General Edition of Engineering Contract Template 1
Employer (full name): _ _ _
Contractor (full name): _ _ _
In accordance with the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and administrative regulations, and following the principles of equality, voluntariness, fairness and good faith, both parties reached an agreement on the construction project and concluded this contract.
I. Overview of the Project: The hardened area of the road hardening project is about _ _ _ square meters. The project includes subgrade leveling, cement pavement pouring and so on. The budget is about _ _ ten thousand yuan.
Second, the contract period: this project will be completed before 20th.
Third, the quality requirements and reward and punishment measures:
1, to ensure that qualified (organized by the two committees of the village to invite professionals to accept), safe production and civilized construction must be achieved.
2. The main roads in the village are constructed according to the cement concrete pavement standard of Grade IV highway, and the quality target is qualified. (1) cement concrete grade C25 grade, thickness 15cm, flexural and tensile strength above 4.5Mp (2) various physical performance indicators should be tested for the main materials during construction, among which the coarse aggregate must be crushed stone, in line with relevant national standards. According to the index of materials and the actual label of cement, choose the mixture ratio (cement should have factory certificate and quality certificate); During the construction, the test shall be carried out in strict accordance with the Test Specification for Cement Concrete in Highway Engineering, and unqualified materials shall not enter the site for construction. (3) Anti-skid measures such as transverse napping or machine pressing groove should be taken for the pavement, and its friction force should meet the requirements of construction specifications. When connecting with other structures, the pavement should be smooth, so that there is no water on the edge of the pavement. (4) After concrete paving, it shall be maintained according to the requirements of construction specifications; The appearance of concrete pavement is free of peeling, marks, cracks, exposed stones, lack of edges and corners. , in line with the specifications and process requirements. (5) The project files and test data shall be submitted to the _ _ _ village committee for future reference.
3. Reward and punishment measures: The contractor must construct in strict accordance with relevant codes and standards to ensure the quality of the project. If the project quality is not up to standard, it must be reworked unconditionally and bear the rework losses. The warranty period is one year.
4. Project contracting mode: contracting for work and materials. The settlement of the completed project is based on the contract price, the contract unit price is cement pavement slab thickness 15CM, and the unit price is 40 yuan/m2; The engineering quantity should be settled according to the facts.
5. Payment method: 50% of the pavement hardening project will pay 20% of the contract price; After all the projects are completed and accepted, 90% of the total project price will be paid after the superior funds are in place, and the performance bond will be returned; Withhold 10% as the project quality deposit, and the quality deposit will be paid within 1 month after the quality guarantee expires.
The contractor shall provide the Employer with a performance bond of RMB 30,000.00 Yuan, which will be returned after the acceptance of the project.
Seven, reward and punishment measures:
1. The project will be completed before 20th. Except for force majeure, the penalty for delaying the construction period is 100 yuan per day.
2. After winning the bid, the contractor shall submit to Party B a detailed list of the project management team when bidding for this project, and require the project manager to be on duty for no less than 20 days every month. Without the prior consent of the employing unit, those who are found to be absent from the post without authorization during spot checks shall be fined 100 yuan per person per day in addition to being ordered to arrive at the post. In addition, after the signing of the project contract, subcontracting is not allowed, otherwise it will be regarded as abandonment, the performance bond will not be returned, and the project will be re-tendered.
3, the contractor must accept the employer's supervisor supervision, accept the rectification opinions.
Eight, safety responsibility:
1. Before construction, the Employer shall be responsible for cleaning up the crops within the construction scope; During the construction period, the Employer shall be responsible for handling disputes related to policies.
2. During the contractor's construction, the blaster must hold relevant certificates (three members and three certificates are complete) and go through relevant formalities such as safety insurance. For accidents such as personal safety, traffic safety and group disputes caused by the contractor, all responsibilities and economic compensation shall be borne by the contractor.
Nine, this project bidding documents as an attachment to sign the construction contract, the contractor shall abide by laws, regulations and relevant policies of the construction industry.
X. The responsibility and obligation of project quality warranty shall be implemented according to the Regulations on Quality Management of Construction Projects issued by the State Council in 2000 1.20 and other relevant laws and regulations.
1 1. This contract is made in triplicate, one for the contractor and the employer, and one for the office.
Twelve. Entry into force of contract
Date of conclusion of the contract: 20 _ _ _ _ _ _ _
Place of conclusion of the contract: _ _ _ _
This contract shall come into effect after being signed and sealed by both parties.
Employer: (official seal) _ _ _ Contractor: _ _
Representative: Address:
Tel: Tel:
Engineering Contract Template General Edition 2
I. Project name:
Second, the purpose
In order to safeguard the common interests of Party A and Party B, ensure the construction quality and safe production, and maintain a good working order and sanitary environment on the construction site, this construction safety agreement is signed by both parties through equal consultation.
Three. Content of the agreement
(I) Party A's responsibility for production safety management
1. Party A must strictly implement the national and provincial laws, regulations and standards related to production safety, formulate its own rules and regulations on production safety and operating procedures, establish and improve the management system of production safety, implement the requirements of various safety technical measures, and ensure the effective implementation of production safety investment in engineering construction.
2. Party A shall provide Party B with the existing technical data required for the construction.
3. The design documents provided by Party A shall meet the safety and health requirements of construction personnel.
4. Party A shall bring the safety supervision and management of Party B's construction site into the unified management within the safety system of the unit, and the emergency rescue plan for production safety accidents must include the contents of Party B's construction safety.
5. Party A shall not ask Party B for requirements that do not meet the laws, regulations and mandatory standards of safety production, and shall not arbitrarily compress the construction period agreed in the contract.
6. Party A shall provide first aid and medical convenience for Party B's work injury.
(II) Party B's responsibility for production safety management
1. Party B shall establish a construction safety guarantee system, implement the post responsibility system for construction safety, implement target management for safety production, and standardize construction site operations.
2. The person in charge of Party B's project shall be a qualified person, responsible for the safety production of mine engineering projects, implementing the rules and regulations of safety production and operating procedures, and ensuring the effective use of safety production inputs.
3. Party B shall designate the person in charge of on-site construction safety, and the number of safety supervisors shall meet the production requirements to supervise the whole process of on-site construction safety.
4. Before the project starts, adhere to the principle of "one project and one measure, report the measures first before construction", and the construction organization design, operation procedures and safety technical measures approved by the competent department of Party B must be reported to Party A for approval before implementation.
5. Party B shall implement the labor production education and training system, strengthen the safety production education and training for its own personnel, truthfully inform the workplace and post of the risk factors, preventive measures and accident emergency measures, and ensure that employees are familiar with and strictly implement the relevant safety production rules and regulations and safety operation procedures, master the safety operation skills of this post, and have the necessary safety prevention knowledge. Special operations personnel shall be organized by the relevant departments stipulated by the state for special training, and can only work at their posts after passing the examination and obtaining the post certificate. The project department shall establish employee training files and report them to Zhonghe Coal Company and supervision company for the record.
6. Party B shall organize employees to participate in safety education and training activities arranged by the construction unit according to their own needs, and bear the related expenses arising therefrom.
7. Party B must participate in social insurance for work-related injuries according to law and pay insurance premiums for employees.
8, construction personnel must wear certificates, uniform wear work clothes, in accordance with the provisions, the correct use of qualified safety protection tools, to prevent the occurrence of objects, falling accidents. The safety protection equipment of the construction team must be in place and the safety measures are effective, otherwise the operation shall not be started; The construction unit must submit a copy of the safety production license, the qualification certificate of the project manager and the operation certificate of special type of work to the safety supervision department for the record as required by Party A. ..
9. Party B shall seriously implement Party A's safety management regulations and strengthen safety management. If Party B violates the regulations or Party A's management regulations, Party A has the right to stop Party B's work and cause certain consequences, and Party B shall bear all the responsibilities.
10. Party A has the right to inspect, stop illegal operations, punish acts violating safety regulations or order the construction team to stop work for rectification at any time. The potential safety hazards discovered by Party A shall be rectified within a time limit, and the rectification shall be reported to Party A in writing in time.
