Simple contract

Selected Five Sample Simple Contracts

With the growing understanding of the law, the use of contracts is becoming more and more widespread, and they harmonize the relationship between people and people, and between people and things. Do you know what the main content of the contract? Here is my simple contract for you to organize 6, for your reference, I hope it can help the friends in need.

Simple Contract Part 1

Party A

Party B

Month and year:

For the purpose of establishing labor relations, clear rights and obligations, according to the Chinese People's *** and the State of the Labor Law, the Labor Contract Law, based on equality and voluntariness, consensus. Conclude this contract.

Article I term of the labor contract

The term of this contract from the date of January to the date of January. Among them, the probationary period for the year from the date to the end of the month.

Article 2 work content and workplace

Party A, according to the needs of the work, arranged for Party B in the workplace, Party B's work tasks for , the workplace is. By mutual agreement, Party A can transfer Party B's work type or position.

Article III labor compensation

Party B according to the provisions of Party A to complete the work of the task, Party A pay wages on the day of each month, the agreed labor compensation of yuan / month, the actual monthly payment of yuan / month, the remaining part of the end of the year and bonuses together, which the probationary period of the remuneration for the work of yuan / month.

Article 4 Termination and termination of labor contract

The termination of the labor contract by both parties shall be handled in accordance with legal procedures.

Article 5 working hours and rest and vacation, social insurance, labor protection, labor conditions and protection against occupational hazards shall be implemented in accordance with laws, regulations, rules and other provisions.

Article 6 Party A arranges for Party B to travel once a year, such as Party B after 2 years of work, in addition to national holidays, another 10 days of paid vacation per year.

Article VI other outstanding matters in accordance with the national and local current regulations, or through consultation in the form of an annex to the agreement.

Article VII of this contract, each party to sign a copy.

Signature of Party A (seal)

Signature of Party B (seal)

Signing Time: Month, Year

Simple Contract Part 2

Party A:

Party B:

Date of Signing: Month, Year

Party A (Employer)

Name of the Employer Name of the Employer Residence of the Employer Legal Representative or Person in Charge Party B (Laborer)

Name Sex Gender Date of Birth Educational Level Contact Information Place of Domicile Actual Place of Residence Resident Identity Card No. Party A and Party B sign this contract on the basis of lawfulness, fairness, and honesty, voluntarily and by consensus in accordance with the Law of the People's Republic of China (PRC) on Labor Contracts and the provisions of the relevant laws, rules and regulations, and abide by the terms and conditions set out in the contract. The terms and conditions listed herein.

First, the duration of the labor contract

Fixed-term labor contract from the date of the year to the date of the year. It is also agreed that the probationary period shall be from January, 2010 to January, 2011.

Second, the work content and workplace

(a) Party B, according to Party A's requirements, after consultation, engaged in work. Party A may, according to the needs of the work and the results of the assessment of Party B's performance, in accordance with the principle of reasonable good faith, by consensus with Party B or by law to change Party B's work position.

(2) The content and requirements of the work arranged by Party A for Party B shall be in accordance with the labor standards stipulated by the State and the rules and regulations formulated by Party A in accordance with the law and made public. Party B shall fulfill the labor obligations in accordance with the work content and requirements arranged by Party A.

III. Working Hours and Rest and Vacation

(1) Party A and Party B have agreed to implement the following clauses: Party B's working hours shall not exceed 40 hours per week on average, Party A shall implement the hourly working day, and Party A shall ensure that Party B rests at least one day per week.

(2) Party A strictly observes the legal working hours, controls overtime work, and ensures Party B's rest and physical and mental health. Party A must arrange for Party B to work overtime due to work needs, should be agreed with the labor union and Party B consultation, and give Party B compensatory time off or pay overtime wages in accordance with the law.

Fourth, labor compensation

Party A shall pay Party B's wages in monetary form at least once a month, and shall not withhold or default on Party B's wages without reason. Party B in the legal working hours or the labor contract signed in accordance with the law to provide normal labor during the working hours, Party A to pay wages to Party B shall not be less than the local minimum wage standard.

(a) Party A promises to pay wages on the day of each month.

(b) Party B's salary during the probationary period is RMB per month.

(3) By consensus between Party A and Party B, Party B's salary and remuneration shall be implemented according to the following terms:

A. Party B's salary and remuneration shall be determined in accordance with Party A's rules and regulations formulated by law in the internal wage distribution, and the monthly salary shall be determined to be RMB according to Party B's work position.

B. Party B shall implement the internal wage distribution method combining basic wage and performance wage, and Party B's basic wage shall be determined as RMB per month, and its wage shall be adjusted according to the internal wage distribution method in the future; and the performance wage shall be determined according to Party B's work performance, labor achievement and actual contribution in accordance with the assessment of the internal distribution method. Labor Contract Simplified Version Download

(d) Party B's wages for overtime work shall be calculated on the basis of the wage standard agreed upon in item (c) of this Article, which shall not be lower than the wage standard agreed upon in item (c) of this Article.

