In today's society, people pay more and more attention to the contract, the use of the contract is more and more extensive, the signing of the contract is to reduce and prevent the occurrence of disputes is an important measure. Do you know what the main content of the contract? The following is my collection of cable laying labor subcontract model final (selected 5), for reference only, let's take a look.
Cable Laying Labor Subcontract Final Version 1Contractor: _____________
Contractor: _____________
According to the "Chinese People's **** and the State Contract Law" and the regulations on the contracting of construction and installation works and relevant provisions, combined with the specific conditions of the project, in order to clarify the rights and obligations of the two parties, sign this contract. .
Article I Project
(a) Name of the project: _________________
(b) Location of the project: _________________
(c) Content of the project: _________________
(d) Scope of contracting: _________________
Article 2 Project Cost (Budget or Estimate) RMB: _________________ Payment Method: _________________
Article 3 Construction Period
Article 4 Project Quality Standard and Warranty Period
Article 5 Responsibilities of Both Parties
(a) The responsibility of the contracting party: _________________
(b) The responsibility of the contracting party: _________________
Article 6 This contract shall be signed in duplicate, with one copy for each of A and B, and shall take effect from the date of signing.
Party A (seal): _________________ Party B (seal): _________________
Residence: _________________ Residence: _________________
Party A representative (signature): _________________ Party B's representative (signature): _________________
Phone: _________________ Phone: _________________
Fax: _________________ Fax: ________________
Zip Code: _________________ Zip Code: _________________
Place of Signature: _________________ Place of Signature: ________________
_____________ __________ __________ _____________ __________ __________
Cable Laying Labor Subcontract Final 2Offeror: _____________
Contractor: _____________
Signing Time: _________________
Signing Place: _________________
In order to ensure the quality of the _____________ construction, complete the construction task on schedule, and achieve the purpose of mutual benefit between the two parties, based on the Chinese People's ** and State Contract Law, the Chinese People's * and State Contract Law", "Chinese People's *** and State Construction Law" and other laws and regulations, the two sides amicably negotiated and reached a consensus on the construction project and entered into this contract.
I. Name of the project: ________________
II. Floor area (form of the project): ________________
III. Place of construction: _____________
IV. Duration: _________________ (a) Start of construction: _________________ on _____; (ii) Completion: _________________ on _____; (iii) Total **** duration of the contract period __________ days.
V. Form of contract: ______________
VI. Quality standard of the project: ______________
VII. Price of the project: _________________***counting RMB yuan.
VIII, payment: _________________ after the entry into force of this contract to pay the contract sum of _____%, counting __________ yuan; after the completion of the project and acceptance, pay the project price of _____%, counting __________ yuan; warranty ______ yuan, paid after the expiration of the warranty period.
IX. Warranty period: _________________ years.
X. Responsibilities and obligations of both parties
(a) the responsibility and obligations of the contractor
1, to provide the contractor with a good construction site, roads, water, power to meet the conditions for the start of work. Solve the four neighboring relations and disputes that need to be coordinated and solved by the contractor during the construction;
2, supervise and manage the quality of the construction process, the quality of materials, and supervise the progress of the project;
3, provide the contractor with the construction drawings, coordinate points, elevation points;
4, make payments to the contractor on time and carry out the acceptance and settlement;
(2) The contractor's Responsibility obligations
1, according to the contractor's requirements and drawings for construction; 2, as scheduled completion of the construction task;
3, accept the contractor's technical guidance and quality standard requirements; 4, responsible for the contractor to provide materials and equipment protection;
5, educate the construction staff to care for the materials and materials of the party shall not be stolen and damaged; 6, bear the responsibility for all safety in construction and costs;
6, the contractor shall be responsible for all safety and security;
6, the contractor shall be responsible for all safety and security;
7, the contractor shall be responsible for all safety and security;
8, the contractor shall be responsible for all safety and security Accident liability and costs;
XI, other
(a) This contract shall enter into force upon signature and seal of both parties, and shall be valid until the expiration of the warranty period.
(b) This contract is not yet complete, can be negotiated by both parties to resolve and sign a written supplemental agreement, supplemental agreement and this contract enjoy the same legal effect. Consultation is unsuccessful, submitted to the People's Court of Cao County, Shandong Province, to bring a lawsuit.
(C) the contract annexes for the contract terms of the component parts, the contract with the annexes in two copies, each party to a copy, with the same effect.
