According to the engineering contract, the construction unit shall complete the construction task assigned by the construction unit, and the construction unit shall provide the necessary conditions and pay the price of the project according to the regulations. Below I bring you the engineering contract model General Edition, more engineering contract model please click " construction contract "view.
Engineering Contract Model General Version 1
Contractor (full name): ____
Contractor (full name): ____
According to the "Chinese People's **** and State Contract Law", "Chinese People's **** and State Construction Law" and other relevant laws, administrative regulations, follow principles of equality, voluntariness, fairness and honesty and credit, the two parties enter into this contract by consensus on the construction matters.
I. Project overview: ___ road hardening project hardening area of about ___ square meters. The project includes road base leveling, cement pavement pouring, etc. The estimated budget is about ___ million yuan.
Second, the contract period: the project in 20___ month ___ before completion.
Third, the quality requirements and rewards and penalties measures:
1, to ensure that qualified (organized by the village committees to invite professionals acceptance), must do safe production, civilized construction.
2, the village of the main road pavement according to the fourth level highway cement concrete pavement standard construction, quality objectives qualified. ① Cement concrete standard C25 standard, plate thickness of 15cm, bending and tensile strength of 4.5Mp or more. ② construction of the main materials should be carried out in the physical properties of the index test, in which the coarse aggregate must be used crushed stone, and in line with the relevant national standards, according to the material indicators and the actual cement grade, select the ratio (cement to have factory certification, quality assurance certificate); test procedures in the construction should be strictly in accordance with the "Highway Engineering Cement Concrete Test Procedures", unqualified materials are not allowed to enter the field of construction. ③The pavement should take anti-skid measures such as transverse pulling or machine pressure groove, and its friction should meet the requirements of the construction specification, and the connection between the pavement and other constructions should be smooth, so that the edge of the pavement is not waterlogged. After concrete paving, it shall be maintained according to the requirements of construction specifications; the appearance of concrete pavement shall be free from diseases such as peeling, marking, cracking, stone exposure and missing edges and corners, etc., and it shall meet the requirements of specifications and technology. ⑤ Project files and test data to send ____ Village Council a copy for inspection.
3, incentives and penalties: the contractor must be strictly in accordance with the relevant norms and standards for construction, to ensure the quality of the project. The quality of the project does not meet the qualified must be unconditionally reworked, bear the rework loss, the warranty period of one year.
Fourth, the project contracting method: the package, the completion of the project settlement based on the contracted price, the contracted unit price for the cement pavement panel thickness of 15CM unit price of 40 yuan/square meter; the amount of work in accordance with the actual settlement.
V. Payment: 50% of the completion of the road hardening project to pay 20% of the contract; full completion of the project, the acceptance of the higher level of funding in place to be paid to the total amount of 90% of the project, and the return of the performance bond; withholding of 10% of the project as a warranty, the warranty is paid in the warranty period expired within 1 month.
Six, the contractor to provide performance guarantee to the contractor, the guarantee is: performance bond of twenty-one million yuan, performance bond in the project after acceptance of the return.
VII, incentives and penalties:
1, the project was completed in 20__ before ___ month ___. In addition to the irresistible factors, the delay of one day penalty of 100 yuan.
2, the contractor shall submit to Party B after the final bidding of the detailed roster of the project management team at the time of bidding for this project, and require the project manager to be on duty no less than 20 days per month. Without prior consent of the Contractor, unauthorized absence from work is found during spot checking in addition to ordering to be on duty, a fine of 100 yuan per person per day. In addition, after the signing of the project contract may not be subcontracted, otherwise it is considered to be abandoned, the performance bond will not be refunded, the project to be re-tendering.
3, the contractor must accept the contractor's supervisor to monitor and accept the corrective comments.
Eight, safety responsibilities:
1, before construction by the contractor is responsible for cleaning up the crops within the scope of construction; the construction period of the relevant policy to deal with disputes is the responsibility of the contractor.
2, the contractor during the construction of blasting operators must be licensed (three members of the three certificates), and do a good job of safety insurance and other related procedures, if the contractor caused by the occurrence of personal safety and driving safety, mass disputes and other large and small accidents, all responsibility and financial compensation are the contractor is responsible for.
IX, the project's bidding documents as an attachment to the signing of the construction contract, the contractor should comply with construction laws, regulations and policies.
