principles of legality, fairness, equality, voluntariness, consensus through consultation, and good faith. Agree to make the following changes to the labor clearing contract signed by both parties on the day of the year:
Party A: (Signature) Party B: (Signature)
The day of the year
p>Articles related to the Universal Contracting Contract Agreement Template:
★ Universal Standard Contracting Contract Template
★ Project Contracting Agreement Agreement Template
★ 4 general version templates of project contracting contracts
★ General version templates of project outsourcing contracts
★ Project contract agreement templates
★ Standard version of project contracting contracts Templates
★ 3 general versions of project contract contract templates
★ Contracting contract templates
★ Universal enterprise contract operation contract templates
★ 3 general project contract templates