Contractor: _________________ Contractor: _________________
Entrusted agent: _________________ Entrusted agent: ___________________
__Year __Month __Day __Year __Month __Day < /p> Cable Laying Labor Subcontract Final 3
The Contracting Party (hereinafter referred to as Party A) __________________
The Contracting Party (hereinafter referred to as Party B) __________________
According to the "Law of the People's Republic of China on Economic Contracts", the "Construction Law of the People's Republic of China", "Regulations on the Quality of Construction Works" and the "Regulations on the Quality of Construction Works", the "Regulations on the Quality of Construction Works" and the "Regulations on the Quality of Construction Works". Construction Project Quality Management Regulations" and other relevant laws, administrative regulations and ______ province promulgated the relevant construction project quality standards, norms, regulations, ordinances, regulations, combined with the specific circumstances of the project, in order to clarify the project and the responsibilities of both parties, in line with the principle of mutual collaboration to ensure the successful completion of the construction project, after negotiation, the signing of this contract.
I. Project Overview
1, project name: __________________.
2. Project location: __________________.
2. Scope of Project Contract
Safety maintenance and rectification.
III. Contract duration
______ days.
Fourth, the cost of the project
The cost of the project is: __________________ whole
Fifth, the quality standard
1, the quality standard: to achieve the current national or professional quality assessment of the qualified standard.
2, the use of standards, norms (including but not limited to the following)
(1) The technical standards and norms of the project shall be in accordance with the national, ministerial and local construction technology (acceptance) regulations and norms.
(2) Local standards and regulations applicable to this project shall be in accordance with ______ provincial standards and regulations.
Sixth, the contracting mode
According to the contracting scope of work listed in Article 2 of this contract package materials, quality, duration, safety package.
VII, project pricing
1, the principle of calculation of the preparation of the project: according to the ____________________________________ unified interpretation of the preparation.
2, the determination of labor and material prices: labor wages according to __________________, material prices in accordance with __________________ implementation.
3. The specific amount of work shall be subject to Party A's visa list.
Eight, the duration
In the following cases, the duration can be postponed after verification of the visa.
1, force majeure factors caused by stoppage of work, force majeure include: national policy adjustments, war, unrest, airborne objects falling or other non-A and B party responsibility to find out the explosion, fire, as well as flooding, earthquakes and other natural disasters, the project location amount of hourly rainfall of 200mm or more than 200mm (based on ______ City Meteorological Bureau report), a water supply, power outage of 8 hours or more.
2, due to non-Party B causes Party B key processes delayed in the work period, the work period can be postponed in accordance with the actual situation.
3. If the delay is caused by Party B, the contract period can not be postponed, and the cost will be borne by Party B.
4. If the project is delayed due to Party A's reasons, the contract period will be postponed, and the cost will be borne by Party A.
Nine, the payment of the project
1, after the completion of the project, Party A within 10 to pay Party B 80% of the budget price of the project.
2, after the completion of the settlement of the project, Party A paid to the settlement of 97% of the total price, the project warranty to stay in the settlement of 3% of the total price, from the date of acceptance of the project after one year, if there is no quality problems within 15 days of the full amount of the return, the warranty does not accrue interest.
X. Liability for breach of contract
1, the default program of this contract agreed form of liability for breach of contract, the contract does not agree, the case of the contract law and relevant regulations.
2, due to the breach of contract caused by the other party's losses, the breach of contract is still not enough to compensate for the other party's losses, should also bear the liability.
Xi, safety and civilized construction
seriously implement the national and local construction safety regulations and provisions and the construction unit of the relevant management requirements, and to do a good job of safety management, to prevent the occurrence of major safety accidents, and do a good job of comprehensive social management.
XII, dispute resolution
This contract in the course of the fulfillment of the dispute, the parties to the negotiation to resolve, but also by the local administrative department of construction mediation, mediation fails, the parties agree to the plaintiff by the People's Court of the location of the settlement, but the litigation period shall not interrupt the construction.
XIII, other
Party B shall pay the wages of the workers in a timely manner in accordance with the relevant provisions of the state, such as Party B to undertake the construction of the project in the process of construction of the wages of the workers in arrears and so on by the government to deal with, Party A has the right to pay the wages of the workers directly from the project funds. This contract shall be executed in ______ copies, and Party A and Party B shall each execute ______ copies. Both sides signed and sealed to take effect.