X. The project quality warranty responsibilities and obligations in accordance with the State Council on January 20, 2000 issued by the "Regulations on Quality Management of Construction Projects" and other relevant regulations.
XI, this contract in triplicate, the contractor, the contractor each holds a copy of the ___ office archives.
Twelve, the contract enters into force
Contract conclusion time: 20___ years ___ month ___ day
Contract conclusion place: ___
The two sides of this contract agreed to sign and seal the contract comes into force.
Contractor: (official seal)___ Contractor:___
Representative: Residence:
Telephone: Tel:
Sample Engineering Contract Generic 2
I. Name of the Project:
II. Purpose
In order to safeguard the A and B **** the same Interests, to ensure the quality of construction and safe production, to maintain good working order and the construction site of the health environment, by the A and B sides of equal consultation, the signing of this construction safety agreement.
Third, the content of the agreement
(a), Party A production safety management responsibility
1, Party A must strictly implement the national and provincial laws, regulations and norms and standards related to production safety, the development of production safety regulations and operating procedures, the establishment of a sound safety management system, the implementation of the requirements of the safety and technical measures to ensure that the project construction safety production investment. The effective implementation of the construction safety inputs.
2, Party A should provide Party B with the existing technical information required for construction.
3. The design documents provided by Party A should meet the safety and health requirements of construction workers.
4, Party A should be Party B construction site safety supervision and management work into the unit's safety system within the unified management, the development of production safety accident emergency rescue plan must have Party B construction safety content.
5, Party A shall not put forward Party B requirements that do not comply with the laws, regulations and mandatory standards of work safety, and shall not arbitrarily compress the contract period.
6, Party A shall provide rescue and medical facilities for Party B's injured workers.
(B), Party B's responsibility for production safety management
1, Party B shall establish a construction safety system, the implementation of construction safety job responsibility system, the implementation of production safety target management and standardization of construction site operations.
2, Party B should be the project leader by obtaining the appropriate licensing personnel, responsible for the production safety of mining projects, the implementation of production safety regulations and operating procedures, to ensure the effective use of production safety inputs.
3, Party B shall designate the person in charge of on-site construction safety, and the number of safety supervisors shall meet the production requirements and supervise the whole process of on-site construction safety.
4, before the start of the project, adhere to the "one project, one measure, first reported measures after the construction" principle, approved by the competent authorities of Party B construction organization design, operating procedures, safety and technical measures must be reported to the Party for approval after the implementation.
5, Party B shall implement the labor production education and training system, strengthen the unit's production safety education and training of personnel, truthfully inform the workplace and the workplace of the existence of dangerous factors, preventive measures and emergency response to accidents, to ensure that employees are familiar with and strictly implement the relevant rules and regulations on production safety and safety regulations and procedures, to master the post of the safe operation of the skills, with the necessary safety precautions. Knowledge of safety precautions. The special operators shall be given special training by the relevant departments organized by the state, pass the examination and obtain the induction certificate before they are allowed to work on the job. The project department should establish the staff training file, and report to Zhonghe Coal Company and Supervision Company for record.
6, Party B according to their own needs to organize their employees to participate in the construction unit arranged safety education and training and other activities, and bear the relevant costs incurred.
7, Party B must participate in social insurance for work injuries in accordance with the law, and pay insurance premiums for its employees.
8, the construction personnel must wear documents, uniform work clothes, according to the provisions of the correct use of qualified safety protection tools, to prevent the occurrence of object strikes, falling accidents. Construction team safety protection equipment must be configured in place, the safety measures are effective, or not to start operations; construction unit must be the safety production license, project manager qualification certificate, special types of operating certificates in accordance with the requirements of the Party reported to the Department of Safety Supervision for the record.
9, Party B should conscientiously implement the provisions of Party A's safety management, strengthen safety management. If Party B violates the rules or Party A's management regulations, Party A has the right to stop Party B's work, resulting in certain consequences, Party B to pay full responsibility.
10, Party A has the right to carry out inspections at any time, the right to stop illegal operation, the right to violate the safety provisions of the act of punishment or order the construction team to stop work for rectification. The hidden safety hazards identified by Party A shall be rectified and completed within the specified period, and the rectification situation shall be promptly fed back to Party A in writing.