1 1. Party B shall sign a safety production management agreement with a third party operating in the same operation area or the same production system. In the event of a safety accident, the responsible party shall bear the consequences. If both parties have responsibilities, they shall bear corresponding responsibilities according to the size of the responsibilities.
12. In case of disasters and accidents, Party B's personnel, materials and equipment shall unconditionally obey the dispatch, and the expenses incurred shall be negotiated separately after the accident is handled.
13, strictly implement the accident reporting system. When a production safety accident occurs, Party B shall report to the superior department of the unit and Zhonghe Coal Company in a timely manner in strict accordance with the accident reporting procedures and requirements.
14. Other outstanding matters shall be settled by both parties through consultation.
(3), production safety management responsibility punishment
1. After winning the bid, when signing the contract and safety agreement, Party B shall pay a safety and quality deposit of RMB 200,000 ~ RMB 10,000, and take the safety effect and project quality as an important basis for project acceptance. In case of accidents, unqualified quality or violation of relevant agreements in this agreement due to the management responsibility of the outsourcing unit, a fine shall be imposed according to the regulations, and the fine shall be deducted from its safety and quality guarantee fund.
2. If Party B subcontracts the contracted contract or subcontracts it to a third party in disguised form, it shall be ordered to make corrections within a time limit and be fined 50,000 yuan.
3. If Party B fails to implement, inspect or sign the safety technical measures for construction personnel, it shall be ordered to make corrections within a time limit and be fined __ 00 yuan.
4. If Party A finds out that Party B has arranged untrained employees to work in the well, it will be fined 5000 yuan/person.
5. Party B shall, according to the requirements of the special terms and conditions, send a technician to lead the shift at the construction site in each shift, and it is strictly forbidden to leave the shift empty. 500 yuan was fined for finding one person in the empty class.
6. If Party B's personnel are injured or killed due to Party B's poor management or illegal operation, Party B shall bear the responsibility.
In case of minor injuries, Party B will be fined 20,000 yuan;
In case of serious injury accident and non-personal casualty accident above Grade II, Party B shall dismiss the project manager and the person directly responsible, terminate the labor contract, and impose a fine of100000 yuan/person;
Party B shall dismiss and demote the project manager and the person in charge of the death 1 accident; At the same time, Party B will be fined1100,000 yuan/person.
1 Party A gives Party B the right to terminate the construction contract if two people died in an accident or two people died cumulatively;
7. Party B shall be responsible for the safety management of other personnel entering its operation area and for the casualties of other personnel. The penalty is the same as article 5.
8. If Party A's management is not in place or Party B's personnel are injured or killed due to illegal operation, the responsibility shall be borne by Party A, and it shall be implemented according to the document No.20 _ _1.
9. Both Party B's management and Party A's management have the responsibility and obligation to * * * implement various reward and punishment measures stipulated in Zhong Mei An No.20 _ _ 1.
(4) This Agreement is made in duplicate, one for each party, and shall come into effect as of the date of signature.
Party A (official seal) and Party B (official seal)
Legal Representative A: Legal Representative of Party B:
Year, month, year, month, year
Engineering Contract Template General Edition 3
Party A: _ _ _ _ _ _ _ _ Open-pit coal mine
Party B: _ _ _ _ Construction Engineering Co., Ltd.
_ _ _ _ _ _ _ _ _ _ _ _ During the execution of the construction contract, in order to create a safer and more efficient construction environment and do a good job in the safety production management of this project, the mine owner (_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
I. Term of the contract: from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Two. Party A's responsibilities:
1. Strictly abide by the national laws and regulations on "safety in production", earnestly implement the relevant safety requirements in project contracting, and establish a safety production management organization with more than five employees and Party B's participation.
2, according to the principle of "safety first, prevention first, comprehensive treatment", adhere to the principle of "safety must be managed in production", so that production and safety can be planned, arranged, inspected, summarized and evaluated at the same time.
3. Important safety facilities must adhere to the principle of "three simultaneities" with the main project, that is, design, approval, construction, acceptance and operation at the same time.
4, regular production safety dispatch meetings, timely convey the superior about the spirit of production safety.
5. Organize the safety production inspection of Party B's construction site, and supervise Party B to deal with all kinds of potential safety hazards found in time.
Three. Party B's responsibilities:
1, strictly abide by the relevant national laws and regulations on safety in production, mechanical operation procedures and other relevant provisions on safety in production, and strictly implement the provisions on safety in production in the engineering contract. At the same time, a "safe production" leading group was established.
2. Adhere to the policy of "safety first, prevention first and comprehensive treatment" and "safety must be managed in production", strengthen the publicity and education of safety production, and enhance the safety production awareness of all employees. Establish and improve various safety production management systems, equip full-time safety inspectors, and organize leaders to carry out safety production education and training. Supervision and inspection, appraisal and other activities. Leaders at all levels, engineering and technical personnel, safety production management personnel and gymnasts must be familiar with and abide by the provisions of this clause, so that production and safety work can be planned, arranged, inspected, summarized and evaluated at the same time.
3, establish and improve the responsibility system for production safety. Strengthen the safety production management of project managers and production workers (including temporary migrant workers).
4. Party B shall take all reasonable preventive measures at any time to prevent its employees from any illegal, illegal, violent or disturbing public order. During the construction process, in case of severe weather such as strong wind and rainstorm, it is impossible to carry out the construction, and it should be evacuated to the station or safety zone in time. Drivers are not allowed to drive back to the station.
5. Party B's personnel involved in the construction shall go through relevant formalities such as temporary residence permit at the local police station after taking up their posts, and must receive safety technical education, be familiar with and abide by various safety technical operation procedures of this type of work, and conduct regular safety technical assessment. Only those who have passed the post assessment are allowed to take up their posts. Personnel engaged in special types of work such as electrical, lifting, building climbing frame deployment, boilers, pressure vessels, welding, motor vehicles, etc. , you must hold relevant certificates, and you are not allowed to work without training from professional institutions and obtaining a safety operation certificate and driver's license. The project manager must bear the corresponding management responsibility and safety responsibility.
6. Party B shall strengthen the fire control work of roads in fire areas and production areas, attach great importance to the fire safety management in fire areas, and take full responsibility for fire accidents.
7. Flammable and explosive materials should be properly kept by specialized personnel, equipped with adequate fire-fighting facilities, and all construction personnel should be familiar with the performance and usage of fire-fighting equipment. Party B shall not give, barter or transfer any kind of explosives to others in any way, and shall not allow or tolerate the above-mentioned behaviors under his own eyes. Once found, Party B shall stop or report it in time.
8, the operator mount guard, must wear protective equipment in accordance with the provisions. The person in charge of construction and safety inspectors should wear safety helmets, and the night shift personnel should wear luminous clothes, and check the wearing conditions of labor protection articles at any time. Those who do not wear protective articles according to the regulations are not allowed to take up their posts.
9, it is forbidden to work without a license, it is forbidden to go to work after drinking, it is forbidden to speeding and illegal driving, it is forbidden to illegal and drunk driving.
10, all construction machinery and equipment and aerial work equipment should be inspected regularly, with the signature record of the safety officer to ensure that they are always in good condition, and unqualified machinery and equipment and labor protection articles are strictly prohibited.
1 1. Party B must organize the formulation of emergency plans for production safety accidents during the implementation of this project according to the characteristics of this project; In case of safety accidents, it is necessary to report to relevant departments in a timely manner in strict accordance with the State Council's "Provisions on the Investigation of Administrative Responsibility for Extraordinary Safety Accidents" and other relevant regulations, adhere to the principle of "three-no pass" and severely deal with those responsible.
12. Due to Party B's poor management, no matter whether there is a safety accident inside or outside the mine, resulting in casualties and property and equipment losses, Party B shall take full responsibility, take the initiative to deal with the aftermath, and bear all economic compensation responsibilities. If Party B mishandles or shirks its responsibilities and causes adverse effects and losses to Party A, Party A has the right to impose economic penalties on Party B until the Contract is terminated.
Four. Liability for breach of contract:
If a safety accident is caused by Party A or Party B's breach of contract, the breaching party shall bear corresponding economic and legal responsibilities.
5. Any disputes arising from the execution of this contract or matters not covered in this contract shall be settled by both parties through consultation. If negotiation fails, both parties shall apply to the local arbitration institution for arbitration or bring a lawsuit to the court.
This contract is made in quadruplicate, with each party holding two copies.
Party A: _ _ _ _ Legal Representative of Open-pit Coal Mine: _ _ _ _ _ _ _
Manager: _ _ _ _ _ _ _
Party B (seal): _ _ _ _ _ _ Legal representative of Construction Engineering Co., Ltd.: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Date of signing the contract: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Engineering Contract Template General Edition 4
Construction (contracting) unit: (hereinafter referred to as Party A)
Construction (contracting) unit: (hereinafter referred to as Party B)
Party A, as a unit, entrusts Party B to undertake the basic earthwork task of the Expo project in accordance with the provisions of the People's Republic of China (PRC) Contract Law and the principles of equality, voluntariness, mutual benefit and good faith. Party A and Party B reach an agreement on relevant matters, conclude this contract and strictly abide by it.
I. Overview
Project name:
Project location:
Two. Scope: Earthwork below 0.00. (including mechanical excavation, earth moving and pile section excavation)
Third, the construction cycle
20 _ _ _ _ _ _ _ _. Within the total calendar days of the contract period, the period will not be postponed except for the following circumstances:
1, force majeure.
2. Party A changes the scheme and construction drawings, which affects the construction.
Fourth, the project price and project payment. 13400m3, and the comprehensive unit price is calculated as /m3 (the above price includes all expenses incurred by Party B in the whole earthwork construction, such as coordination, spoil, taxes and fees, and is a lump sum price, which will not be adjusted during the construction period). After the excavation and transportation are completed, Party A shall pay in cash after passing the acceptance.
1. After the earthwork is completed and accepted by Party A, Party B shall provide the tax invoice approved by the tax authorities for settlement, otherwise, Party A has the right to refuse payment.
Verb (abbreviation of verb) Quantity: 3400m3.
Six, quality requirements
1. Excavation in earthwork (including earthwork excavation and earthmoving, etc. ), all construction procedures of Party B must be carried out in accordance with the construction quality requirements of the project department.
2. All construction procedures must be checked by Party A's project department, supervision, construction unit and relevant personnel, and the next construction procedure can only be carried out after Party A signs it.
3. If rework is caused by Party B during construction, Party B will unconditionally handle it as soon as possible according to Party A's work requirements. For the losses caused to Party A, Party A has the right to claim compensation from Party B according to relevant laws and regulations.
4. Party B must return the soil on _ _ _ _ _ _ _ _ _ _ _.
Seven. Party A's responsibilities
1. Party A shall pay the project payment according to the contract.
Eight. Party B's responsibilities
1. Obey the supervision, command and management of Party A. ..
2. Carry out the construction according to the drawings and Party A's guidance, ensure the quality and quantity, and finish it on schedule.
3. Carry out safe and civilized construction to ensure construction safety. Before the contract comes into effect, Party B shall pay the security risk deposit of RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Nine, other terms:
1, liquidated damages: If the contract is terminated due to Party A's reasons, Party A shall pay Party B _ _ _ _ _. If the Contract is terminated due to Party B's reasons, Party B shall pay Party A RMB as liquidated damages.
2. Party B shall take full responsibility for the industrial accidents during the construction period.
3. For matters not covered, Party A and Party B may sign supplementary terms and agreements through negotiation, which have the same legal effect as this contract.
4. Dispute settlement: In case of any dispute between the two parties, Party A and Party B shall settle it through consultation; If negotiation fails, a lawsuit can be brought to Huangchuan County People's Court.
5. This contract shall come into effect as of the date of signing. The original of this contract is in duplicate, each party holds one copy, which shall come into effect after being signed by both parties.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Engineering Contract Template General Edition 5
Employer: (hereinafter referred to as Party A)
Employer: (hereinafter referred to as Party B)
Party A entrusts Party B to build the existing steel structure workshop project. In order to define the division of labor, assist each other, ensure the quality and quantity, and complete the construction task on schedule, the following contract is signed by both parties through consultation:
Article 1. Project name:
Article 2, the project site:
Article 3. Project overview: the workshop area is about.
Article 4, project contracting form and construction basis:
1. Form of contract: manufacturing and installing the steel structure of the factory building.
2. Scope of contract: steel structure: fabrication and installation of steel structure of workshop. Including embedded parts, steel columns, steel beams, sandalwood strips and colored steel tiles on the wall.
3. Construction basis: According to Party A's requirements (construction drawings, engineering technical contact list, relevant specifications, material model specifications, drawings, project budget table).
Article 5. The materials must be the national standard materials of regular state-owned factories, and the material inspection report is attached. Project quality: According to Party A's requirements, meet the requirements of drawings and relevant construction specifications, and the project quality reaches the qualified standard.
Article 6 Duration: The duration of the project is days. In case of irresistible factors such as rain and power failure, or delay caused by Party A, the construction period shall be postponed according to the actual number of days.
Article 7, the project cost:
1, project cost:
A, steel roof acceptance for _ _ _ _ yuan /m2.
B supporting facilities shall be settled according to the actual quotation (excluding tax).
2. If there is any increase in the project, both parties will confirm to increase the project cost.
Article 8. Payment terms:
After the contract is signed, Party A shall make payment according to Party B's project progress, and reserve 5% of the total project cost as quality deposit after the completion acceptance, which shall be paid within one month after the project acceptance.
Article 9, construction:
1. Before construction, Party B shall formulate safety measures and assume the responsibility for construction safety. In the process of construction, we must strengthen safety awareness education, and supervise the implementation at the site, so as to buy enough personal accident insurance for the site construction personnel. In case of safety accident, Party B shall be responsible, and Party A shall not bear any responsibility.
2. Party A shall provide water and electricity for site installation and construction free of charge. Party A is responsible for leveling the roads and workshop floors entering the construction site for Party B's transport vehicles to enter.
3. Party A shall designate the on-site representative for Party B, and designate the on-site representative as the designated on-site representative to sign relevant engineering contact sheets, visa sheets, settlement sheets, etc. And handle project-related matters on behalf of all parties.
Article 10 Acceptance:
1. Acceptance basis: according to the construction drawings and construction change notice provided by Party A at the time of signing the contract and the current national codes and standards.
2. The engineering quality grade is qualified.
3. Party A shall organize the acceptance within one week after the completion of the steel structure project of this project.
Article 11 Warranty time and content: The warranty period of the steel structure of this workshop is years, counting from the date of acceptance. During the warranty period, Party B shall be responsible for rework and repair of quality problems caused by Party B's construction, and Party A shall be responsible for quality problems and damage caused by natural disasters (such as earthquake and typhoon) or man-made damage not for Party B's responsibility.
Article 12 Legal liability
1. During the construction period, Party A shall be responsible for the losses caused by Party A, and Party B shall be responsible for the accidents caused by Party B's violation of the safety system and operating procedures.
2. Party B must carry out the construction according to the time stipulated in the contract, and ensure that the tasks are completed on time, with good quality and quantity. In case of quality problems due to Party B's delayed working hours, Party B shall be responsible for the losses caused thereby.
3. This contract is legally established and legally binding. If there is any dispute in this contract, Party A and Party B shall settle it through consultation in a timely manner in the spirit of seeking truth from facts. If negotiation fails, either party may apply to the contract management authority for arbitration or bring a lawsuit to the people's court.
Article 13 This contract is made in duplicate, one for each party. If there are any unfinished matters, both parties shall supplement them separately after consultation.
Party A (seal)
Signature of representative:
Party B: (Seal)
Signature of representative:
20___ _ _ _ _ _ _ _
Five articles related to the general version of the engineering contract model;
★ General Edition of Engineering Contract Model 5 articles
★ 5 engineering contract samples.
★ 4 templates for general version of engineering contract.
★ 5 model engineering service contracts
★ 5 copies of construction project contract model
★ Five construction agreements
★ 5 templates of common engineering construction contracts.
★ Engineering construction contract 202 1 5 samples.
★ Five standard versions of the construction contract in 2022.
★ Five model construction contracts for building projects