Party A (official seal) __________________
Party B (official seal) __________________
______ year ______ month ______ day
Cable Laying Labor Subcontract Final 4The contracting party (hereinafter referred to as (hereinafter referred to as "Party A"):
Contact number:
Legal representative:
Contractor (hereinafter referred to as "Party B"):
Legal representative:
Contact number:
The Contractor shall not be liable for any loss or damage arising from the use of the cable. p> In accordance with the provisions of _____ and relevant laws and regulations, combined with the characteristics of the construction of family room decoration works, the two sides, on the basis of equality, voluntariness and consensus, reached the following terms on matters related to Party A's family room decoration works (hereinafter referred to as the project):
Article I. Overview of the project
1.1 Location and area of the project:
Location: _____
Location: _____
Legal representative:
Contact number:
The Contractor (hereinafter referred to as "Party B").
Location: _____________.
Area: ______________ square meters.
1.2 Project cost: ￥ _____________, capital (RMB): _______.
1.3 Project contracting: the two sides agreed to take the following _____ kind of contracting.
(1) Party B contract labor, package all the materials;
(2) Party B contract labor, part of the package, Party A to provide some of the materials;
(3) Party B contract labor, Party A package all the materials.
1.4 Duration of the project ________ days.
Date of commencement _____ month _____ day;
Date of completion _____ month _____ day.
Article 2 Project Supervision
If project supervision is implemented in this project, Party A (or Party B) and the supervising company will sign a separate Project Supervision Contract and notify Party B (or Party A) of the supervising engineer's name, unit, contact information and the supervising engineer's duties.
Article 3 Construction Drawings
The two sides agreed that the construction drawings shall be provided in the following _____ ways:
3.1 Party A shall design and provide the construction drawings on its own, and the time of handing over the drawings shall be _____ day of _____ month, and the drawings shall be made in triplicate, and Party A, Party B, and the construction team shall each take a copy of them;
3.2 Party A shall entrust Party B to design the construction drawings.
3.2 Party A entrusted Party B to design construction drawings, drawings in triplicate, Party A, Party B, the construction team each holds a copy of the design fee to be paid by Party A (this cost is not in the project price);
3.3 construction drawings signed by both parties to enter into force.
Article 4 Obligations of Party A
4.1 Before the commencement of construction ____ days, create conditions for Party B to enter the construction. Vacate all or part of the house, remove obstacles affecting the construction; only part of the house to be vacated in the furniture, furnishings should be taken to protect the principle of not affecting the construction. Party B's construction workers should carefully count and protect Party A's livestock at the construction site, and both sides signed a "list of items";
4.2 Remove the original telephone equipment before the start of construction; provide water and power during construction and explain the precautions to be taken;
4.3 Responsible for coordinating the construction team with the neighbors;
4.4.3 Coordinate the relationship between the construction team and neighbors.
4.4 Prohibit the demolition of indoor load-bearing structures, such as the need to demolish, change the building's load-bearing, non-load-bearing structures or relocation of kitchen, sanitary position and equipment pipelines, should be responsible for the relevant departments for the appropriate approval procedures; according to the provisions of the relevant departments, Party A does not have the right to require Party B to move or transform the heating, gas pipelines;
4.5 Participate in the quality of the project, the progress of construction supervision and the materials into the site, the works, and the supervision of the construction progress. And the acceptance of the materials on the site, the completion of the project;
4.6 The property management department where the project is located in the construction deposit and various property management fees, paid by Party A (except for the pass), Party B to help provide the property management materials required.
Article 5 Obligations of Party B
5.1 Strictly implement the national "Residential Decoration and Decoration Engineering Construction Code" in the construction, to ensure the quality of the project, and to complete the project on schedule;
5.2 In the Party has not been formally provided by the relevant departments for approval of the documents, it is strictly prohibited to alter the main body of the building, the load-bearing structure, heating and gas piping, etc., or else it should be assumed the corresponding responsibility;
5.3 Strictly implement the provisions of the city's construction site management, not to disturb and pollute the environment;
5.4 Protect the furniture and furnishings of the original living room, to ensure that the indoor up and down the pipeline smooth;
5.5 to ensure that the site of the construction site is clean and is responsible for cleaning the construction site after the completion of the project;
5.6 due to the party violating the provisions of the property management in construction Party B is responsible for the fines and compensations caused by Party B's violation of the property management regulations during the construction;
5.7 Party B's designer is responsible for providing Party A with consulting, design, quotation and other related services. After the contract is signed, the representative of Party B to execute the project construction is the project manager sent by Party B. Party A should contact with Party B's project manager on all matters related to the project to ensure the unified command and management in the project.
