Directional Drilling Project Construction Contract Agreement 6_Construction Contract
When signing a construction contract, you must abide by national laws and conform to national policies. Never create your own new words or unfamiliar words, the contract is not a literary creation, it is about clarity, directness, accuracy and non-controversy rather than new and strange ideas. Are you looking for is ready to write "directional drilling project construction contract agreement", I collected the relevant material below, for you to write a reference!
Directional Drilling Project Construction Contract Agreement 1
Party A:
Party B:
In accordance with the principles of the "Chinese People's **** and the State of Economic Contracts Law", combined with the relevant provisions of the Guangdong Provincial Zhanjiang City, and the specific circumstances of the project, by the consensus of the A and B parties, signed this contract.
Article 1 project overview
top to find out the cracks grooving with Qinglong 203 waterproof glue for waterproofing, both sides of the inner wall open delamination mortar re-building and waterproofing with Qinglong 203 painting. 1 staircase top of the ceiling grooving repair for waterproofing and then paving self-adhesive membrane.
Article II construction period: 20__.07.01--20__.08.10
Article III quality requirements and scope of work
Article IV contract price:
Article V safety construction
Party B should be in accordance with the relevant provisions of the safety measures. Bear the responsibility and the expenses incurred as a result of unfavorable safety measures. Party A is responsible for providing workers' insurance. Party A shall provide Party B with water and electricity supply and construction convenience.
Article 6 Acceptance and payment
Party B into the field, Party A must send a responsible person to cooperate with Party B, the project should be in accordance with the requirements of the construction, the project is completed, notify the Party A quality inspection and acceptance signature, acceptance of the acceptance before leaving the field. Engineering warranty period of one year, one year if there is a quality problem, Party B unconditional repair.
Article VII mode of payment
After acceptance of the project, with the acceptance of the signed bill settlement.
Article VIII of this contract is signed, that is, has the force of law, the two sides must be fully performed, shall not be lifted arbitrarily, if there is a dispute, the two sides should be resolved in a timely manner through consultation; consultation fails. Either party may apply to the contract arbitration institution in the place of fulfillment of this contract or by the people's court in the place of fulfillment of this contract.
Article IX of this contract in duplicate, each party holds a copy of the two sides since the two sides signed and sealed effective.
Party A (seal): Party B (seal):
Party A's representative: (Signature) Party B's representative (Signature)
Month and year:
Directional Drilling Project Construction Contract Agreement 2
Contractor (Party A):
Contractor (Party B):
In accordance with the provisions of the Contract Law of the People's Republic of China, the Ministry of Construction, the Implementation Measures for the General Subcontracting of Construction and Installation Works and related documents, this contract is signed by both parties by consensus.
Article I Project
First, the project name: Chengdu Yandao Street Foreign Language School Campus Style Improvement Project, the second section of the project location: Chengdu Airport Airport Road, Chengdu Airport
Third, the scope of the project: the original school Meiluo kindergarten basketball court before the renovation of the Fourth, the project price and volume confirmation: detailed attached visa (visa in the unit price for the comprehensive unit price, single does not include taxes) Gold, tax according to the list of fixed amount of another, the amount of work for the actual amount).
Article II construction content
1, the main project content: the original basketball court redo EPDM plastic permeable surface layer (surface layer thickness of 8mm thick), drawing the standard basketball and badminton activities area.
2, ancillary project content:
1), new work before shoveling the original plastic surface layer of the basketball court;
2), the use of C30 fine gravel concrete to repair the grass-roots level of the basketball court damaged places;
3), with black plastic particles of the grass-roots level of the basketball court where there is a difference in height leveling;
4), the basketball court around the greening increase. Article III responsibilities of both parties
A party responsibility
1, to provide on-site construction of water interfaces, power supply connectors, with the normal smooth progress of the construction process.
2, confirm the construction drawings and programs, and explain the use of materials and effects.
3, the organization of the completion of the project acceptance, and according to the contract for the final account.
Second, Party B's responsibility
1, according to Party A's requirements and relevant construction specifications for construction.
2, the use of materials to meet the standards and requirements.
3, the project needs to meet the acceptance criteria: basketball court surface flatness to meet the requirements of the error of 2mm or less; basketball court surface appearance without cracks, no obvious joints, layering, bump phenomenon, no water.
4, after the completion of the project to clean up the site, so that the work is done.
Article IV of the project settlement contract total price for (capitals: ), in the month of one-time settlement.
Article V Supplementary Provisions
First, the contract disputes, the parties should consult in a timely manner, the consultation fails. If it can not be resolved, it can apply for arbitration to the Arbitration Committee of Economic Contracts where the project is located.
Second, this contract in duplicate, A and B each party.
Third, this contract shall come into effect upon signature by both parties, and shall expire upon completion of all works and payment of the project.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ ____ ____ _________ ____ ____ Day
Directional Drilling Project Construction Contract Agreement 3
The Contractor (hereinafter referred to as Party A):
The Contractor (hereinafter referred to as Party B):
In accordance with the "People's Republic of China **** and the State Contract Law" and other relevant laws, and in accordance with the principles of equality, voluntariness, fairness and honesty and credit, the two sides on the Ltd. standard basketball court construction, enter into this contract.
Article 1 Project Overview
1.1 Construction Location: Jiaxing Situ Factory
1.2 Construction Area: East of Dormitory Building
1.3 Project and Price
1.3.1 At the request of the Ministry of Management, the East of Situ Dormitory Building is required to build a Standard Basketball Court, with the specific requirements as follows:
1. The geometrical dimensions of the Basketball Court are 20_37M. The geometry of the demarcation area is 18_25M.
2. Foundation treatment: 200-thick pond slag bedding, 150-thick triple slag stabilization layer, 50-thick coarse-grained asphalt concrete, 30-thick fine-grained asphalt concrete. Higher than the peripheral road surface 150, surrounded by cofferdam with C25 concrete pouring. Site long to each set the ditch a requirement of concrete pouring steel brazing dimension cover plate.
3, around the ballpark with 76mm_3mm welded steel pipe to do columns, 60_3 welded steel pipe to do the upper and lower crossbar, welded into a 2.5M-high fence frame, filled with 45_45_3.2mm PE air-coated wire mesh. Use 50mm steel pipe and rubberized wire mesh to make a 2400_1400 iron door.
4, all iron spraying two layers of anti-rust reddish primer and two layers of dark green anti-rust top coat.
5, with 114mm_4mm steel pipe to do 6M high lamp post 8, 76mm steel pipe to do the lamp arm cantilevered 1200mm, the installation of 1000W metal halide lamps and lanterns 8 sets.
6, pre-buried 25mm-40mm PVC pipeline, wiring connected to the control box.
7, the installation of 80A waterproof leakage-proof power distribution control box.
8, the surface pavement using the United States Dekry acrylic surface coating. Construction in three steps, leveling layer with asphalt base coatings repeatedly leveling unevenness thickness of about 1mm, bonding layer in the asphalt substrate pavement coating bonding layer coating layer thickness of about 1mm, texture layer thickness of about 0.7mm, the color layer thickness of about 0.3mm.
9, basketball court on both sides of the bench to do 28m long, 40cm wide steel bench. Bench surface with 80_40_2.0 flat steel pipe production, bench legs with 30_30_2.0 square tube production. The bench surface is connected with the fence riser.
10, the basketball frame belongs to the A refers to the material to be specified by the A brand, price, after the completion of the project will be adjusted in the settlement.
Article II contract price
2.1 This contract is a fixed total price: 328561 yuan RMB 3,028,561 yuan (installation of other machinery and equipment such as racks are provided by Party B, the cost is included in the total contract price).
2.2 Increase in the amount of work need to have Party A visa list.
2.2 Provide unified invoice for construction industry.
Article 3 Construction Period
3.1 Start and completion time: 30 days from the notice of entering the site issued by Party A, with 500 RMB deducted for each day of delay. During the construction period, submit to Party A's on-site schedule.
Article IV Quality Guarantee
4.1 Guarantee the quality of construction of this project, Party A in accordance with the unified standards for acceptance verification of construction quality, site drainage smooth
4.2 The warranty period for this project is one year to the date of acceptance of the two sides of the completion of the project, one year, if due to the problems caused by Party B, Party B is responsible for the return of repairs to the qualified without compensation.
Article V Project Acceptance
5.1 Within 10 working days after the completion of the project, Party A shall organize the relevant personnel to accept and confirm the actual number of operations; in case of special circumstances need to be postponed, notify Party B, Party B agreed to delay, up to a maximum of ten days.
5.2 In case of any of the following circumstances, the Project shall be deemed to have been actually completed and accepted and confirmed by Party A as qualified.
5.2.1 Party A does not do the acceptance beyond the specified time.
5.2.2 Party B's operation area has been put into use and no doubt has been raised about the quality of construction.
Article VI Payment
6.1 contract signed Party B into the site to pay 30% of the total contract price in advance, the completion of the project after acceptance of 95% of the settlement price, the balance of the warranty period expired within 28 days, a one-time payment (the warranty period of one year).