11, Party B shall sign a production safety management agreement with the third party operating in the same operation area or the same production system. If a safety accident occurs, the consequences are borne by the responsible party, and when both parties are responsible, they will bear the corresponding responsibility in terms of the size of the responsibility.
12, in the event of a disaster, Party B personnel, materials, equipment, etc., should unconditionally obey the scheduling, the costs incurred, the accident is dealt with after a separate agreement.
13, strict implementation of the accident reporting system. Party B occurs safety production accidents, in strict accordance with the accident reporting procedures and requirements, in addition to reporting to the unit's higher departments, but also must be timely to the Zhonghe Coal Company report.
14. Other Matters to be resolved through consultation between Party A and Party B.
(C), safety production management responsibility penalties
1, Party B won the bid, in the signing of the contract and the security agreement must pay 20 ~ ___ 0 million yuan as a safety and quality deposit, the safety effect, the quality of the project as an important basis for the acceptance of the project, due to the management responsibility of outsourcing units caused by accidents, quality failure or violation of the relevant provisions of this agreement, in accordance with the provisions of the fines given. The fine is deducted from its safety and quality deposit.
2. Party B will subcontract or subcontract the contracted contract or subcontract or subcontract to a third party in any disguised form, and will be ordered to make corrections within a certain period of time and be fined 50,000 yuan.
3, Party B did not carry out, assess and sign the safety technology measures for construction personnel, ordered to make corrections within a period of time, and imposed a fine of ___ 00 yuan.
4. Party A checks that Party B arranges untrained employees to work in the well, and will give a fine of 5,000 yuan/person.
5, Party B shall follow the requirements of the Special Provisions, there must be a management and technical personnel to lead the shift at the construction site every shift, and empty shifts are strictly prohibited. Found empty shift a fine of 500 yuan.
6, because of Party B management is not in place or because of illegal operation caused by Party B personnel casualties, the responsibility borne by Party B.
The occurrence of minor accidents, party B 20,000 yuan fine;
The occurrence of serious injuries and accidents above the second level of non-personal injuries and deaths, party B to the project part of the management in charge of the person in charge, the person in charge of the direct dismissal and termination of the labor contract sanctions, and at the same time give party B a fine of 100,000 yuan / person;
1 deaths of one person responsible for accidents, party B to give the project manager, responsible for the person in charge of the dismissal and demotion Disposition; at the same time give party B a fine of one million yuan / person.
For a death of 2 people or cumulative death of 2 people responsible for the accident, Party A to give Party B to terminate the construction contract;
7, Party B is responsible for the safety management of other personnel into its operating area, causing casualties to other people, the responsibility borne by Party B, the penalty with Article 5.
8, due to Party A's management is not in place or due to illegal operation caused by Party B personnel casualties, the responsibility is borne by Party A, according to the implementation of the document Zong coal security 20__1.
9, Party B's management and Party A's management have the responsibility and obligation to **** with the implementation of all kinds of rewards and penalties stipulated in the document of Zong coal security 20___ 1.
(D), this agreement in two copies, Party A and Party B, each signing a copy, effective from the date of signing.
Party A (official seal) Party B (official seal)
A method of human representative: legal representative of Party B:
year month day year month day
Engineering Contract Model General Edition 3
Party A: __________ Open Pit Coal Mining
Party B: _____ construction engineering Ltd.
__________ Surface Coal Mining, Stripping Project in the implementation of the construction contract in order to create a safer and more efficient construction environment, and effectively improve the management of the project's production safety, the project owner (_____ Surface Coal Mining) hereinafter referred to as the "Party" and the project Contractor (_____ Construction Engineering Co., Ltd.) hereinafter referred to as "Party B" to renew this production safety contract:
I. Contract period: from _____ _____ to _____ _____.
Second, Party A's responsibility:
1, strictly abide by the state laws and regulations on "production safety", seriously implement the relevant safety requirements in the contracting of the project, the establishment of more than five people and the participation of Party B's production safety management organization.
2, in accordance with the "safety first, prevention first, comprehensive management" principle, adhere to the "management of production must manage the principle of safety" to achieve production and safety at the same time planning, layout, inspection, summary and evaluation.
3, important safety facilities must adhere to the main project with the "three simultaneous" principle, that is, the same time the design, approval, construction, acceptance and put into use.
4, regularly held safety production scheduling meetings, timely convey the spirit of the higher levels of production safety.
5, the organization of Party B construction site safety inspection, supervision of Party B to deal with the timely discovery of a variety of hidden safety hazards.
Third, Party B's responsibilities:
1, strictly abide by national laws and regulations on production safety, machinery operating procedures and other relevant safety regulations, and strictly fulfill the terms of the contract for the contracting of works related to production safety. At the same time, set up a "production safety" leading group.
2, adhere to the "safety first, prevention first, comprehensive management" principle, "management of production must manage safety", to strengthen the safety of production education and publicity, enhance the awareness of production safety. Establish and improve the production safety management system, with full-time safety inspectors, organized and led to carry out production safety education and training. Supervision, inspection, evaluation and other activities. Leaders at all levels, engineers and technicians, safety management personnel and specific operators, must be familiar with and comply with the provisions of this article, production and safety work at the same time planning, layout, inspection, summary and evaluation.
3, the establishment of a sound production safety responsibility system. Strengthen the project manager and production workers (including temporary hired civilian workers) safety production management.
4. Party B shall at all times take all reasonable precautions to prevent its employees from committing any illegal, prohibited, violent or obstructionist acts. During the construction process, if you encounter stormy weather and other inclement weather and can not work, you should be timely evacuated to the premises or a safe place. The driver shall not drive back to the premises.
5, Party B to participate in the construction of the personnel, on duty should be to the local police station for temporary residence permit and other relevant procedures, must accept the safety and technical education, familiar with and comply with the safety and technical procedures of this type of work, regular safety and technical assessment, qualified before being allowed to work. For personnel engaged in electrical, lifting, construction of elevated frame deployment operations, boilers, pressure vessels, welding, motor vehicles and other special types of personnel, must be licensed to work, not after training in professional organizations, did not obtain a safety operation certificate and driver's license, are not allowed to go on duty, the project manager must bear the corresponding management responsibility and safety responsibility.
6, Party B shall strengthen the fire area and production area road fire fighting, attach great importance to the fire area fire safety management, fire accidents bear full responsibility.
7, for flammable and explosive materials should be properly stored by the personnel in charge, equipped with adequate fire-fighting facilities, all construction workers should be familiar with the performance and use of fire-fighting equipment, Party B shall not give any kind of explosive substances, barter or in any other way to transfer to others, and do not allow and tolerate the above behavior occurs under their own noses, and once perceived to stop or report in a timely manner.
8, the operator on duty, must wear protective gear as required. Construction personnel in charge and safety inspectors should wear helmets, night shift personnel must wear night clothes and always check the wearing of labor protective equipment, not in accordance with the provisions of the protective equipment worn by the personnel shall not be on duty.
9, is strictly prohibited to work without a license, is strictly prohibited to go to work after drinking, is strictly prohibited to speed and illegal driving, is strictly prohibited to violate the rules and risky operations.
10, all construction machinery and equipment and equipment working at height should be regularly inspected and have a safety officer's signature record, to ensure that it is often in good condition, and strictly prohibit the use of substandard machinery, equipment and labor protection supplies.
11, Party B must be in accordance with the characteristics of the project, the organization to develop the implementation of the project's safety production accident contingency plan; if a safety accident occurs, in strict accordance with the "State Council on the provisions of the administrative responsibility for large-scale safety accidents," as well as other relevant provisions, and timely report to the relevant departments, and adhere to the "three don't let go! The company is also committed to the principle of "three no spares", and seriously deal with the relevant responsible persons.
12, due to Party B's mismanagement, regardless of mine safety accidents occurring inside and outside the mine, resulting in casualties and loss of property and equipment, Party B is fully responsible for proactively dealing with the aftermath, and bear all the economic compensation responsibility. If Party B mishandles or shirks its responsibility and causes adverse impacts and losses to Party A, Party A has the right to impose economic penalties on Party B until the termination of the contract.
Fourth, the responsibility for breach of contract:
If Party A or Party B breach of contract caused by security accidents, the party in breach of contract to bear the corresponding economic and legal responsibility.
V. Disputes in the course of contract implementation or the contract has not exhausted the two sides to negotiate a solution, the consultation fails to apply for arbitration to the local arbitration institution or to the _____ court litigation.