Article 6 Engineering Changes
6.1 In order to ensure the quality of Party A's works, the construction period and warranty services, after the signing of the contract, such as engineering projects or construction changes, shall be negotiated by the two sides after signing a written agreement on the "Decoration Project Change Order", and at the same time to adjust the relevant project costs and construction period, verbal promises or verbal agreements are considered invalid; where Party A directly with the site of the B staff to agree to change the construction content of everything caused by Agree to change the construction content of all the consequences arising from Party A;
6.2 After the signing of the contract, Party A project to reduce more than 5% of the total amount of work, Party B shall pay Party B to reduce the total amount of 8% of the change fee. If Party A reduces the materials used in the project, Party B has ordered or transported to the site, Party A has to pay for the materials back and forth transportation, wear and tear, and return costs; if Party A requests to reduce the construction project has been constructed, Party A has to pay for Party B's construction costs, materials, management and demolition of the project;
6.3 Party A's second payment for the construction of the project after the increase in the construction of the Party B needs to be received by the Party the increase in the project after the project payment of 100 percent to be constructed. Party B shall construct the project only after receiving 100% of the project payment from Party A.
Article 7: Provision of materials
7.1 The materials and equipments provided by Party A shall meet the design requirements in terms of specification and quality. Party A shall transport materials and equipment to the construction site on time and notify Party B, and both parties *** with the acceptance and handover procedures; if Party A fails to provide materials on time or the specifications and quality of the materials do not meet the design requirements, thus delaying the construction period or affecting the quality of the project, the responsibility shall be borne by Party A.
7.2 Materials and equipment provided by Party B, Party B shall notify Party A in advance of the time when the materials and equipment are transported to the construction site, and both parties *** shall notify Party A in advance, and both parties *** shall notify Party A in advance of the time when the materials and equipment are transported to the construction site. Notify Party A in advance, the two sides *** with the acceptance; if Party B provides the brand, specification, quality of materials and quotations do not match, Party A has the right to refuse to use, which delayed the construction period or affect the quality of the project, the responsibility borne by the Party B;
7.3 Party A to determine the material brand, specification, model or price standard, Party B is responsible for purchasing for the Party in the material transported to the construction site and the Party acceptance of the identification Party B shall not use the materials until they are delivered to the construction site and accepted by Party A. Party B charges Party A's material purchasing fee for the material picking fee (____% of the material) + material transportation costs (determined according to the actual situation); if the construction process due to the quality of the material caused by the return of the goods, replacement, and the delay in the construction period, are borne by Party A;
7.4 In addition to the contract states that the hardware (door locks, pulls, faucets, etc.), stone, ceramic tiles, equipment, sanitary ware, lamps, etc., are purchased by Party A and transported to the site on time; if Party B is required to purchase on behalf of Party B, add the purchasing fee of ____% of the purchased material amount and transportation fee.
Article 8: Delay of construction period
8.1 For the following reasons, the completion date is delayed, confirmed by Party A, the construction period will be postponed accordingly:
(1) Changes in the amount of work and design changes;
(2) Force majeure;
(3) Party A did not participate in the phase acceptance on time and the stoppage of work;
(4) Party A agrees to the postponement of the construction period. (4) Other cases where Party A agrees to extend the construction period.
8.2 If the construction period is affected by Party A's failure to complete the work for which it is responsible according to the agreement, the construction period will be postponed; if the construction quality is affected by the unqualified quality of the materials and equipments supplied by Party A, the cost of reworking will be borne by Party A, and the construction period will be postponed;
8.3 If Party A fails to make the payment of the project payment, the construction period will be postponed;
8.4 If the project cannot be completed on schedule because of Party B's supply of materials and construction, the construction period will be postponed. Can not be completed on time, the construction period will not be postponed; due to Party B caused by the quality of the project there are problems, rework costs borne by Party B, the construction period will not be postponed.
Article 9 quality standards
9.1 The two sides agreed that the quality of the construction of the project according to the following ______ standard acceptance:
(1) "GB50210 - _________ quality acceptance specification for building decoration and renovation works";
(2) "_____ city of family house decoration Decoration Project Quality Acceptance Regulations";
(3) Other acceptance standards: _______________________________.
9.2 When there is a dispute between the two parties about the quality of the project during the construction process:
(1) Mediation can be made by filing a complaint to ______ Municipal Consumers' Association Complaints Center for Home Decoration and Renovation or ______ Municipal Construction and Decoration Association;
(2) If the mediation is not obeyed, identification of the project quality testing organization agreed by both parties, and the required cost and the loss caused by it shall be borne by the Responsible party to bear. Both parties are responsible for, by both parties according to their responsibilities respectively.
