Engineering construction, you need to go to sign a good contract to ensure the rights and interests. The following is the "engineering construction contract sample", which is only for reference, welcome to read.
Sample engineering construction contract (a)Party A: __________________
Party B: __________________
In accordance with the "Contract Law of the People's Republic of China*** and the State" and the relevant state laws, regulations and relevant provisions of the company's documents, following the principle of equality, voluntariness, fairness and good faith, A, B The two sides on _______ (project) labor construction contracting matters negotiated and agreed. Conclude this contract.
Article I, Project Overview
Project Name: ______________
Project Location: ______________
Article II, Project Contracting Scope
___________________________________
Article 3, Project Duration
1. Planned start date: _______ _______ month _______ day, planned completion date: _______ _______ year Month _______, total calendar days _______ days;
2. Main node duration: ___________________________________
3. Party B shall unconditionally carry out Party A's progress schedule arrangement (including the newly adjusted progress schedule).
Article 4, Project Quality Standards
The quality of the works within the scope of the contracted works must reach _____________________
Article 5, Component Contract Documents and Order of Interpretation
The documents and the order of priority of interpretation that make up the contract are as follows. Can not be clearly explained, without affecting the normal construction progress of the project under the circumstances of the two sides to negotiate a solution.
Article VI, standard specifications
This contract applies to the standard specifications: ____________________________
Article VII, Party A's responsibility and obligations
1. Management objectives, organization and preparation of construction plans, material requirements schedule, the implementation of the quality of the project, schedule, production safety, civilized construction, measurement and testing, laboratory testing control, supervision, inspection and acceptance.
2. Responsible for working with the owner, supervision, design and related departments to coordinate the site working relationship.
3. According to the project situation requires Party B to increase or decrease the number of construction workers to meet the needs of construction production. On the construction of poor quality, poor technology, disobedience to command, illegal and disorderly behavior of the personnel to be dismissed.
4. Timely provision of construction machinery and equipment supplied by Party A, turnover materials.
5. Pay labor remuneration to Party B as agreed in this contract.
6. Arrange and coordinate the solution of Party B's construction personnel living temporary facilities, water, with ______________ its costs:
7. Assist Party B for on-site construction personnel entry and exit documents, the cost of which Party B shall take care of itself.
Article VIII, Party B responsibilities and obligations
1. Comply with national policies and laws and regulations; comply with the owner and the relevant rules and regulations of Party A's enterprises, and do a good job of safety, civilized construction, environmental and occupational health and safety, labor protection and other work.
2. Strictly in accordance with the design drawings, construction acceptance norms, the relevant technical requirements and construction organization design carefully organized construction, to ensure that the quality of the project meets the agreed standards, the quality of the project within the scope of the contract labor contracting to the Party A is responsible for; according to the owner's or A's plan requirements (including adjusted plans), reasonable organization, scientific arrangement of the operation plan, investing sufficient manpower and material resources, Ensure that the construction period; bear the quality of their own responsibility caused by the return to repair, delayed loss of time and various fines.
3. Should be in place according to the requirements of the bidding documents and the commitment of managers, safety personnel (licensed) quality and quantity. Skilled workers must be held in accordance with national regulations on the job, mechanics must have vocational skills license, the license rate of 100%. Special types of work must have a special operating license, the license rate of 100%
4. Obey the Party and the owner of the supervision, inspection, management; accept the Party and the owner of the relevant personnel on quality, progress, technology, safety, civilized construction, environmental protection and other aspects of management: accept the Party to check at any time the equipment, materials, storage, use, and its operators valid documents, licensed to work Situation;
5. Do a good job in the construction site around the buildings, structures and underground pipelines and the finished project part of the finished product protection work. Damage due to Party B's responsibility, should bear all the resulting economic losses and various fines:
6. According to Party A's unified planning of stacking materials, machinery; proper storage, reasonable use of Party A provided or leased to the use of Party B's machinery, turnover materials and other facilities:
7. According to the national policies and regulations of each worker signed a "labor contract" and pay wages to workers in accordance with the terms of the contract agreed upon. Payment of wages to workers (workers' wages monthly register for the record), bear the consequences of disputes caused by the lack of this work or the penalties and responsibilities of the relevant local administrative departments;
8. Equip the construction workers with the necessary labor protection and safety supplies (such as safety helmets, safety belts, overalls, gloves and other related protective equipment);
9. Construction personnel required to have a good quality of mind, physical health, skilled and other conditions; prohibit minors under 18 years of age and 55 years of age and the elderly and frail sick and disabled personnel; prohibit the use of illegal personnel, Party B shall bear the responsibility and consequences arising from the use of the above unqualified personnel.
10. Party A in the funds temporarily not in place, the owner failed to pay the project on time, Party B shall not affect the normal construction, not mobbing, to achieve understanding of Party A.
Party B shall not affect the normal construction.
Article IX, environmental protection, production safety and civilized construction
1. Party A shall focus on organizing Party B's construction personnel to carry out production safety, civilized construction, environmental protection and the company's relevant systems and other aspects of education; based on national laws and regulations and the company's relevant rules and regulations, supervision, monitoring and implementation of the relevant work of Party B, to make its system operate effectively. The situation, so that the system operates effectively.
2. Party B shall comply with the relevant management regulations of engineering construction safety production, strictly according to the safety construction standards for construction; strengthen the safety education of workers operating on the site; conscientiously implement safety measures, take the necessary safety measures to eliminate hidden accidents, to ensure safe production; at any time to accept the safety inspectors to implement the supervision and inspection in accordance with the law. As a result of their own safety measures are not effective and unauthorized operation caused by accidents, bear all the consequences of responsibility and economic costs.
In the event of a safety accident, Party B shall immediately report to the relevant departments of Party A in accordance with the relevant provisions, and at the same time deal with the accident in accordance with the relevant state laws and regulations.
3. Party B will strictly implement the construction department and environmental protection, fire, sanitation and other relevant departments of the management of the construction site to achieve civilized construction; to ensure that the construction site is clean and orderly, in line with the relevant provisions and requirements of civilized construction, to maintain a good corporate image of Party A, and bear the losses and fines caused by violation of the relevant provisions.
Strengthen the site management, take all appropriate measures to protect the environment inside and outside the site, to limit the noise or other pollution caused by the construction work; to avoid damage and obstruction to the public and third-party property.
Article X, materials, equipment supply and management
1. Party A provides Party B with the use of turnover materials for the implementation of the transfer system, according to the needs of the project plan to Party B.
2. Party B on the proper custody, reasonable use of materials, equipment supplied by Party A (including collocation, storage, loading and unloading, return to the warehouse, for the relevant procedures, according to Party A's designated location in the field of categorization of stacking); due to improper storage and use of loss, damage, Party B shall be compensated according to the price of the time of collocation.
3. Materials according to the budget folding amount of Party B to implement the limit of collaterals, Party B should be reasonable use of materials, pay attention to savings. If the use of materials exceeds the budgeted amount, the excess part of the cost borne by Party B; material savings part of the A and B parties according to the _______ proportion of the share.
Article XI, contracting methods, prices and content
1. contracting methods and unit price
2. contracting prices include:
Contracting prices include all kinds of risks during the construction of the Party B and the construction of staff wages and transfer costs: small machinery costs; all kinds of materials in the field of the second Inverted transport; natural weather effects of water, electricity, pending material and other unforeseen man-days cost; including turnover of materials, loading and unloading, care, storage, return to the warehouse; labor protection supplies costs (helmets, seat belts, gloves, etc.); safety protection facilities (safety nets, protective rails, protective sheds, etc.);
civilized construction costs (including the higher departments of the various types of inspections on the site of temporary labor);
civilized construction costs (including higher departments of the site of temporary inspection);
the cost of construction of the site, including the cost of construction workers and the cost of construction workers and the cost of construction workers and the cost of construction workers. Labor); the scope of the contracted works with the measurement and placement, material testing, electricians, mechanical equipment maintenance and installation and dismantling with the labor; prevention of natural disasters in general measures taken with the cost of labor;
3. The unit price of this contract is a package of dead price, in the implementation of the contract does not change due to changes in other factors to adjust the change.