Six, this contract in quadruplicate, A and B each of the two copies.
Party A: _____ Open Pit Coal Mine Legal Representative: __________ Agent
Agent: __________
Party B (Chapter): _____ Construction Engineering Limited Legal Representative: __________ Agent: __________
Date of contract signing: _____ year _____ month _____ day
Sample Engineering Contract General Edition 4
Construction (contracting) unit: (referred to as Party A)
Construction (contracting) unit: (referred to as Party B)
Party A for the unit, according to the "Chinese People's *** and the State of the Contract Law" of the provisions of. Followed by the two sides in equality, voluntariness, mutual benefit and the principle of good faith, Party A will be the foundation of the Expo project earthworks tasks entrusted to Party B contract, Party A and Party B on the relevant matters of consensus, to enter into this contract, and strictly abide by it.
I. Overview
Project name:
Project location:
II. Scope: ± 0.00 earthworks. (Including mechanical excavation, soil transfer, hollowing out pile joints)
III. Duration
20___ ___ month ___. The total number of calendar days of the contract duration of the work process, in addition to the following circumstances, the work period will not be postponed:
1, resistible force.
2, Party A change of plans, construction drawings and affect the construction.
Fourth, the price of the project and the payment of the project. 13400m3, the comprehensive unit price is calculated according to / cubic meter (the above price includes the construction of the whole earthwork of Party B coordination, abandonment of soil, taxes and all other costs incurred, for a one-time lump sum price, in the construction period, without any adjustment). The end of digging and transportation, after acceptance by Party A, cash settlement payment.
1. After the end of earthwork and acceptance by Party A, Party B shall provide tax invoices recognized by tax authorities for settlement, otherwise, Party A has the right to refuse payment.
V. Quantity: 3400m3.
VI. Quality Requirements
1. In the earth excavation soil (including digging, transferring soil, etc.), all construction processes of Party B must be constructed according to the construction quality requirements of the project department.
2, all construction processes must be qualified by the Party A project department, supervision, construction units and the inspection of the relevant personnel, and the next construction procedures, Party A can sign the approval.
3, in the construction of rework caused by Party B, Party B unconditionally as soon as possible according to Party A's work requirements, causing Party A losses, Party A has the right to demand compensation in accordance with relevant laws and regulations of Party B's right to compensation.
4, Party B must be in 20___ ___ month ___ back to finish the soil, otherwise the daily fine of five thousand yuan.
VII. Party A's responsibility
1. Party A will pay for the project according to the contract.
VIII. Party B's responsibility
1. Obey Party A's supervision, command and management.
2, according to the drawings and Party A's guidance for construction, quality, quantity, and on schedule.
3, safety, civilized construction, to ensure construction safety, before the contract comes into force, Party B shall pay Party A a security risk deposit ____, Party B in the construction process, such as the occurrence of unsafe accidents, resulting in Party A, Party B and the staff of the two sides and the third party injuries, deaths, or property damage, Party B shall bear the full amount of its own. After the completion of the project, if Party B does not occur unsafe construction, Party A will return the security risk deposit ____ paid by Party B in full.
IX. Other terms:
1. Liquidated damages: Party A terminates the contract due to Party A's reasons, Party A pays Party B liquidated damages ____. Termination of the contract due to Party B, Party B pays Party A liquidated damages ____.
2. Party B bears the full responsibility for work-related accidents in construction.
3. If there are any outstanding issues, Party A and Party B can enter into supplementary terms and agreements by consensus, and the supplementary terms and agreements shall have the same legal effect as this contract.
4, dispute resolution, such as disputes between the two sides, A and B should be resolved through consultation, consultation fails to Diaochuan County People's Court to file a lawsuit.
5, this contract shall enter into force from the date of signing, the original contract in duplicate, A and B each party to sign a copy of the two sides shall enter into force after both signatures.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): _________ Legal representative (signature): _________
_________ year ____ month ____ day _________ year ____ month ____ Day
Sample Engineering Contract General Edition 5
Construction unit: (referred to as Party A)
Construction unit: (referred to as Party B)
Party A's existing steel plant project, entrusted to be responsible for the construction of Party B. In order to clarify the division of labor, assist each other, quality and quantity, and to complete the construction task on schedule, through the consultation of both parties, signed the following contract:
Article I, project name:
Article II, project location:
Article III, project profile: plant area of about.
Article 4, the form of contracting and construction basis:
1, the form of contracting: production, installation of plant steel structure.
2, the scope of contracting: steel part: the production and installation of the steel structure part of the plant. Including embedded parts, steel columns, steel beams, roof and wall sandals and color steel tiles.
3, construction basis: according to the requirements of Party A (construction drawings, engineering and technical contact sheets, the relevant norms shall prevail, the material type, specifications to drawings and project budget table) shall prevail.
Article 5, the material must be state-owned regular factory of the national standard material, and come with material inspection report. Project quality: According to the requirements of Party A to meet the drawings and relevant construction specifications, the quality of the project to meet the qualified standards.
Article 6, duration: the project duration of days. In the event of rain, power outages and other irresistible factors affecting the situation, or by the Party caused by the delay in the case of the actual number of days of work will be postponed.
Article VII, the cost of the project:
1, the cost of the project:
A, the steel structure for the roof acceptance ____ yuan/m2.
B, supporting facilities according to the quotation in accordance with the actual settlement (excluding tax).
2, the project if there is an increase in the two sides reconfirmed the increase in construction cost.
Article VIII, payment:
After the contract is signed, Party A will make payment according to the progress of Party B's works, and after the completion and acceptance of the project, Party A will leave 5% of the total project amount as a warranty, which will be paid off within one month after the project is accepted.
Article IX, construction:
1, Party B should develop safety measures before construction, and assume responsibility for construction safety. In the construction process must strengthen the safety awareness education and on-site supervision of the implementation of the site construction personnel to buy enough personal accident and other insurance, such as security and accidents by Party B is responsible for their own, Party A does not assume any responsibility.
2, Party A provides free on-site installation of construction water and electricity. Party A is responsible for leveling the road and plant floor for Party B's transportation vehicles to enter the site.
3, Party A appoints the representative at the site for Party B appoints the representative at the site for the appointed representative at the site on behalf of the parties to issue the relevant engineering contact sheets, visas, billing statements, etc., and to handle engineering-related matters.
Article X, acceptance:
1, acceptance based on: the signing of the contract, Party A provides construction drawings and construction change notice, the current national norms and standards as the basis.
2, the project quality grade qualified.
3. Party A shall organize acceptance within one week after the completion of the steel structure project.
Article 11, warranty time and content: the warranty period of steel structure of this plant is one year, counting from the acceptance. During the warranty period, Party B is responsible for reworking and repairing the quality problems of the plant caused by Party B's construction, such as natural disasters (e.g. earthquakes, typhoons, etc.) or man-made damages that do not belong to Party B's responsibility for the quality problems and damages caused by Party A. Party A will be responsible for the corresponding responsibilities.
Article XII, legal responsibility
1, in the construction process, Party A causes damage to Party B by Party A is responsible for Party B due to violation of the safety system and operating procedures caused by accidents by Party B is responsible for.
2, Party B must be in accordance with the time specified in the contract for construction, to ensure that the task is completed on time, quality and quantity. If the quality problem occurs due to Party B's delay, Party B will be responsible for the loss caused.
3, the contract was established in accordance with the law, legally binding, contract disputes, Party A and Party B should be in the spirit of seeking truth from facts to solve the problem in a timely manner through consultation. If the consultation fails, either party can apply to the contract management organs or arbitration, and to the people's court.
Article XIII, this contract in duplicate, each side of a copy, if any outstanding issues, the two sides **** with the consultation and then supplemented.
Party A (seal)
Signed on behalf of:
Party B: (seal)
Signed on behalf of:
___ 20___ year ___ month ___ day
Engineering Contract Model Generic 5 Related Articles :
★ Engineering Contract Model Generic 5 <
★ Engineering Contract Model 5
★ Engineering Contract General Edition Model 4
★ Engineering Service Contract Model 5
★ Architecture Contract Model 5
★ Engineering Construction Agreement 5
★ Engineering Construction Contract Model 5
★ Frequently Used Engineering Contracts 5
★ Engineering Construction Contracts 2021 Model 5
★ 2022 construction contract standard version model five
★ Construction engineering construction contract model five