(E) Party B is entitled to wages during paid leave (e.g., marriage leave, funeral leave, annual leave, etc.) in accordance with the law.

(F) Party B in the event of industrial accidents or occupational diseases. , Party A shall be responsible for timely treatment, or to provide possible assistance, and within the prescribed time, to the administrative department of labor security to apply for recognition of work injuries, for Party B in accordance with the law for the identification of labor capacity, and for Party B to enjoy the necessary obligations to perform the treatment of work injury insurance.

Sixth, labor protection, labor conditions and protection against occupational hazards

(a) Party A must provide Party B with labor safety and health conditions in accordance with state regulations and the necessary labor protective equipment, arrangements for Party B to engage in exposure to occupational hazards of the work, should be regularly for the occupational health examination of Party B, and before Party B left the workplace to carry out occupational health checks.

(b) Party A shall provide protection for Party B in accordance with the state regulations on special protection for female workers and underage workers.

(C) If Party B is sick or injured not due to work, Party A shall implement the provisions on medical treatment period in accordance with the state.

Seven, the two sides agreed by consensus, the following terms of the labor contract simple version download

Nine, other matters

This contract is not exhaustive, in accordance with the state, the province and the city of the implementation of the relevant provisions, there is no provision, through the two sides of the equal consultation to solve the problem.

This contract shall not be altered.

This contract is in duplicate, A and B each party.

Signature of the legal representative or person in charge: Signature of Party B:

Seal of Party A:

Date of Signature: Date of Signature:

Simple Contract Part 3

Name of Party A (employer):

Residence:

Legal representative (principal person in charge):

Telephone number:

Name of Party B (worker). Laborer) Name:

Domicile Location:

Current Residence Address:

Identity Card Number:

Contact Phone Number:

According to the "People's Republic of China*** and the State of Labor Contract Law" and the provisions of the relevant laws and regulations, the A and B follow the lawfulness, fairness, equality and voluntariness, consensus, and honesty and trustworthiness of the principle of the conclusion of the present contract.

Article I of this contract period type (fixed term / open-ended / to complete certain work tasks for the period), from the date of the year until the end. Among them, the probationary period (with/without), from the date of the year until the date of the year.

Article 2 Party A arranges Party B to engage in the work of , the workplace is .

Party B shall, in accordance with the content and requirements of the work arranged by Party A, conscientiously fulfill the duties of the post and complete the work on time.

Article 3 Party A arranges Party B to implement the working hours system (standard working hours/comprehensive calculation of working hours/indeterminate time).

Article 4 Party A pays Party B's salary in full and on time in the form of cash or transfer before the day of each month, and the salary (hourly/piecework) is standardized. Among them, the wage rate during the probationary period.

Article 5 Party A shall pay social insurance premiums for Party B in accordance with relevant national and local regulations. Party A shall be responsible for withholding and paying the portion of Party B's burden.

Article 6 Party A shall provide Party B with safety training and labor safety and hygiene conditions and necessary labor protective equipment in accordance with national regulations. Arrangements for Party B to engage in occupational hazards of the work, should be regularly for Party B health checks. Party B in the labor process should strictly abide by the system specifications and operating procedures.

Party B in the event of work-related injuries, Party A shall take timely measures to enable Party B to get treatment, and in accordance with the provisions of the "Regulations on Work-Related Injury Insurance", to pay the appropriate treatment of work-related injuries.

Article 7 Party A and Party B shall perform, change, cancel and terminate this contract in accordance with the relevant provisions of the Labor Contract Law. Party A shall pay Party B economic compensation in accordance with the relevant provisions of the Labor Contract Law.

Article 8 Party A unlawfully terminate or terminate this contract, Party B requires the continuation of this contract, Party A shall continue to perform; Party B does not require the continuation of this contract or this contract has been unable to continue to perform, Party A shall, in accordance with the law, the economic compensation standard of two times the compensation to be paid to Party B.

Article 9 Other matters agreed by the parties:

__________________________________________________

Article 10 The unfinished matters of the labor contract shall be carried out in accordance with national and local relevant regulations.

Article 11 This contract shall come into effect on the date when it is signed or sealed by both parties. This contract shall be in duplicate, and each party shall execute one copy.