Article 7 Default and Dispute
7.1 If either party unilaterally terminates the contract or partially terminates the contract, it shall be liable for breach of contract, and pay the other party liquidated damages in accordance with 30% of the amount of breach of contract.
7.2 If Party A does not pay the contract payment according to the progress stipulated in the contract and Party A does not provide normal working surface, Party B has the right to stop the construction, and the loss of missed work caused by Party A shall be borne by Party A.
7.3 Disputes arising from the fulfillment of this contract shall be resolved through consultation between the two parties, or through arbitration or litigation if consultation fails.
Article 8 Entry into force and termination of the contract
8.1 This contract shall enter into force on the date of sealing by both parties.
8.2 The contract will be terminated after acceptance and settlement by both parties (except for warranty terms).
Article 9 Supplementary Provisions
9.1 Matters not yet resolved, in accordance with the "People's Republic of China **** and the State Contract Law", and other relevant laws and regulations, or the two sides to negotiate a solution.
9.2 This contract is in four copies, held by the A and B parties, each with two copies, all have the same legal effect.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ ____ ____ _________ ____ ____ Day
Directional Drilling Project Construction Contract Agreement 4
Party A:
Party B:
Based on << Chinese People's **** and the State of the Contract Law>>, << Chinese People's **** and the State of the Construction Law>> and other relevant Laws and regulations, follow the principle of equality, voluntariness, honesty and trustworthiness. Both sides on the roof of the waterproofing project construction matters consensus, to enter into this contract for both sides *** with compliance.
a, project overview
1, project location: layer mountain elementary school courtyard
2, project name: layer mountain elementary school building, dining hall building roof waterproofing
3, the project content: in the original basis of a new layer of SBS modified asphalt waterproofing roll-roofing construction, including detailing, bottom grass-roots processor construction, the construction of the additional layer, the construction joints and the waterproofing of the back pouring zone and the waterproofing of the construction joints and the waterproofing of the back pouring zone and the waterproofing of the construction joints and the construction joints and the waterproofing of the back pouring zone. Waterproofing treatment and waterproofing after pouring zone with the project related to the sporadic works.
4, two, the scope and mode of contracting: package work, package materials, package quality, package safety, package progress, package civilization construction.
Third, the selection of main materials and project prices, etc.:
1, the selection of materials: Party B in the construction of the material must be provided before the certificate of conformity, material inspection certificate, material samples and Party B construction qualification certificate. Materials can only enter the field and start work after passing the test by the testing center.
2, the unit price of 45 yuan / square meter, **** 1638 square meters (including: 1008 square meters of teaching building, dining room building 630 square meters, a total of 1638 square meters), *** counted 73,710 yuan.
Fourth, the construction period: February 12, 20__ -20 days.
V. Project quality:
1. Project quality standards: qualified project quality standards.
2, the contractor's construction quality must meet the current national norms, standards, atlases and design drawings. And meet the requirements of the contractor. Engineering construction quality must comply with ? Elastomer modified bitumen waterproofing membrane? (GB18242-20__), waterproofing construction materials used must have product certification and performance test report.
Six, the contract price and payment According to the contractor actually completed, and meet the quality standards of the amount of work, 45 yuan per square meter. No longer count any other costs. Failure to meet the quality standards, the contractor rework, rework to the contractor caused by the loss, the contractor should be compensated for the loss; the contractor refused to rework, or serious delays in the construction period, the contractor to organize another construction unit to carry out the construction, the contractor has been constructed the volume of the works, the contractor can refuse to pay any costs, the contractor has no objection.
VII. Party A undertakes to pay the contract price in accordance with the time and manner agreed in the contract.
VIII. Other matters:
1. Disputes occurring in the implementation of the contract, the two sides should be resolved through friendly consultation. If the consultation is invalid, apply for arbitration to the People's Court where Party A is located.
2, this contract in duplicate, signed and sealed by both parties shall come into force.
Party A (seal): Party B (signature):
Month and year:
Directional Drilling Project Construction Contract Agreement 5
The contractor (hereinafter referred to as Party A):
Contractor (hereinafter referred to as Party B):
In accordance with the "People's Republic of China*** and State Contract Law" and other relevant laws and administrative regulations. other relevant laws and administrative regulations, in order to clarify the rights and obligations of both parties in the construction process, the two sides voluntarily signed this contract through consultation.