Article 12, settlement methods and payment
1. Monthly ___ by Party A according to the actual amount of work completed by Party B (or according to the node of the progress of the project) settlement of labor contracting fees, ___ according to the contract price settlement is completed, to the financial department of the Party as the basis for payment of labor contracting fees.
2. Party A does not prepay Party B's living expenses, labor contracting costs are paid monthly (or according to the node of the progress of the project), the payment time for the owner's payment, payment of the last month's settlement of _______%. After the completion of the contracted works to pay the settlement amount of _______%, the balance of _______% to be contracted for the completion of the contracted works to meet the acceptance of the contract requirements to be paid off. (The amount of settlement payment is based on the amount after deducting the labor management fee)
3. In the monthly contracting fee settlement, the labor management fee of _______% payable by Party B to Party A's labor company shall be deducted.
Article 13, Construction Acceptance
1. Party B shall organize the construction according to the quality standard agreed in this contract to ensure the quality of construction. Construction is completed, Party B shall promptly submit a self-inspection report to Party A, notification of acceptance; Party A shall promptly organize the preliminary acceptance of the results of Party B's construction of the relevant departments, acceptance before entering the next process of construction operations; acceptance of the results show that the quality of Party B's construction is unqualified, Party B shall be responsible for repairing the gratuitous, do not extend the period of time, and bear the resulting loss of Party A's related losses.
Completion of the acceptance, the owner, supervision and other relevant parties to put forward the quality defects of the project, Party B shall be repaired free of charge, and bear the resulting loss of Party A, not due to the prior acceptance of Party A to reduce the Party B responsibility.
2. Party B shall cooperate with Party A in the preliminary acceptance of its work and acceptance of the completion of the project; Party A or a third party in the construction site must work with Party B, Party B shall cooperate with Party A's instructions. (The cost of working with the third party is negotiated separately)
Article XIV, Engineering Warranty
1. Warranty scope and period: ______________
2. During the warranty period, Party B shall send someone to repair the work according to Party A's requirements and time after receiving the maintenance notice. If Party B does not perform as requested by Party A, Party A may entrust other units or personnel to repair, the cost of which Party B shall bear.
Article 15: Insurance
1. The person in charge of Party B must apply for accidental injury insurance for personnel engaged in hazardous work, and apply for insurance for the life and property of its own personnel and construction machinery and equipment in the construction site, and pay for the insurance costs.
2. When the insurance accident occurs, Party A and Party B have the responsibility to take necessary measures to reduce the loss.
Article 16: Disputes
1. A and B in the performance of the contract disputes can be resolved through negotiation; otherwise, both parties should be in the contract signed by the local labor arbitration department or the People's Court to resolve.
2. After the dispute, unless the following circumstances occur, both parties should continue to perform the contract, to maintain the continuity of the work, to protect the results of the completed work;
2.1 A unilateral breach of contract has led to the contract has been unable to perform the two sides to agree on the termination of the contract;
2.2 mediation requirements to stop the work of the contract, and the two sides to accept;
2.3 Arbitration body requirements to stop the work on the contract;
2.4 A court request to stop the work on the contract.
Article 17, Contract Performance Deposit
1. B pays Party A a contract performance deposit of _______ yuan.
2. The content of the contract performance bond shall include the conditions of commitment in the bidding documents and the bids of the bids set out in this contract, such as: construction period, quality, safety, environmental protection, civilized construction, the number of personnel in place during the peak construction period, the number of personnel in the busy season, the payment of farmer's wages, and compliance with the law, and so on.
If the above requirements are not met, a certain amount will be deducted from the performance bond; in the event of a serious breach of contract or irreparable loss to the Party, the entire bond will be confiscated and compensation will be made to the Party for the result.
3. After the completion of the project, Party B according to the content of the contract signed by the two sides to complete the acceptance of the relevant departments in line with the requirements of the contract, then Party A in January to return Party B's performance bond (without interest).
Article 18, force majeure
1. Force majeure standard implementation of the contract signed by Party A and the owner, when the contract signed by Party A and the owner of the contract does not have the corresponding standards, the implementation of the provisions of the state or local government.
2. After the occurrence of force majeure event, Party B shall immediately notify Party A's project manager, and take measures promptly under the conditions of ability to minimize the loss, Party A shall assist Party B to take measures.
3. Due to force majeure event delays in the work time is postponed.
4. Force majeure occurs after the delay in the performance of the contract by one of the contractual parties, the delay in the performance of the party can not be exempted from the corresponding responsibility.
Article 19: Termination of the contract
1. The contract can be terminated if it is impossible to fulfill the contract due to force majeure, or if it is impossible to fulfill the contract due to one of the parties' defaults, or due to the owner's reasons for stopping or slowing down the construction of the project.
2. Due to force majeure or the owner's reasons for the termination of the contract, Party B will do a good job on the completed project and the remaining materials, equipment protection and transfer of work, according to the requirements of the withdrawal of the construction site; Party A agreed to pay the completed work labor remuneration.
Article 20, the termination of the contract
Both parties to perform all the obligations of the contract; labor remuneration paid; Party B to Party A to deliver the results of the contract contract works, and the completion of the acceptance of the work; the warranty period has expired without the occurrence of quality problems, the contract will be terminated.
Article 21, the number of copies of the contract
This contract is a form of _______, Party A _______; Party B _______.
Article 22, Supplementary Provisions
__________________________________________
Article 23, Entry into Force of the Contract
The parties to this Contract Agreement _______ shall enter into force.
Contract signing time: ______________
Contract signing place: ______________
Party A (seal): ______________
Party B (seal): ______________
Sample of Engineering and Construction Contract (II)Contractor (Party A): ________________________
Contractor (Party B): ________________________
The two parties follow the principles of equality, voluntariness, fairness and honesty and credit, and enter into this contract by consensus on this construction project.
I. Project Overview
Project Name: ____________________________
Project Location: ____________________________
Project Content: ____________________________
II. Scope of Contracting
Scope of Contracting: _____________________ area shall prevail
III. Contract Duration
Start date: ______ year ______ month ______ no.
Billet completion date: ______ year ______ month ______ no.
Completion date: ______ year ______ month ______ no.
Total calendar of the contractual work period Days: ______ days
Delays
Delay in construction period due to the following reasons, confirmed by Party A, the construction period will be postponed accordingly
1. Design changes and increase in the amount of work;
2. Suspension of work due to suspension of water, electricity and gas for reasons not attributable to Party B for an aggregate total of more than ______ hours in one week;
2. Hours;
3. Force majeure natural conditions;
V. Completion of the project
Party B must be completed in accordance with the date of completion of the agreement. Because of Party B can not be completed in accordance with the completion date agreed upon in the agreement, Party B shall be liable for breach of contract.
Six, project quality standards
__________ County Quality Inspection Bureau shall prevail. (Excluding the quality of materials)
VII, the contract price
Amount: ￥ ______ per square meter of floor area × the total square meter of floor area
Advance payment for the project: ￥ ______ million
Completion of the day of payment: the remaining total amount of ______%
Settlement of the project: testing the completion date of the project ______ months after the absence of any construction quality problems, then settle the amount owed to She
Eight, the documents that make up the contract
1. the agreement of this contract
2. standards, specifications and related technical documents
3. drawings
The two sides related to Written agreements or documents of the two parties concerning the work, such as negotiation, change, etc. are regarded as an integral part of this contract.
Nine, B to Party A commitment to the contract agreed to carry out the construction, completion and in the quality warranty period to assume responsibility for the quality of the project warranty.
Ten, Party B in the construction process of building materials must be ___ in advance to Party A to submit a written application, Party A is required to provide all the construction in a timely manner shall not be missed, to ensure that the construction period of the smooth. Party B in the construction process, such as causing unnecessary waste in accordance with the market price of compensation.
XI, Party A has the right to supervise Party B's project. In the internal structure of the pigsty, Party B shall construct in accordance with Party A's requirements. Party A shall not mobilize Party B's construction personnel during Party B's construction process.
XII, the original ___ copies of this contract, have the same effect, by the contractor contractor to keep ___ copies.
XIII, the contract enters into force
The time of conclusion of the contract: ________ _______ ______
The place of conclusion of the contract: _________________________________________
This contract shall enter into force upon agreement between the parties ___________________________________.
Offeror: (Signature) _______________
Telephone: _________________________
Residence: _________________________
Contractor: (Signature) _______________
Tel: _________________________
Residence: _________________________
Sample Engineering and Construction Contract (III)Contractor (hereinafter referred to as Party A): _________________________
Contractor (hereinafter referred to as Party B): _________________________
In accordance with the Contract Law of the People's Republic of China (PRC) and the Construction Law of the People's Republic of China (PRC) as well as other relevant laws and administrative regulations, and in order to clarify the rights and obligations of the two parties in the process of construction, the two parties voluntarily enter into this contract by mutual agreement.
Article I, Project
I. Project Name: _____ Installation Project
II. Project Location: _____
III. Contracting Mode: Contract Labor, Contract Machinery, Contract Safety
Article II, Project Period
Article II.
The total number of calendar days of the contract period _____ days
Article 3, the project price, settlement and payment
This contract implements a fixed unit price according to the actual settlement, as agreed by the two sides, the photovoltaic panels installation project at _____ yuan per group/group (a group of _____ panels).
1, Party B construction is completed and accepted by Party A, Party A confirms the amount of work, the cost of its approval.
3, the confirmation of the amount of work, all the amount of work to be done by both sides to the site for verification, to meet the standard according to the unit price of _____ installation of the number of groups for the cost of settlement.
4, the cost of payment, after the end of construction, Party A _____ to pay the relevant project costs.
Article 4, Party A and Party B responsibilities
1, Party A need to transport materials to the installation site.
2. Party B must install the PV panels in such a way that the height difference between groups is no more than _____cm.
3. Party B must install the PV panels in each group to ensure that the whole group of PV panels is on a level surface.
4, Party B needs to carry out daily safety checks on its own members to ensure that the construction site zero accident.
5, Party B needs to protect the results of their own completion, such as the scene of the breakage, Party B needs to be no bar, pieces of maintenance.
Article 5, safety construction
Party B must pay attention to safety matters, to ensure that the installation of its relevant personnel before the safety education. The responsibility for accidents caused by Party B's inadequate safety measures and the costs incurred as a result shall be borne by Party B.
Article VI, reward and punishment responsibility
1, such as _____ month _____ before the installation to reach the _____ photovoltaic panels installed, then the _____ yuan standard settlement.
2, the agreement of a party to the unauthorized termination or termination of this contract, the defaulting party shall pay liquidated damages to the defending party in accordance with the _____% of the project amount.
Article 7, dispute resolution disputes arising out of this contract, such as consultation can not be resolved, both parties have the right to file a lawsuit to the People's Court in the location of the Party.
Article VIII, bylaws
This contract is a _____ copy, A and B each sign _____ copies, since the representatives of the two sides signed.
