2020 electric power construction contract agreement (I) Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _
Project name: _ _ _ _ _ _ _ _
Project location: _ _ _ _ _ _ _ _
Planned working hours: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
As one of the contractors in charge of power grid projects, Party A has established a labor contract relationship with Party B for the specific needs of some projects. In order to clarify the safety responsibilities of both parties to the labor contract, ensure the safety of engineering construction and prevent accidents, Party A and Party B have reached the following agreement through consultation:
I. Party A's Safety Responsibility
1. According to _ _ _ _ issued by _ _ _ and _ _ _ _ issued by _ _ _ _ _, Party A is responsible for reviewing the construction safety qualification of the project contracted by Party B.. Review the construction business license and construction qualification certificate issued by relevant government departments, the qualification certificate of legal representative (organization code certificate), the construction resume held by Party B, and the configuration of relevant project managers, responsible persons and technicians of the construction unit and the safety construction records in recent three years. After passing the qualification examination, Party A shall issue a safety construction qualification certificate to Party B in time.
2. Before the project starts, Party A shall make a comprehensive safety technical disclosure to Party B's responsible person and engineering technicians, and have complete records or materials. Safety technical disclosure In accordance with the provisions of _ _ _ _ _ _, please make a comprehensive safety technical disclosure to the responsible person of the contractor, engineering and technical personnel and safety supervision personnel before commencement.
3. Party A is responsible for reviewing the technical quality of project construction leaders, engineering technicians and workers. Review and confirm the qualifications of the project working ticket issuer and working person in charge.
4. Party A is responsible for reviewing the organization and construction design of the project, and formulating safety measures in advance according to Party B's operation requirements in dangerous power production areas.
5. Party A is responsible for inspecting and supervising the implementation and execution of _ _ _ _ _ _ in the safety management of the construction unit.
6. Party A shall inspect the safety and quality of the engineering institutions on June 5438+05 every month, and conduct random checks from time to time. Focus on the on-site safety management and safety measures such as special operations personnel holding certificates and on-site safe electricity use. In particular, check the safety situation at the site, fill in the safety inspection notice in time for the problems found in the inspection, issue the rectification notice for serious problems and impose corresponding economic penalties.
7. Use _ _ _ _ to check and evaluate the management of the project department and the construction site, and diagnose and judge Party B's safety, health and environmental management behavior accordingly.
8. Other safety and labor protection matters agreed by Party A in this Agreement.
II. Party B's Safety Responsibility
1. Seriously implement the laws, regulations, rules and regulations of the state and the electric power industry on safety in production and occupational safety and health, and formulate detailed implementation rules according to the actual situation, but it shall not conflict with the provisions of the higher authorities and shall not lower the safety standards.
2. Party B shall establish and improve the safety management organization and implement the post safety production responsibility system according to the relevant regulations of the state and the power industry.
3. Workers who recruit, employ and change jobs must go through three-level safety education, emergency rescue training and professional technical training, and put on record after passing the examination, and can only enter their production site after being examined and approved by Party A. Party B shall conduct safety technical disclosure, safety education and safety publicity for the construction personnel, and strictly implement the safety technical plan.
Personnel who belong to special operations and dangerous operations stipulated by the state must receive professional training at the same time and hold the operation certificate issued by the competent government department before taking up their posts.
4. The project department and the construction site shall be arranged according to the provisions of _ _ _ _ _ _, and various safe and civilized construction management systems and emergency plans shall be formulated, and Party B shall be required to be equipped with sufficient safety appliances and safety books. Clear signs must be set up on the construction site, indicating the construction permit approval number, project name, names of all contractors, project management organization chart, project construction objectives (safety, quality and construction period) and main management systems. The site operation area is clearly marked, and special construction equipment storage places, material storage stations and garbage storage points are set up. The construction unit is responsible for protecting the signs on the construction site.
5. Abide by the labor discipline and rules and regulations on site, and strictly implement relevant regulations when entering the construction site. All personnel entering the construction site should wear work permits to prove their identity and ensure safe construction. Party B shall ensure that the safety protection facilities and safety warning signs on the construction site are complete.
6. According to the actual construction situation, Party B shall do a good job in wind and flood prevention, heatstroke prevention and cooling, fire prevention, electric shock prevention, falling prevention, etc. , safety measures should be in place.
7. Party B shall formulate corresponding labor protection articles distribution standards according to national laws and regulations on safety production and labor protection and relevant health regulations; Provide construction personnel with personal labor protection articles that meet the safety and health requirements of this type of work; According to the production characteristics of different posts, provide safety protection articles and safety appliances, and guide, supervise and check their use. All kinds of safety facilities and labor protection devices on the construction site must be inspected and maintained regularly to eliminate hidden dangers in time and ensure their safety and effectiveness.
8, all personnel entering the construction site dress must comply with the provisions of _ _ _ _. Construction personnel shall wear various safety protection tools as required.