Article 10 Acceptance and Warranty
10.1 The two sides agreed to accept the quality of the project in the construction process in the following three phases:
(1) water, electricity pipelines, waterproofing and suspended ceiling grass-roots level and other hidden works acceptance;
(2) paint, surface coatings acceptance of the construction;
(3) completion acceptance.
Party B shall notify Party A two days in advance of each stage of acceptance, and shall fill in the project acceptance form after each stage of acceptance. If Party A receives the notice, not on time to participate in the acceptance, Party B has the right to stop work and wait for the delay and other losses caused by Party B are borne by Party A;
10.2 project completion and acceptance and settle the balance of the project, Party B to Party A to handle the handover formalities and fill in the project warranty form.
Article 11 Payment for the works
11.1 The two sides agreed to pay for the works in the following _____ ways:
(1) After the contract comes into effect, Party A pays the works directly to Party B's finance according to the agreement in the following table:
Number of payments Payment time Payment ratio Payment amount:
The first time the contract signing date;
Within _____ days after the second hidden works acceptance;
Within _____ days after the third completion and acceptance.
(3) Other payment methods: _________________________.
11.2 Within 2 days after the acceptance of the project, Party B shall propose the project settlement to Party A and send the relevant information to Party A. Party A shall notify Party B within 2 days after the acceptance of the project. Party A receives the information within 2 days if there is no objection, the two sides should sign the project settlement, Party A and at the same time to Party B to settle the balance of the project.
11.3 Party A shall hand over the project payment directly to Party B's financial department. After the project is fully settled, Party B should become Party A to issue a formal uniform invoice. If Party A hands over the project payment directly to Party B's construction personnel and cause losses, the responsibility shall be borne by Party A itself.
Article 12 Default Liability
12.1 After the signing of the contract, any party to the contract proposed to terminate the contract or for whatever reason default caused by the contract can not be fulfilled, it should be promptly notified to the other party, the two sides agreed to the termination of the contract by mutual negotiation or postponement of the performance of the contract formalities, the defaulting party should be paid to the party in default of the cost of the works of ______% of the. Liquidated damages; if this causes losses, the defaulting party shall be compensated;
12.2 The project is not accepted or not settled the final payment and not handed over to the party to use or unauthorized use of finished products, the project is considered to be qualified, and the losses caused by the party is responsible for and is considered to be the party to give up the right of warranty and maintenance and the party to collect the balance of the right;
12.3 party to fail to pay the second (third) payment on time, the party to pay the second (third) payment on time. Party B has the right to stop the work if Party A fails to pay the second (third) payment on time, and pay Party B 2 per cent liquidated damages for each day of delay in the total cost of the project;
12.4 Due to Party B's reasons, the quality of the project fails to meet the quality standards agreed by both parties, Party B is responsible for the repairs, and the required repair costs are borne by Party B, and the construction period will not be postponed.
12.5 delayed due to Party A or Party B, each day of delay by the responsible party to the other party to pay the total cost of the project 2 ‰ as liquidated damages.
Article 13 Settlement of Contract Disputes
If the parties fail to settle the disputes through consultation, the disputes shall be settled in the following ______ ways:
(1) Apply to the _____________________ committee _____;
(2) Apply to the ________________ personnel Court.
Article 14 Several Specific Provisions
14.1 For the decoration works where the project site is outside the urban area, Party B will add 3%-10% of the total cost of the project to the remote construction fee;
14.2 The garbage generated due to the construction of the project shall be removed and transported by Party B to the garbage dumping site stipulated by the government, and Party A shall pay for the cost of garbage removal (RMB) _____________ Yuan, (this cost is not in the project payment);
14.3 During the construction period, Party A will be the key of the outer house door ________ to the person in charge of the construction of Party B ____________ is responsible for the safekeeping of the project completion and handover, Party A is responsible for the provision of new locks __________, Party B is responsible for the installation of the delivery of the Party A on the spot to use
14.4 During the construction period, Party B's daily working hours are:
from _________ to _________ in the morning;
from _________ to _________ in the afternoon.
Article 15 By-laws
15.1 The works shall not be subcontracted after the signing of this contract;
15.2 In case of direct signing of the contract by Party A and Party B, this contract shall be signed in _____ copies and shall come into effect after signing (sealing) by both parties, and Party A and Party B shall each hold _____ copies;
Party A (Signature):
Legal Representative (Signature):
________ year _____ month ____ day
Party B (seal):
Legal representative (signature):
________ year _____ month ____ day
Cable laying labor subcontract Final 5The contracting unit: _____________ (hereinafter referred to as Party A)
Contractor: _____________ (hereinafter referred to as Party B)
In order to clarify the rights and obligations of Party A and Party B in the process of construction, and to promote the two sides *** together to get good cooperation and collaboration, to ensure that the project completes the construction task on time in terms of quality and quantity. According to the "Chinese People's *** and State Contract Law" of the relevant provisions of the A and B consensus, signed the construction contract, so that both parties *** with compliance.
Article 1 General Provisions
1. Name of the project: _____________
2. Location of the project: _____________
3. Scope and content of the construction of the project: _____________
4. Cost of the project: _____________
This contract stipulates that Party B is contracted on a lump-sum basis.
Article 2 Construction Period and Stoppage
1. All the projects of this contract started on September 14, 20xx and completed on December 31, 20xx.
2. In the course of construction, in the event of the following circumstances, the extension of the construction period, the two sides should consult in a timely manner to determine in writing the period of extension.
3. Because of manpower irresistible natural disasters forced to stop;
4. Because of the Party's engineering program adjustments need to stop;
5. Because of the difficulties in purchasing materials forced to stop.
Article 3: Occupation and supply of materials
1. The materials and templates required for the project will be processed and purchased by Party B itself.
2. Cement will be purchased by Party B in the county with qualified products.
3. Blasting materials will be purchased by Party B in principle, and Party A can assist in the procedures if there are difficulties.
Article IV Quality Requirements and Design Changes
1. Party B in the organization of the construction process, must strictly implement the current state and the industry to develop the relevant technical procedures, norms and quality assessment standards. Establish and improve the construction quality assurance system, carefully fill out the unit project quality assessment form. Strengthen the construction quality management, so that the quality of the project to meet the qualified standards.
2. The relevant technical data of each project must be strictly according to the design of the construction, not to lower the standard.
3. Quality requirements for construction materials: all construction materials for this contract must meet the requirements of the relevant regulations and specifications, and are not allowed to use materials that do not meet the quality requirements, if there is a violation, Party A has the right to require Party B to compensate for all losses and terminate the contract.
Article V Project Payment
1. Project prepayment: after the start of the project, Party A does not pay progress payments, all costs paid by Party B. After the completion of the project, Party A and Party B will pay in a timely manner. After the completion of the work, Party A and Party B timely acceptance settlement.
2. Party B shall not default on the wages of civil workers.
Article VI acceptance of completion of the project, settlement and warranty
1. Acceptance of completion of the project: After the completion of the project, Party B should be submitted to Party A as soon as possible to the completion of the acceptance of the information (i.e., as-built drawings, construction technical summaries, engineering quality inspection and evaluation of the relevant forms, etc.). Party A received the completion information, within one month to organize the relevant units and departments acceptance.
2. Project settlement: Party B according to Party A acceptance of the project, the settlement of the actual amount of work Party A identified. With the acceptance settlement list issued by the person in charge of engineering and technology of Party A, Party B issued construction invoices to Party A's financial personnel to settle the account.
Article 7 Work Accidents
Party B must strictly implement the national laws, regulations, rules and policies on work safety. In the construction of safety first, strict operating procedures, to eliminate the occurrence of safety accidents, if the occurrence of safety accidents, Party B is responsible for their own.
Article VIII Liability for breach of contract
1. Duration: completion time exceeds the time specified in the contract, Party A has the right to start from the 10th day, a daily penalty of 5% of the settlement price of the project.
2. According to the provisions of this contract, Party B default, Party A has the right to take any way according to the relevant laws and regulations and regulations and norms require Party B to give compensation. On the contrary, Party B has the right to ask Party A to give compensation.
Article IX of the number of copies of the contract and the validity period
1. This contract is in four copies, Party B executes a copy of the Party A three copies.
2. This contract shall enter into force on the date of signature by both parties, and shall expire after the final payment of the project.
Article X bylaws
1. This contract is not exhaustive, Party A and Party B to solve the problem.
2. All attachments to this contract have the same effect as this contract.
The contracting unit (Party A): (Signature) _____________
Legal person entrusted representative: (Signature) _____________
The person in charge of the project: (Signature) _____________
The contracting unit (Party B): (stamp) _____________
Legal Entrusted Representative: (Signature) _____________
Project Manager: (Signature) _____________
Entered into on the _____________th day of the _____________th month of the _____________th year of _____________