Party A: ______________________ Party B: ______________________
Representative: ___________________ Representative: _____________________
Phone: ______________________ Tel: ______________________
Date: ______ Date: _____ Date: _____ Date: _____ Date: ______ Sample Engineering and Construction Contract (4)
General Contractor (Party A): ____________________________
Address: ____________ Postal Code ____________ Telephone ____________
Legal Representative: ____________ Position ____________
Subcontractor (Party B). ): ____________________________
Address: ____________ Postal code ____________ Telephone ____________
Legal representative: ____________ Position ____________
In accordance with the provisions of the Contract Law of the People's Republic of China*** and the State of China", the Ministry of Construction "Implementation Measures for General Subcontracting of Construction and Installation Works" and ____ the relevant provisions of the ____ Municipal People's Government ____ document, by consensus of the two parties, sign this contract and seriously fulfill it.
Article 1, Project
I. Name of the project: ________________
II. Location of the project: ________________
III. Project No.: _________ Construction License No.: _______ Business License No.: _______
IV. Scope and Quantity of Subcontracted Work (with budget)
V. Duration of Subcontracted Work ________ started on ____ ____ and ____ completed on ____ ____.
VI. The cost of labor for the subcontract work ________.
VII. The type and number of laborers ________ put in by Party B.
The second, project settlement
According to the subcontracting project, the first month advance living expenses, calculated according to the number of people per person ____ of the contract, and deducted back in the next month settlement, in the construction of the project is underway according to the amount of acceptance of the work completed in the month in advance of the settlement (the magnitude shall not exceed the amount of the _____% of the completed amount) after the completion of the project by the A and B *** with acceptance, to be settled.
Article 3, project quality
Party A according to the national quality acceptance norms and assessment standards for technical delivery and organization acceptance, Party B in accordance with the construction drawings and specifications requirements, carefully organized construction, to ensure the quality of the project, such as the quality of substandard, must be reworked and repaired, and its loss of material and cost of labor and materials, borne by Party B; such as the quality of the project If the quality of the work is poor and can not be saved, Party B shall be responsible for compensating all the material losses.
Article IV, production safety
A party to the project undertaken by party B to do a safety briefing, put forward clear safety requirements, and supervision and inspection, party B must conscientiously implement the rules and regulations relating to safety construction, strict compliance with safety regulations, party A to provide safety facilities, party B by the inspection of the qualified to use, construction, if the violation of the above rules and regulations, and strictly comply with the safety regulations. Party B shall be responsible for the losses incurred in the event of injury or death during construction due to violation of the above provisions.
Second, labor protection supplies and construction of personal use of electrified operating tools such as insulated gloves, rubber boots, etc. by Party B to solve their own problems, such as Party B has difficulties, can be put forward to the plan, Party A to help solve.
Third, in the construction process, Party B is responsible for fire accidents caused by violation of fire regulations and laws.
Article V, life management
First, Party B workers into the field, food and accommodation by Party A to provide accommodation and the main cooking utensils (cauldron, cage drawer, hair dryer, large panels) by Party B to keep, if any damage to the lost at the price of compensation. Small sporadic appliances Party B to provide their own, living coal provided by Party A according to the ration.
Second, the life of the food, oil, by Party B, Party A should be in the medical, health and other aspects of the provision of convenience, Party B workers, such as disease, signed by the person in charge of the consent, can be in the Party to seek medical treatment, medical costs are responsible for Party B to pay off monthly.
Article VI, subcontracting labor cost unit price
First, the unit project subcontracting, each budgeted work days for ________ yuan. The implementation of a single square meter labor cost lump sum, per square meter ____ yuan.
Second, the inner eaves plastering subcontracting, to achieve high quality per budgeted man-days for ________ yuan. To achieve qualified per budgeted man-days for ________. Implement a sub-labor rate package of ________ per square meter.
Third, a single subcontract stone, earthwork per budgeted labor day is ________ yuan.
iv. The clearing labor rate is ________ per man-day.
v. Full day stoppage, standby, water, power and cleanup work days shall be ________ dollars.
VI. Water, electricity, heating and sanitation works, per budgeted man-day (subcontracted by block number for) ________.
VII, winter construction period (_____ month _____ to _____ the end of the month) to reduce the efficiency _____% of the man-days. The unit price of its labor day is ________ dollars.
Eight, subcontracting project cost breakdown (one to seven items can be listed)
Article VII, material supply management
Party B set up a special person to Party A for cement, steel, commodity components, hardware, linoleum, asphalt, and water, electricity, heating and sanitation, and other special materials, such as the limit of the collateral procedures. Party B shall strictly follow the quality requirements and materials provided by Party A for the construction. Party B shall be responsible for any waste of materials used in the construction and any unreasonable exceeding of the limit. Party B in the construction according to the stack (heap) use of materials, to do day-to-day clean, work clean, keep the site clean.
Article VIII, construction machinery
I. Large tools by Party A is responsible for, to ensure that the use of needs.
Second, hand-operated tools, Party B is responsible for.
Third, Party A is responsible for the supply of tools, Party B should be carefully kept and cared for, if lost or damaged, Party B is responsible for compensation.
Fourth, the construction of small and medium-sized machinery, equipped by Party A according to the construction program, a machine should be equipped with a driver to ensure that the normal construction of Party B, Party B is not allowed to unauthorized operation of the equipment (bring their own machinery in accordance with the relevant provisions of the treatment).
Article IX, site management
a, a, party B personnel should strictly abide by the site of the various management systems, in the party in charge of the site under the unified leadership of the organization of the construction, the plan, progress, supply of materials and other work the two sides should work closely to ensure that the construction is carried out smoothly.
Second, Party B should be construction personnel to comply with the law and safety production, care of property education, and designate a person responsible for site security, is strictly prohibited from stealing the site materials, such as violation of the site management system of unlawful acts, Party A has the right to take the necessary measures, Party B shall bear legal responsibility, and is responsible for compensation for economic losses.
Third, the subcontracting personnel to maintain relative stability, in and out of the construction site to wear a work sign, not allowed outside the contract personnel access to the site and accommodation.
Article X, liability for breach of contract
I. Party B subcontracted projects, may not be subcontracted. In the construction process by the test fails to meet the national acceptance criteria, can not guarantee the quality of the project, Party A has the right to terminate the contract, resulting in rework losses, Party B shall be compensated.
Second, after the signing of the contract, without the consent of both parties, no party shall not change or cancel at will. If Party B does not agree with Party A, unilateral termination of the contract, Party B shall compensate Party A for the economic losses caused by the impact of the construction program; such as Party A to terminate the contract in the middle of the contract, shall compensate Party B for the resulting . Economic loss.
Third, Party B must be completed in accordance with the contractual requirements for the duration and quality, or every day late, should be reimbursed to Party A according to the subcontracting labor ____% of the overdue liquidated damages.
Fourth, Party A and Party B shall not default on all kinds of payables, such as arrears, according to the bank short-term loan interest rates, pay the other side of the late payment of liquidated damages.
Article XI, bylaws
I. This contract in case of disputes, the parties shall consult in a timely manner, consultation fails. If it can not be resolved, it can be resolved in accordance with the following item ():
(1) apply for arbitration to the Arbitration Commission for Economic Contracts where the building is located,
(2) to the People's Court.
Second, this contract is ___ copies, A and B each of the original _____ copies. The remaining copies, reported to ____ for the record.
Third, the request for authentication (notarization), you can go to the district or county administration for industry and commerce where the building is located for authentication or notarization.
4. Other terms agreed by both parties:
1. _________________________
2. _________________________
Article 12, Contract Annexes and Validity Period
I. Annexes to the contract:
1. Budget of the project;
2. ____________________
II. This contract shall enter into force on the date of sealing by both parties, and shall expire after the project is fully completed and settled.
General Contractor: ________________________
Legal Representative: ______________________
Subcontractor: ________________________
Legal Representative: ______________________
Date of signature: ____ ____ ____ ____