Party A (official seal) Party B (signature)

Legal representative (principal person in charge)

or proxy signature

Signature date: Signature date:

Simple Contract Part 4

Party A (employer) Name:

Legal representative:

Address:

Contact phone number:

Party B (laborer) Name:

Resident Identity Card No.:

Current Residential Address:

Contact No.:

Party A (Employer): ______________ Responsible Person:

Address:

Party B (laborer): ___________ Gender: _____ Year of birth: _____________

Home address: ______________________________ Current residence: __________________________________________________

Emergency contact person and his contact information:

A and B agree to enter into this labor contract on the basis of equality and voluntariness and consensus.

Article 1 The labor contract between A and B shall be for a period of years, starting from the day of January to the day of January. This includes a probationary period of months, from ____ month ____ to ____ month ____ of ____ year.

Article 2 According to Party A's work needs, Party B agrees to engage in ________ post (type of work) work, the workplace __________ , the implementation of standard working hours system.

Article 3 Party B wages include basic wages, post wages and assessment of wages, Party B's trial period of the basic wage rate of ______ yuan / month. Party B's basic salary after the probationary period is _______ yuan / month, Party A according to Party B's position, attendance, assessment, rewards and punishments accounted for the post salary, performance appraisal salary.

Article 4 Party A shall pay social insurance for Party B according to law, and provide Party B with necessary labor tools and labor protection.

Article V. The termination of this contract is based on the Labor Law, Labor Contract Law and other relevant laws and regulations.

Article 6 Party B, when signing this contract, is willing to comply with all the rules and regulations implemented by Party A, and is willing to comply with any violation of these rules and regulations in accordance with the relevant provisions.

Article 7 Party B undertakes to provide Party A with personal information, the former unit of the certificate of separation, educational certificates and other information, data are true and lawful and effective, otherwise Party A has the right to unilaterally terminate this contract on the grounds of Party B fraud.

Article VIII of this contract in duplicate, since the two sides signed or stamped to take effect, Party A and Party B each sign a copy of the contract, each contract has the same legal effect.

(No text below)

Party A (seal) Party B (signature):

Year ____ Month ____ Day ____ Month ____ Day

Simple Contract Part 5

Contractor (Party A): Business License No.:

Contracting Representative: ID Card No.:

Contractor (Party B): Business License No.: Business License No.: Contracting Representative.

Contracting representative: ID card number:

In accordance with the provisions of the Contract Law of the People's Republic of China (PRC) and relevant laws and regulations, combined with the characteristics of the construction of plant decoration works, the two sides, on the basis of consensus, have reached the following agreement on the matters relating to the contractor's plant decoration works (hereinafter referred to as the works):

Article I Project Overview

(a) Project location: _____________________________________.

(b) The content of the project and practice (see the plant decoration project construction project budget table).

1, the contractor contractor, materials;

2, the contractor contractor, part of the package (contractor to provide decorative materials table), the contractor to provide some of the materials (contractor to provide decorative materials table);

3, the contractor contractor, contractor package materials (contractor to provide decorative materials table).

(D) The duration of the project _______ , the date of commencement _______ of ____ month ____ , the date of completion ______ of ____ month ____ .

(E) contract price: the contract cost of the work is (upper case): _______________________ yuan, lower case: ______________ yuan (see plant

renovation works quotation).

Article 2 Project Supervision

If project supervision is practiced in this project, the Contractor will sign a separate Project Supervision Contract with the Supervision Company and notify the Contractor of the Supervision Engineer's name, unit, contact information and the Supervision Engineer's duties.

Article 3 Construction Drawings

The two sides agreed that the construction drawings shall be provided in the following ______ ways:

(a) The contractor shall design and provide the construction drawings on its own, and the drawings shall be in duplicate, with one copy for each of the contractor and the contractor (for details, please refer to the design drawings of the industrial plant decoration project);

(b) The contractor is commissioned by the contractor to design construction drawings, drawings in duplicate, the contractor, the contractor, each one (see the industrial plant decoration project design drawings), the design fee (capital) ____________, paid by the contractor (this cost is not included in the price of the project).

Article 4 Obligations of the Contractor

(a) Create conditions for the Contractor to enter the construction site ________ days before the commencement of the construction work, with the principle of not affecting the construction work;

(b) Provide the water source and power source during the construction period;

(d) not to tear down the indoor load-bearing structure, such as the need to demolish the original non-load-bearing structure of the building or equipment pipeline, is responsible for the relevant departments for the appropriate approval procedures;

(e) during the construction period, the contractor still need to partially use the plant, is responsible for the security of the construction site and fire prevention and other work;

(f) participate in the quality of the project and the progress of the construction of the supervision, is responsible for the materials, completion inspection and inspection of the construction of the building, and the construction of the building.

(f) Participate in the supervision of the quality and progress of construction, responsible for the entry of materials, completion inspection

Acceptance.

Article 5: Obligations of the Contractor

(a) Strictly implement the safe construction practices, fire prevention regulations, construction specifications and quality standards during the construction, and complete the project on schedule and with quality assurance;

(b) Strictly implement the regulations on the management of the construction site, and do not disturb the people and pollute the environment;

(c) Protect the furnishings in the original plant. (C) to protect the original plant furnishings, to ensure that the plant up and down the water pipe smooth;

(D) to ensure that the construction site is clean, responsible for cleaning the construction site after the completion of the project.

Article VI Quality Requirements

(a) The project uses the main material varieties, specifications, names, recognized by both parties.

(b) project acceptance criteria, the two sides agreed to refer to the "building decoration and renovation project quality acceptance specification" provisions.

(C) construction, Party A, such as special construction projects or special quality requirements, the two sides should confirm that the increase in costs, should be signed in a separate supplemental contract.

(d) All materials and equipment purchased by Party A, the quality of the product is the responsibility of Party A; the quality of construction is the responsibility of Party B. The quality of construction is the responsibility of Party B.

Article 7 Payment

(a) Once the contract is signed, Party A shall pay % of the project materials and __% of the construction cost; when the progress of the work period is more than half (___ year ___ month ___), Party A shall pay a second __% of the construction cost. The remaining __% of the final payment will be settled after Party A accepts the completion of the project. (Note: the construction cost includes labor cost) Party A pays off the project price, see the annex to this contract "plant decoration project settlement table", Party A does not pay on the due date is a breach of contract, Party B has the right to stop the construction. Acceptance of the project price is not settled, shall not be delivered for use.

(b) project construction, such as project increase or decrease or the need for change, see the annex to this contract, "plant decoration project change table", the two sides should sign a supplemental contract, and Party B is responsible for the issuance of the construction of change orders, notify the person in charge of the construction site. The price of the increase or decrease of the project shall be settled on the spot.

(C) Party A did not pay the project price in advance according to the contract period, every day overdue according to the unpaid amount of the project price of % paid to Party B.

Article 8 Construction Period

(1) If the completion of the project is delayed due to Party B's reasons, Party A shall be paid ___% of the construction cost as penalty for breach of contract every day until the construction cost is deducted. If the completion is delayed due to Party A, for each day of delay, Party B shall be paid ___ yuan for lost labor as ___% of the labor cost in the price of the decoration project.

(ii) If the materials and equipment selected by Party A itself affect the quality and duration of the project due to unqualified quality, the reworking cost shall be borne by Party A. If the quality accident is caused by Party B's construction, the reworking cost shall be borne by Party B, and the duration of the project shall remain unchanged.

(C) in the construction, due to the quality of the project, the two sides disagreed and caused the stoppage, are not according to the missed or delayed work, both sides should take the initiative to request the relevant departments to mediate or arbitration department to coordinate and deal with the dispute as soon as possible in order to continue the construction.

(d) If rework is required during construction due to Party A's reasons, or if the construction period is delayed due to Party A's change of construction content, visas are required, and Party A shall bear all the construction costs, and Party B shall bear the responsibility for rework due to Party B's reasons, and the construction period shall remain unchanged.

(e) During the construction, Party A, without the consent of Party B, privately notify the construction personnel to change the construction content without authorization of the quality problems and delays caused by Party A's own responsibility.

Article IX Acceptance

(a) Project quality acceptance, see the annex to the contract, "Quality Acceptance Table for Plant Renovation", in addition to the hidden works need to be segmented acceptance, to be the end of all the projects, Party B organizes Party A to carry out the completion of the acceptance. Both sides for the project settlement and handover procedures.

(b) Party B notified Party A of the acceptance of the process and completion of the acceptance, Party A should come to the acceptance within seven days, the late party is considered as Party A automatically give up the right to acceptance, if there is any problem, Party A is responsible for their own responsibility. Party A move their own equipment into the construction of the acceptance area, as acceptance.

(c) Party A can not come to acceptance within the time limit specified by Party B, should promptly notify Party B, another date. However, Party A shall recognize the completion date of the process or project and bear the caretaker's fee and related expenses of Party B.

Article 10 Other Matters

(A) Party A

1. It must provide the house plan and water, electricity and gas line diagrams recognized by the property management department, or Party A shall provide the house plan and water, electricity and gas line diagrams, and conduct on-site briefings to Party B.

2, the second decoration works, should be vacated or partially vacated houses, remove obstacles affecting the construction. Can only partially vacate the house in the lingering furniture, furnishings, etc., must take the necessary protective measures, are required to go through the formalities with Party B and bear the costs.

3, if you really need to tear down, change the original building structure or equipment, pipelines, should be to the local housing department for formalities, and bear the costs. If you need to temporarily use common parts during construction, you should greet the neighbors.

(B) Party B

1, should take the initiative to show the business license, membership certificate or construction qualifications;