Article I Project
I. Project name: the roof of the firewood shed and the cafeteria entrance canopy of Taijiang County Zhixing Hope Primary School
II. Project location: Zhixing Hope Primary School
III. Project content: the roof of the firewood shed and the cafeteria entrance canopy
IV.
Article II Project Period
I. Total calendar days of the contract period 10 days
Start date: August 25, 20__
Completion date: August 27, 20__
II. In case of the following circumstances, after the visa of Party A's on-site representative, the construction period can be postponed accordingly. 1. In the course of construction, if due to the blackout of power for more than 8 hours or Continuous intermittent power outage for more than 3 days (more than 4 consecutive hours each time), affecting normal construction; power outage for more than 2 days;
2, due to typhoon rainstorms hurricane and other force majeure factors;
3, due to manpower irresistible to other factors and delay the construction period.
Article 3 Supply and Purchase of Construction Materials and Equipment
1. The materials and equipment for the project will be purchased by Party B. The construction materials and equipment will be purchased by Party B. The construction materials and equipment will be purchased by Party B. The work will be contracted out.
2, Party B purchased materials, equipment, must be accompanied by product certification to be used in the project
Article IV Acceptance and Payment
The total price of the construction project is calculated to be: six thousand rounds (6,000 yuan), and after the completion of the project, the Party A acceptance of payment to Party B.
Article IV Acceptance and Payment
The total price of the construction project is estimated to be: six thousand rounds (6000 yuan), after the completion of the project, Party A acceptance of payment.
Article V Supplementary Provisions
I. Party A's representative: __x Party B's representative: Jiang Xiaowu.
Second, this contract in duplicate, Party A and Party B each sign a copy, since the signature of the representatives of both parties, stamped with the official seal of both parties or the contract seal after the entry into force.
Party A: Party B:
Representatives: Representatives:
Year Month Day Year Month Day
Directional Drilling Project Construction Contract Agreement 6
Party A:
Party B:
After the school meeting, Party A will be the campus cultural construction of the wall of clear water wall, painting the classroom 6, stove room door sewage settling tank project construction contracted to Party B (Wei sex Zhi). Construction period August 1, 20__ - August 20, 20__, must be completed on time with quality and quantity. Party B is responsible for the construction, Party A to provide materials, in order to ensure the successful completion of the project plan, especially the development of this contract, in order to abide by.
First, the project overview and cost
1, part of the wall clear water wall
The area of the clear water wall (10 yuan per square meter)
Sixth-grade classroom in front of the left side of the 18.5 × 2.0 = 37.0 square meters
Teachers east back wall 28.33 × 1.72 = 49.3 square meters
The west back wall of classroom 28.23 × 1.72 = 48.6 square meters
The west back wall 28.23 × 1.72 = 48.6 square meters
Teachers east back wall 28.33 × 1.72 = 48.6 square meters. 1.72=48.6m2
Total 37.0+49.3+48.6=134.9m2
Total price: 134.9m2×10.00 yuan/㎡=1349.00 yuan
2, painting classrooms of grades 1-6 (500 yuan for each classroom)
No. of classrooms: 6
Total: 6 × 500.00 yuan / room = 3000.00 yuan
3, the stove in front of the sewage settling tank
Labor wages 120.00 yuan / day × 4 days = 480.00 yuan
Second, the materials used in the project
1, the cultural wall of water wall
Cement 1 ton × 260 yuan / ton = 260.00 yuan
Sand 10 square × 55 yuan/square = 550.00 yuan
Total: 810.00 yuan
2, classroom wall painting
Putty powder 20 bags × 16 yuan/bag = 320.00 yuan
801 adhesive 2 buckets × 50 yuan/bucket = 100.00 yuan
Latex Paint ( Apple Green) 2 buckets x $165.00/bucket = $330.00
Sandpaper 20 sheets x $0.50/sheet = $10.00
Sandpaper palms 2 x $5.00/each = $10.00
Brushes 2 x $5.00/each = $10.00
Total: $780.00
3, Settling tank
U-tank 8 x $40.00/each = $320.00
4-inch water pipe 2 x $100.00/each = $200.00
Cement 2 bags x $13.00/bag = $26.00
Cover 2 x $30.00/each = $60.00
Total: 606.00 yuan
The total of the above one and two items is RMB 7025.00 yuan, capital: seven thousand and two hundred and twenty-five yuan. After Party B completes the work and submits it to Party A for acceptance, payment will be made to Party B. This contract in duplicate, Party A and Party B each sign a copy, effective from the date of signing.
Signature of Party A's representative: Signature of Party B's representative:
Date of signing: