Purchase and sale, a Chinese word with the pinyin gòu xiāo, means buying and selling in commerce. How to write a purchase and sale contract in general? Below I bring you the purchase and sale contract, browse more purchase and sale contract can click " purchase and sale contract " to view.
Purchase and sale contract template electronic version 1
Party A (buyer):
Party B (seller):
According to the "Chinese People's Republic of China *** and the State of the contract law" and the provisions of the relevant laws and regulations, A and B on the basis of equality and voluntariness, in the purchase of inverter pump matters Reached the following agreement:
First, the contract subject name, brand, model, specifications, manufacturers, the number of lists are shown in the table below
1, the above price includes: living water pump, frequency control cabinet, diaphragm type pneumatic tanks, channel steel base, supporting piping and valves and other all parts of the production, transportation, loading and unloading of trucks, installation and commissioning, inspection and acceptance, after-sales service, ordinary value-added tax invoices and other related costs. All costs.
2, the packaging of materials and equipment by Party B is responsible for, according to the design of suitable transportation conditions.
Note: The attached drawing (printout) of the foundation will be provided to Party A within seven working days after the contract is signed.
Second, quality standards:
1, product quality to meet the national mandatory standards;
2, provide relevant acceptance information (a copy of the company's business license, organization code certificate, tax registration certificate, company profile, a copy of the legal person's identity card and other credentials. National Industrial Products Production License; ISO9001:20__ quality management system certification; CCC China National Compulsory Product Certification; product inspection reports ); imported goods are issued by the State Commodity Inspection Bureau of the security license issued by the factory original qualified products.
3, found that the goods supplied are inconsistent with the contract, Party A has the right to refuse to accept or return the goods, and all the responsibilities and consequences arising therefrom shall be borne by Party B.
3, Party A has the right to refuse to accept or return the goods.
Third, the delivery time and place:
1, Party A signed the contract, the prepayment to the account within 35 calendars, Party B should be delivered, and according to Party A's notice, the equipment will be supplied to Party A's designated location to unpacking, and is responsible for assisting in the installation and commissioning is completed after the acceptance of the Party A.
2, Party B shall deliver the goods to Party A after the installation and commissioning is completed, and the equipment shall be delivered to Party A for acceptance.
2, in the delivery of goods for use, Party B must provide Party A with product instructions, quality assurance, warranty cards, certificates of conformity and other must have the relevant information (information text in Chinese) and the necessary accessories, otherwise Party A has the right to refuse acceptance and delay in the payment of the contract until Party B make up for the relevant information, during the period of delay in the delivery of the period will not be postponed.
3, delivery location:
Fourth, the payment method (transfer):
1, the payment of equipment for the two sides of the contract signed, Party A to pay Party B 20% of the total price of the equipment deposit (Party B issued a receipt to Party A);
2, to the site of the goods to the Party A to pay the total price of the equipment in the 10 working days, 60% of the total price of the equipment (Party B to issue the total price of the tax bill to Party A);
2, the goods to the site of Party A to pay the total price of 60% (Party B to issue the total price of the tax bill to Party A);;
2, to the site of Party A in 10 working days to pay the total price of equipment (Party B to issue the total price of tax bill to Party B) to Party A);.
3, equipment installation and commissioning acceptance within 10 days after payment to 95% of the total contract price (or goods to the site within three months of debugging, late as debugging qualified);
4, the remaining 5% of the total price of the equipment warranty, acceptance of the full one year after 20 days to pay off (the warranty period of one year, one year from the date of acceptance of the commissioning ).
V. After-sales service
1, the free warranty period for equipment installation, commissioning and acceptance of equipment for one year from the date of acceptance; 3 years free of maintenance, after the warranty period, Party B still provides maintenance services, charge a cost fee.
2, Party B free configuration of some of the parts to ensure that the equipment supplied in the event of failure, at the latest within 24 hours to repair, if necessary, should be provided with the equipment model, specifications and technical indicators consistent with the spare parts or updated compatible products, to take temporary replacement and other measures to ensure that the normal work of Party A.
Sixth, the equipment warranty period is one year from the date of installation, commissioning and acceptance of the equipment; three years free of maintenance, maintenance services are still provided at cost.
Sixth, the liability for breach of contract
1, Party B late supply (or late installation, installation within 7 days after the arrival of the goods), each day of delay in accordance with the 500.00 yuan penalty, if more than 20 days in accordance with the default liability of the implementation of Article 3.
2, if Party B provides the product is not the contract agreed brand, model specifications, origin, then Party A has the right to return, the supply period will not be postponed, and according to the responsibility for breach of contract Article 3.
3, Party B withdraws midway according to the total cost of the contract 50% of the liquidated damages.
4, Party A if late payment, each day of delay in the amount of unpaid part of the 1‰ penalty.
5, the implementation of this contract, Party A, Party B does not adjust the unit price set in this contract due to market fluctuations in equipment, materials, labor prices.
6, Party B is fully responsible for the safety of the equipment before arriving at the site for delivery to Party A; equipment arrives at the site for delivery to Party A after the safety of Party A is responsible.
7, if the party B product upgrades, in order to ensure that the product indicators and the use of parameters unchanged or enhance the premise, the cost of party B is responsible for, party A reserves the right to change the product model agreed in the contract, party B at the same time to ensure that the product upgrades do not increase the price of all the changes in the product must be notified to the party A and party A agreed.
8, Party B to provide products must comply with the relevant national green regulations; Party B of the product materials and equipment design and quality of full responsibility, Party B or not according to the contract agreed to design the configuration and production, resulting in all losses borne by Party B.
9, Party B reserves the right to change the product model as agreed in the contract, at the same time to ensure that product upgrades without price increases.
9, Party B must provide new and authentic materials and equipment products, such as found that the materials and equipment provided by Party B are fake, counterfeit, fake, inferior, Party A has the right to return and terminate the contract, and according to the responsibility for breach of contract, Article 3 implementation and Party B must compensate for Party A's total losses 10, Party A on-site representative
B on-site representative
VII, the settlement of disputes
The contract Disputes occurring in the course of fulfillment, the two parties to solve the problem by negotiation, the consultation fails, according to the law to the People's Court of Party A where the project is located.
VIII, the contract entered into force, expiry date: the two sides signed and sealed since Party B received the advance payment after the contract entered into force; payment clearance, the contract warranty period is automatically lifted (except as agreed).
Nine, this contract is a four copies, A and B each holding two copies. All the terms of this contract are printed text (in Chinese), the modification of any provision should be made by the two sides in the contract "Annex" indicated and confirmed in the seal after the entry into force. Attachment "Configuration List"
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): _________ Legal representative (signature): _________
_________ ____ ____ _________ ____ ____
Purchase and Sales Contract Template Electronic Version 2
Purchaser: (hereinafter referred to as Party A)
Supplier: (hereinafter referred to as Party B)
Purchaser, due to the needs of the construction of the project, the Project Department procurement bidding competition and the two sides friendly and equal consultation, in accordance with the "Chinese People's *** and the State Contract Law" and other relevant provisions, follow the principle of equality, voluntariness and fairness and honesty and trustworthiness, on the following matters reached a unanimous agreement on the establishment of the contract, in order to both parties to comply with the implementation of the two sides.
First, the project overview:
1, project name: Deyang Economic and Technological Development Zone, East River Relocation Room, a three-phase project
2, the project address: Deyang City, East River Town
Second, the product details:
1, the supply side for the buyer to customize the following products: Contract No.
2, the above number of tentative estimates of the number of, in accordance with the actual number of supply settlement. Quantity settlement.
3, quality standards: in accordance with the national standard GB/T4100-20__ implementation. The products supplied by the supplier must be basically consistent with the samples provided by the supplier.
Fourth, the supply period:
After the signing of the contract between the two sides came into effect, the supply side in 15 days to send the first batch of goods to the site of the successive organization, and later according to the buyer of the progress of the project, the buyer of the number of goods required in writing and stamped with the official seal of 5 days in advance of notification of the supply side, so that the supply side in the receipt of the notice of the buyer in order to timely arrange for the delivery of goods.
V. Delivery and pickup method and location:
The supplier is responsible for delivery to the East River construction site, the two sides counted the number of unloading by the supplier is responsible for the buyer to designate Fan Xiaolin, Xie Bin for the consignee, the contact phone number, . The consignee in the supply side of the delivery note signed to confirm, and issued a valid receipt to the supply side, as a basis for settlement.
Six, acceptance criteria:
1, according to the national ceramic tile GB/T4100-20__ standards and samples for acceptance.
2, the product breakage rate according to the national standard 1% implementation, more than 1% of the part of the supply side is responsible for making up;
3, because the ceramic raw materials from natural minerals, firing process is complex, allowing the delivery of the product there is a reasonable color difference.
4. According to the sample sent to assess the requirements: floor tiles for non-slip tiles (ivory), face tiles for white light-colored stripes.
VII. Time and method of objections to the product:
1. The quality of the products from the supplier must meet the national standards. If the buyer finds that the quality of the products does not meet the national standards, the buyer should stop the construction immediately and keep it properly, notify the supplier by phone, and make a written objection to the supplier within three days.
2. If the purchaser fails to raise written objections within the specified period, the goods supplied by the supplier shall be regarded as conforming to the contract.
3. The purchaser shall not object to the decline in product quality caused by poor storage and construction.
4. The supplier shall be responsible for handling the objections within three days after receiving the written objections from the buyer.
5, the buyer's objections, the third party identification confirmed that the batch of products have quality problems, the supplier is responsible for replacement.
VIII. Settlement methods and deadlines:
1. No advance payment for this project.
2, demand-side payment in batches, the first supply to 15,000, signed by the materials department to verify the payment of 60% of the batch, the second supply to 15,000, signed by the materials department to verify the payment of 60% of the batch, the third payment to be paid to the project after the handover acceptance report, the return of the remaining goods for the settlement of the balance of a payment of the entire balance.
IX. Liability for breach of contract:
1, such as the supplier did not supply the contract period, seriously affecting the progress of the purchase of the project, after consultation between the two sides still can not be resolved, should be reimbursed to the buyer can not be delivered part of the purchase price of 10 ‰ of liquidated damages.
2, such as the buyer did not pay according to the contract period, the buyer delayed the supply side of the payment for each day, should be paid daily to the supply side can not pay the payment of 10 ‰ of liquidated damages, and the supply side has the right to postpone the delivery of goods or stop the supply of goods, all the losses caused by the buyer to assume.
3, the supply side according to the contract specifications, models, colors, the number of production, in the arrangement of production, such as the buyer needs to change the contract, should obtain the consent of the supply side, and compensation for all losses caused by the supply side.
X. Returns and replenishment:
If the purchaser needs to replenish the goods, the purchaser must notify the supplier in writing 3 days in advance, so that the supply side for scheduling; the purchaser should bear the additional cost of replenishment of small quantities.
XI, dispute resolution:
If a dispute arises in the course of the fulfillment of this contract, by the purchase and supply of the two sides of the friendly negotiation to resolve; consultation fails, can be sued to the court.
XII, other agreements:
This contract by the two sides of the negotiations, may be signed by a separate supplemental agreement, supplemental agreement and this contract has the same legal effect.
Thirteen, the entry into force of the contract, termination:
This contract shall enter into force immediately from the date of signature and seal of both parties, and shall automatically expire when the payment for the goods is cleared.
This contract is a ___ four ___ copies, the buyer of three, the supplier of ___ a ___ copies, all have the same legal effect.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ ____ ____ _________ ____ ____
Purchase and Sales Contract Template Electronic Version 3
Party A:
Party B:
According to the "Chinese People's *** and State Contract Law" and other relevant laws and regulations of the relevant provisions of the contract, the A and B in a voluntary and equal basis after friendly consultation signed this contract, in order to fund the two sides *** together to comply with.
I. Purchase of goods and unit price:
1. Sand unit price: yuan / ton or cubic meter;
2. The contract amount to the receipt of the pound single in the actual number of received multiplied by the unit price shall prevail; the price of the above products have included taxes and fees.
Second, the quality requirements:
1. the sand supplied should be granite mechanism washed sand;
2. specifications: medium sand;
3. mud content of less than 3%, mud content of less than 1%.
Third, the supply mode:
Party A will send the sand to Party B's designated place within 4 hours after receiving Party B's notice of demand, 100-150 tons per day. Party A is responsible for the organization of transport, transport costs borne by Party B.
Fourth, the settlement mode:
1. Party B with the pound bill and Party A reconciliation, payment Party A to Party B to issue official tax invoices;
2. Payment: cash or transfer mode. If Party B fails to pay the payment on time, this contract will be terminated automatically.
V. Delivery location:
Party B designated location, Party B construction site.
VI. Acceptance:
1. Party B will formulate specific acceptance standards according to the rules of the trade, and acceptance and measurement accordingly.
2. Party B overweight quantity shall prevail, but must be verified by both parties, Party A has the right to conduct random checks of overweight at any time, if there is any disagreement, it must be resolved through consultation between the two sides.
3. Each batch of goods sent to Party B, Party B for sampling after passing, but in the actual use of the process, found that there are unqualified products (except for man-made), Party B should promptly notify Party A, Party A should be given to the replacement and bear all the responsibility for breach of contract.
VII, the contract changes to cancel
A B party in a breach of contract, the other party has the right to unilaterally terminate the contract, and pursue the resulting economic responsibility.
VIII, liability for breach of contract
(a) Party A's liability for breach of contract
1. The quality of the products delivered by Party A does not comply with the provisions of Party B, if Party B agrees to utilize the quality of the price should be based on the quality; if Party B can not be utilized, according to the specific circumstances of the product, the Party is responsible for the replacement or return, due to the quality of the problem of all the economic losses incurred by all of the Party A and bear the payment of 20% of liquidated damages. 20% of the liquidated damages.
2. Party A can not supply according to the time notified by Party B, or late delivery, late delivery of liquidated damages for the current payment of 20%.
3. Party A can't supply the same kind of sand to any unit or individual in Party B's geographical area, otherwise, Party B has the right to hold Party A responsible for all the economic losses.
(ii) Party B's liability for breach of contract
1. Returning the goods in the middle of the process, Party A should be reimbursed 20% of the amount of the returned goods.
2. Late payment, should be in accordance with the provisions of the People's Bank of delayed payment to the seller to pay the late payment of liquidated damages.
3. If the wrong place of arrival or receiver, should bear the losses suffered by Party A.
IX.
Nine, force majeure
Any party due to force majeure reasons can not perform the contract, should promptly inform the other party can not perform or can not perform the reasons, in order to mitigate the losses caused by the other party, after obtaining the certificate of the relevant agencies, allowed to delay performance, partial performance or non-performance of the contract, and according to the situation can be partially or completely exempt from liability.
X. Settlement of disputes
If there is a dispute in this contract, the parties should promptly negotiate to resolve it, and if the negotiation fails, either party may sue the People's Court in the location.
This contract shall enter into force after both parties have signed and sealed it, and neither party shall change or cancel the contract at will during the period of contract execution. If there are any outstanding issues in the contract, the two sides **** with the consultation, to make additional provisions, additional provisions and the contract has the same effect. The original of this contract in two copies, each side of a; have the same legal effect.
XI, the duration of the contract:
This contract in two copies. Signed by the legal representative of the entry into force.
Party A: Party B:
Manager: Manager:
Signing time: Signing time:
Purchase and sale contract template electronic version 4
Party A (demand side): ________________________
Party B (supply side) : ________________________
According to the ___________ and other relevant laws and regulations, following the principles of equality and voluntariness, justice and honesty and credit, the two sides on the purchase of construction materials consensus to enter into this contract.
First, the name of the product specifications unit price quantity and other: template according to the sample receipt, the whole plate in the natural normal use of the case (Note: Refer to the template provided by the use of the instructions for the use of the information, the product qualification rate of 95%) if there is a quality problem such as large areas of open glue layered package transfer package replacement, there is a change one for one.
Second, Party B supply products or raw materials must meet:
1, to achieve the corresponding quality inspection and acceptance standards in Sichuan Province;
2, in accordance with the specifications of the brand brand trademarks (origin) and the number of Party A need to supply in a timely manner;
3, there is a certificate of conformity of the product or related documents.
Third, the supply time, transportation
1, Party A should be ____ days in advance of the supply plan to inform Party B, Party B get the plan should be supplied within two days of Party A's plan.
2, Party B is responsible for the loading and transportation of goods, and transported to the designated location: to the site by Party A is responsible for unloading. After the goods arrive at the designated location, Party A promptly sends the receipt of the number of goods for acceptance, and sign the delivery note to confirm, as the final basis for settlement between the two sides. (Settlement is based on the actual number of deliveries.)
Fourth, the payment method and time
Calculation of payment method and payment agreement: Goods to the site _____ months after _____ working days to pay off this payment.
V. Party A's liability for breach of contract
1, Party A returns the goods in the middle of the day, should be reimbursed to Party B for the return of part of the purchase price _____% of the liquidated damages.
2, Party A late payment, should be in accordance with the provisions of the _______ bank related to delayed payment to Party B to repay the late payment of liquidated damages.
3. If Party A refuses to take over the goods in violation of the provisions of the contract, it shall bear the losses and fines from the transportation department.
4. Party A shall bear the losses suffered by Party B if it fills in the wrong place of arrival or receiver, or raises wrong objections to Party B.
Sixth, Party B's breach of contract
1, Party B can not deliver the goods, should be reimbursed to Party A can not deliver part of the purchase price of 2% of the liquidated damages.
2, Party B handed over the product varieties, specifications, quality does not meet the requirements, if Party A agrees to use, it should be based on the quality of the price; if Party A can not be utilized, according to the specific circumstances of the product, Party B is responsible for the replacement and bear the return of the actual costs incurred.
3, Party B late delivery, should be compared to the provisions of the __________ bank about the delayed payment, according to the late delivery of part of the purchase price calculation, to reimbursement of late delivery of liquidated damages to Party A, and bear the loss of Party A suffered as a result of the cost.
VII. Force majeure
A and B, either party due to force majeure reasons can not perform the contract, should promptly inform the other party can not perform or can not fully perform the reasons, in order to mitigate the losses that may be caused by the other party, in order to obtain the relevant agencies to certify that
in order to allow the postponement of the performance of the performance of the contract, or part of the contract, or non-performance, and according to the situation can be partially or fully exempted from liability for breach of contract. or completely exempted from liability for breach of contract.
VIII, other
According to the provisions of this contract should be reimbursed for liquidated damages and all kinds of economic losses, should be clearly responsible for the _____ days after the settlement of the bank provisions of the settlement method to pay off, or else according to the treatment of overdue payment. However, no party shall withhold the goods or withhold the payment to offset by itself. This contract in the event of disputes, the parties shall promptly negotiate to resolve the consultation fails, either party may request the competent authorities to mediate or apply to the Arbitration Commission for arbitration, or directly to the People's Court.
IX, this contract in duplicate, the supply side of a, the demand side. This contract is signed or sealed by both parties to enter into force, after the settlement of the purchase price of this contract is terminated.
Party A (official seal): ___________________________ Party B (official seal): ___________________________
____________ year __________ month __________ day ____________ year __________ month __________ day
Purchase and Sales Contract Template Electronic Version 5
Demand side: ___________ (hereinafter referred to as Party A)
Supply side: ___________ (hereinafter referred to as Party B)
In accordance with the "Contract Law of the Chinese People's *** and the State"
In accordance with the "Contract Law of the Chinese People's *** and the State", Party B (official seal): __________ (official seal). ***In accordance with the Contract Law of the People's Republic of China, Party B shall provide Party A with energy-saving thermal insulation materials for external walls after friendly negotiation between the two parties. In order to clarify the rights and obligations of both parties, the following agreement is signed to *** with the compliance:
I. Scope of supply of materials:
Party B to Party A to build the _____ Phase I, Area B _____ project site to provide the external wall energy saving required for the external wall insulation materials.
Second, construction quality requirements and acceptance:
1, Party B in strict accordance with the industry standards for insulation materials and the relevant national norms to ensure the quality of materials.
2, Party B is responsible for Party A's insulation materials on-site sampling to send a test (the cost of. And with Party A organization acceptance.
3, Party B must ensure that the acceptance of the exterior wall insulation materials, such as unqualified test, the loss of Party B bear.
Third, the unit price of materials:
Quantity for the tentative, specific to the site to receive the amount shall prevail.
Fourth, the payment method:
Delivery of the month to the 25th reported to the owner, the next month 25 according to the owner of the single paragraph amount to pay for the material, the material amount the owner agreed to pay for the single cost.
V. Duties and obligations of both parties:
A: Party A:
1, Party A needs to pay Party B material payments in a timely manner as agreed in the contract, otherwise Party B has the right to stop supplying materials.
2, Party A is responsible for providing materials into the field plan, a week in advance to declare the plan, Party B with Party A phone notice delivery.
3, slightly
4, Party A is strictly according to the construction program provided by Party B construction.
B: Party B:
1, must be in accordance with the quantity ordered by Party A to provide materials sent to the site of Party B, and with the shipment of the product factory inspection report (copy), certificate of conformity (original), instruction manuals (original), construction programs, manufacturers qualification certificates (copy) and other information, a copy of the need to be stamped with the official seal.
2, such as the quality of materials provided by Party B lead to unqualified acceptance of the external wall insulation system resulting in losses caused to Party A by Party B.
3, the material quality of the external wall insulation system is not qualified.
3, Party B undertakes to cooperate with Party A in the acceptance of the quality of insulation works.
Six, the contract since the first car for Party B to the construction site of Party A date of entry into force.
VII, the contract in the implementation of arguments or disputes, Party A and Party B to negotiate a solution, can not be resolved when the following program.
1, apply for arbitration to the arbitration institution
2, to the jurisdiction of the People's Court.
VIII, this contract in five copies, A and B each of the two, the owner of a copy, after the settlement of the payment expires.
Party A (seal): _____
Party B (seal): _____
_____ year _____ month _____ day
Purchase and Sales Contract Template Electronic version of the five related articles :
★ Commodity Purchase Contract Agreement Electronic version of the five
p> ★ 2022 Simple Purchase and Sales Contract Sample Five
★ Classic Sales Contract Standard Template Five
★ Goods Purchase and Sale Written Contract Format Five
★ Purchase Contract Sample Electronic Five
★ Classic Sales Contract Formal Template Five
★ Standard Purchase and Sale Contract Five Sample
★ 2022 Standard Sales Contract template five
★ Company product purchase and sale contract sample 5
★ Departmental goods sales contract template five