9. Use and management of safety appliances, safety protection facilities, hand-held power tools and electrical equipment. Must strictly implement the relevant provisions of the state and industry, must have the factory certificate, can be used after inspection, and establish the distribution, use and management system and ledger.
10. Party B shall use _ _ _ _ to conduct self-inspection and self-evaluation on the project department, construction site and team management.
1 1. Party B has a labor contract relationship with Party A, and it is strictly forbidden for Party B to subcontract the construction project.
12. Take legal responsibility for the authenticity of all documents and materials provided.
13. Other matters related to safety and labor protection. It shall be stipulated by Party B in the agreement.
Three. Rules that Party A and Party B shall abide by.
After signing the construction safety agreement, Party A and Party B must strictly abide by the laws and regulations of the state, the rules and regulations of the electric power industry and the regulations of the electric power enterprises on infrastructure installation. * * * Abide by _ _ _ and other relevant regulations.
Four. Default handling
During the validity period of the agreement, if there is any safety accident or potential safety hazard caused by violation of any of the above terms, the assessment will be strengthened in strict accordance with the relevant provisions of _ _ _ _ _ _, and the reward and punishment system will be strictly implemented for the construction unit that violates on-site safety management or causes engineering quality accidents. Rewards and punishments should be reported to _ _ _ _ for the record.
Verb (short for verb) others
1. Party A shall provide Party B with necessary construction technical data and try its best to provide convenient construction conditions.
2. In the process of construction, if Party B suffers from accidental personal injury or death for which Party B is responsible, Party A shall do its utmost to help the wounded and people in danger in the spirit of humanitarianism, but all expenses required shall be borne by Party B. ..
3. According to the _ _ _ _ _ agreement signed by both parties, Party B shall pay _ _ _ _ _ _ _ _ _ deposit, which shall be managed in a special account. Party A shall punish Party B for violating site safety regulations and notify the other party in writing. After the completion of the project, it shall be returned to Party B after deducting the total liquidated damages, and the insufficient part shall be made up by Party B.. .
4. The validity period of this agreement is from _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
5. This Agreement is made in duplicate, one for each party, and shall come into effect after being signed and sealed.
Party A: _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2020 electric power construction contract agreement (II) Party A: _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _
According to the Contract Law of People's Republic of China (PRC), the Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, combined with the actual situation of this project, Party A and Party B reached the following agreement on the construction of this project through friendly negotiation.
Article 1 Project Overview and Contract Scope
1. Project name: _ _ _ _ _ _ _ _ _ _.
2. Project location: _ _ _ _ _ _ _ _ _ _ _.
3. Contract scope: _ _ _ _ _ _ _ _ _ _ _ _.
4. Contracting method: _ _ _ _ _ _ _ _ _ _ _.
The second construction section
1. The total number of days in the project cycle is _ _ _ _ _. That is to say, starting from _ _ _ _ _ _ _ _
Article 3 Work and responsibilities that Party A shall undertake
1. Party A is responsible for providing Party B with the connection points of materials, stacking places of machines and tools and construction water and electricity at the construction site free of charge.
2. Party A has the responsibility to pay the project payment in time according to this contract.
Article 4 Work and responsibilities that Party B shall undertake
1. After this contract comes into effect, Party B shall send technicians to the site to make preparations before construction. In the construction site investigation, it is necessary to find out all kinds of underground communication, water supply, gas transmission, oil transmission, electricity, lighting, traffic signals, chemical industry, heating and drainage pipelines, etc. Find and collect pipeline data, and find with the help of pipeline instrument. Mark the position, depth and direction of the pipeline on the ground with paint. Use drawing paper to draw the pipeline distribution map and section map for later use; All accidents and losses caused by Party B in the construction process shall be borne by Party B. ..
2. Party B shall conduct a preliminary geological survey on the construction site to find out the stratum structure, geological composition and buried depth of groundwater. At present, drilling and pipe laying are limited to the construction of soil layer, sand layer and silt layer. Other drilling tools must be used in the construction of sandy pebble layer, bedrock and stone backfill layer, and certain conditions must be met.
3. Water source is a necessary condition for drilling and pipe laying. It is required to find out the water source of the construction site and prepare the water before construction.
4. Be responsible for handling all government approvals, approvals and relevant laws and regulations related to this pipe jacking project, and Party B shall be solely responsible for all responsibilities arising therefrom.
5. Party B shall be responsible for the equipment and personal safety within the construction scope, and do a good job of anti-theft and fire prevention. If any personal injury or death is caused by Party B, Party B shall be responsible for it.
6. Strictly abide by the relevant provisions of the electric power department, and do not open or operate the electrical equipment of the electric door without permission. In case of violation, Party B shall bear all responsibilities and losses.
7. Party B shall actively cooperate with Party A to carry out phased project quality acceptance and make records.
8. Party B shall guarantee the quality of the project, carry out the construction in strict accordance with the rules and regulations, construction specifications and technical requirements of relevant administrative departments, and complete the project contents on schedule.
9. Party B shall carry out civilized construction, so as to clear the site after work, and the cost has been included in the total project price.
Article 5 Project Price and Payment
1, the lump sum price of this project, the unit price is _ _ _ _ _ yuan/meter, and it shall be settled according to the straight line length in the horizontal direction.
2. Within three days after the completion and acceptance of the project construction, Party A shall pay the project payment to Party B in cash.
Article 6 Acceptance of project quality
1. Acceptance method: Party B shall provide Party A with the acceptance report and material quality inspection certificate of this project. The project shall meet Party A's requirements for smooth lines, and Party B shall be responsible for the maintenance and replacement of unqualified projects, and the expenses shall be borne by Party B. If there are irreversible obstacles in the process of pipe jacking construction, the requirements for power pipe threading cannot be met smoothly after many efforts, and Party B cannot ask Party A to pay any project funds when he leaves unconditionally.
2. Acceptance time: Party A shall organize the completion acceptance within 2 days after receiving Party B's completion report. If the completion acceptance is not organized within the time limit, the project quality shall be deemed as all qualified.
Article 7 Liability for breach of contract
If one party terminates or dissolves this contract without authorization, or fails to fully perform its obligations as agreed in the contract, it shall bear the liability for breach of contract according to law and compensate the other party for all economic losses caused thereby.
Article 8 Ways to settle disputes
In case of any dispute arising from the performance of this contract, Party A and Party B shall settle it through negotiation on the principle of mutual understanding and mutual accommodation. If negotiation fails, either party may bring a lawsuit to the people's court where the project is located.
Article 9 Matters not covered in this Contract
It shall be settled by both parties through consultation. Supplementary contracts and supplementary agreements reached through consultation have the same legal effect as this contract.
Article 10 Others
This contract shall come into effect as of the date of signature and seal by both parties.
This contract is made in duplicate, one for each party.
Party A (seal): _ _ _ _ _ _ _ _ _ _ _ _
Party B (seal): _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2020 electric power construction contract agreement (III) Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Party B: _ _ _ _ _ _ _ _ _ _ _
Party A entrusts Party B to implement the _ _ _ _ _ _ _ _ project. In order to clarify and safeguard the responsibilities and rights of Party A and Party B, this contract is signed for the construction, installation and management of this project in accordance with _ _ _ _ _ _ _ _ and other relevant laws and regulations, based on the principles of equality, voluntariness and fairness:
I. Project Name: _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Two. Project location: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Three. Contract method: _ _ _ _ _ _ _ _ _ _ _ _.
Four. Project cost: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Verb (abbreviation of verb) project content and scope: high-voltage line erection; Transformer installation; High and low voltage switchboard and metering device in distribution room. Dismantle the original installed transformers and high-voltage poles; The utility pole frame for extending high-voltage lines and its installation; Demolition, relocation and installation of power distribution room.
VI. Contract Term: Party A shall notify Party B to enter the site for construction within seven working days.
7. Quality standard: This project shall be constructed in strict accordance with the relevant national technical regulations for electric power installation engineering, and shall be reported to the competent department of electric power for acceptance after the project is completed.
Eight. Payment of project funds: After the project is completed and delivered to Party A and Party B for normal use, Party A shall pay the project funds in one lump sum.
Nine. Responsibility of Party A: Party A must tidy up the construction site three days before notifying Party B to start work, remove obstacles, ensure the smooth flow of construction vehicles, and ensure that the construction site has the conditions for starting work, and continue to be responsible for solving the above-mentioned omissions after starting work. Pay the project payment according to the agreed time, otherwise it will be regarded as a breach of contract. If Party A fails to complete the project according to the above contract, which affects the construction, the project will be postponed accordingly.
X. Party B's responsibilities: responsible for the laying of power lines and the procurement and installation of related materials and equipment to ensure the quality of the project. Ensure the progress of the project, ensure that it is completed on schedule with good quality and the electricity consumption is normal.
1 1. Safe construction: Party B shall take strict safety protection measures and operate in strict accordance with relevant regulations. During the construction period, if a safety accident is caused by Party B's ineffective safety measures, Party B shall bear all expenses, and the responsible party shall bear the responsibilities and related expenses. In case of force majeure accidents, Party A and Party B shall bear the engineering losses and delays through negotiation.
Twelve. Ways to settle contract disputes: During the execution of this contract, if Party A and Party B have different opinions on the relevant clauses of this contract or have other disputes, they shall be settled through consultation. If negotiation fails, the parties may apply to the relevant arbitration organ for arbitration or bring a lawsuit to the court for settlement.
Thirteen. Original and duplicate copies of this contract. With the same legal effect, Party A and Party B each hold one original and one copy. Other matters not covered shall be supplemented by both parties through consultation.
Party A (seal): _ _ _ _ _ _ _ _ _ _ _ _
Party B (seal): _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _