With the general improvement of the legal awareness of the general public, the contract is more and more widely used in life, which can protect civil legal relations. What kind of contract have you seen? The following is the engineering simple version of the contract model (selected 5) that I have helped you organize, welcome to learn and reference, I hope to help you.
Engineering simple version of the contract 1General Contractor: ________________________ (hereinafter referred to as Party A)
Subcontractor: ________________________ (hereinafter referred to as Party B)
In accordance with the "People's Republic of China*** and the State Contract Law", the Ministry of Construction, "General Subcontracting of Construction and Installation Engineering Measures for the Implementation of General Subcontracting of Construction and Installation Works" of the Ministry of Construction and the relevant provisions of the _______ Municipal People's Government's _______ document, this contract is signed by consensus between the two parties and is to be performed seriously.
Article 1 Project
1, Project Name: ____________________
2, Project Location: ____________________
3, Project Number: ____________________
4, Construction Permit No.: ________________
5, Business License No.: __________________
6, Scope and Quantity of Subcontracted Works (with budget)
7, Duration of Subcontracted Works The construction of the project started on ________, ______ and completed on ________, ______.
8, subcontract work labor costs ________.
9, Party B put into the work and the number of people ________.
Article II Project Settlement
According to the subcontracting project, the first month advance living expenses, calculated according to the number of people per person ________ of the contract, and deducted back in the next month settlement, in the construction of the project is underway according to the amount of acceptance of the work completed in the month of the pre-settlement (the magnitude shall not exceed the amount of the ________% of the amount already completed) engineering After the completion of the A and B *** with acceptance, to be settled.
Article III quality of the project
Party A according to the national quality acceptance norms and assessment standards for technical delivery and organization acceptance, Party B in accordance with the construction drawings and specifications requirements, carefully organize the construction, to ensure the quality of the project, such as the quality of substandard, must be reworked and repaired, and its loss of material and cost of labor and materials, borne by Party B; such as the quality of the project If the quality of the work is poor and can not be saved, Party B should be responsible for compensation for all the material losses.
Article IV Safety
1, Party B to undertake the project to do a safety briefing, put forward clear safety requirements, and supervision and inspection, Party B must conscientiously implement the rules and regulations relating to the safety of the construction, strict compliance with safety regulations, the safety facilities provided by Party A, Party B can only be used after passing the inspection, if the construction violates the above provisions, Party B can only use the safety facilities.
2, labor protection supplies and construction of personal use of electrified operating tools such as insulated gloves, rubber boots, etc. by Party B to solve their own problems, such as Party B has difficulties, can be put forward to the plan, Party A to help solve.
3, in the construction process, Party B due to violations of fire regulations and laws caused by fire accidents, Party B is responsible for.
Article V life management
1, Party B workers into the field, food and accommodation by Party A to provide accommodation and the main cooking utensils (cauldron, cage drawer, hair dryer, large panels) by Party B to keep, if any damage is lost at the price of compensation. Small sporadic appliances Party B to provide their own, living coal provided by Party A according to the ration.
2, the life of the food, oil, by Party B, Party A should be in the medical, health and other aspects of the provision of convenience, Party B workers, such as disease, signed by the person in charge of the consent, can be in the Party to seek medical treatment, the medical costs are responsible for Party B to pay off the monthly.
Article 6 subcontracting labor cost unit price
1, unit project subcontracting, each budgeted work day for ________ yuan. The implementation of a single square meter labor cost lump sum, per square meter ________ yuan.
2, the inner eaves plastering subcontracting, to achieve high quality per budgeted man-days for ________ yuan. Achieve the qualified per budget work days for ________ yuan. The implementation of sub-labor cost package per square meter ________ yuan.
3, a single subcontract stone, earthwork per budgeted labor day for ________ yuan.
4. The clearing labor rate is ________ yuan per labor day.
5, full day stoppage, pending material, water, electricity and cleanup work days are ________ yuan.
6, water, electricity, heating, sanitation works, each budgeted man-days (subcontracted by building number for) ________ yuan.
7, winter construction period (________ month ________ to ________ the end of the month) to reduce the efficiency of ________% of the man-days. The unit price of its labor day is ________ yuan.
8, subcontracting project cost breakdown (________ items can be, and after the consensus of both parties in the form of an annex attached to this contract)
Article VII of the management of material supply
Party B set up a special person to the Party for cement, steel, commodities, hardware, linoleum, asphalt and water, electricity, heating, sanitation and other special materials limits. The company has set up a special person to handle cement, steel, hardware, linoleum, asphalt, and water, electricity, heating, sanitation and other special materials, such as the limitation of the material receiving procedures. Party B shall strictly follow the quality requirements and materials provided by Party A for the construction. Party B shall bear the burden of wastage and unreasonable excess of materials used in the construction. Party B in the construction according to the stack (heap) use of materials, to do day-to-day clean, work clean, keep the site clean.
Article VIII of the construction machinery
1, large tools by Party A is responsible for, to ensure that the use of needs.
2, hand-operated tools, Party B is responsible for.
3, Party A is responsible for the supply of tools, Party B should be carefully kept and cared for, if lost or damaged, Party B is responsible for compensation.
4, construction of small and medium-sized machinery, equipped by Party A according to the construction program, a machine should be equipped with a driver to ensure that Party B normal construction, Party B is not allowed to unauthorized operation of the equipment (bring their own machinery in accordance with the relevant provisions of the treatment).
Article IX site management
1, Party B personnel should strictly abide by the site of the management system, in the party responsible for the site under the unified leadership of the organization of the construction, the plan, progress, supply of materials and other work the two sides should work closely to ensure that the construction is carried out smoothly.
2, Party B should be construction personnel to comply with the law and safety production, care of property education, and designate a person responsible for site security, is strictly prohibited from stealing the site materials, such as violation of the site management system of unlawful acts, Party A has the right to take the necessary measures, Party B shall bear legal responsibility, and is responsible for compensation for economic losses.
3, subcontracting personnel to maintain relative stability, in and out of the construction site to wear a work sign, not allowed outside the contract personnel access to the site and accommodation.
Article 10 liability
1, Party B subcontracted projects, may not be subcontracted. In the construction process by the inspection does not meet the provisions of the national acceptance criteria, can not guarantee the quality of the project, Party A has the right to terminate the contract, resulting in rework losses, Party B shall be compensated.
2, after the contract is signed, without the consent of both parties, no party shall change or cancel at will. If Party B terminates the contract unilaterally without Party A's consent, Party B shall compensate Party A for the economic loss caused by affecting the construction plan; if Party A terminates the contract in the middle of the contract, Party B shall be compensated for the economic loss caused by this.
3, Party B must be completed in accordance with the contractual requirements for the duration and quality, or every day late, should be reimbursed to the Party according to the subcontracting labor costs ________% of the late liquidated damages.
4, Party A and Party B shall not default on all kinds of payables, such as arrears, according to the bank short-term loan interest rates, pay the other side of the late payment of liquidated damages.
Article XI bylaws
1, this contract in the event of disputes, the parties shall consult in a timely manner, the consultation fails. If it can't be solved, it can be solved according to the following ____ items:
(1) Apply for arbitration to the Arbitration Committee of Economic Contracts in the place where the building is located;
(2) File a lawsuit to the People's Court.
2, this contract in one _______ copy, A and B each of the original _______ copy. The remaining copies, reported to _______ for the record.
3, the request for authentication (notarization), you can go to the district or county administration for industry and commerce where the building is located for authentication or notarization.
4, the two sides agreed on other terms:
① ______________________________
② ______________________________
Article XII of the contract validity period
This contract from the date of the two sides sealed It shall come into effect and expire after all the works are completed and settled.
General Contractor (seal): _______________ Subcontractor (seal): _______________
________ year ________ month ________ day ________ year ________ month ________ day
Engineering Simple Version Contract 2Contractor: (hereinafter referred to as Party A)
Contractor: (hereinafter referred to as Party B)
I. Name of the project: Teacher's Garden Subdivision, Chang'an District, _____ Building
II. Location of the project: Youth South Street, Chang'an District, Xi'an City
III. Contracting method: only labor and not materials (including all construction machinery)
IV. Contracting content: indoor and outdoor The contract content: indoor and outdoor filling and tamping.
V. Contract unit price: indoor filling _____ yuan / m3, outdoor filling _____ yuan / m3 (including gray soil).
VI. Payment: Party B completed all the work within the scope of contracting and accepted by Party A, Party A paid Party B all the money for the project.
VII, quality and schedule requirements:
1, backfill thickness of not more than 300 mm, compaction factor of not less than 0.94 at the same time as the high, surface smoothness and other technical indicators must comply with the national acceptance specifications, do not meet the requirements of Party B must be reworked to deal with, and bear the resultant delay in the construction period and the loss to Party A.
2, Party B completed all the work within the scope of the contract and after Party A acceptance, Party A paid all the project payments.
2, due to Party B causes stoppage or withdrawal of losses, by Party B to bear all, and Party B to finish 60% of the volume of work for settlement. The remaining 40% will not be settled.
Eight, safety requirements:
1, Party B must comply with all the rules and regulations of Party A on site, Party A has the right to order its exit for those who do not obey the management of Party A.
2, Party B must comply with all the rules and regulations of Party A on site.
2, Party B should always check the status of their own power equipment is normal, found that the problem should be immediately shut down for maintenance, shall not operate with disease.
3, Party B in the construction should always educate workers to pay attention to safety, Party A is not responsible for injuries or property damage caused by Party B's illegal operation.
Party A (official seal): ________ Party B (official seal): _________
Legal representative (signature): ________ Legal representative (signature): _________
____ ____ ____ ____
____ ____ ____ ____
_________
_________ p> Engineering simple version of the contract 3
Party A: ____________________
Party B: _____________________
Party A in order to Leling City, Yuefeng River desilting project needs, A and B in the spirit of fairness, justice and equality of the principle of the signing of this agreement, the specific matters negotiated by the A and B signed the agreement as follows
1. Project name: _______________________
2. Project volume: the length of the river has 3150 meters or so, (the specific length of the time measurement, the amount of work in accordance with the Water Conservancy Bureau under the drawings of the section of the surface of the earth amount of calculations)
3. Project price: the unit price of five dollars and fifty cents per cubic meter ($ 5.5) (including) Transformer installation, transformer rent 200 yuan per day, mobile transformer each time 1,000 yuan mobile fee, materials and labor costs 53,000 yuan, electricity 0.53 yuan per kilowatt-hour, calculated according to the meter, watch the dam is responsible for Party B, the occurrence of the collapse of the dam is responsible for Party B,) the above costs are borne by Party B, the Party will first advance later deducted in the project, the cost of installing the transformer and the cost of electricity is higher than the above number of unit price, the extra cost by the Party A The cost of installing the transformer and the unit price of electricity is higher than the above, the extra cost is the responsibility of Party A.
4. Payment: workers enter the site to pay part of the living expenses, payment according to the image of the progress of the project to pay 50%. The end of the project to solve all the wages of the workers home, the remaining balance of three days to pay a lump sum.
5. Quality and acceptance: Party A and the Water Conservancy Bureau of the relevant personnel acceptance shall prevail, in accordance with the drawings issued by the Yuefeng River Water Conservancy Bureau of construction, Party B due to the difficulties of the water supply, must be constructed in segments, Party A must be segmented in a timely manner, acceptance, do not miss the time of construction of Party B.
6.
6. Safety responsibility: Party B according to industry standards, the arrangement of the construction team, under the premise of quality assurance, according to the contract to complete the construction project, the construction of safety accidents during the period of Party B is responsible for.
7. Party A's responsibility: Party A is responsible for payment on time, arrange an excavator resident site, listen to Party B management personnel management, excavation slurry pool and reinforcement, drainage ditches, etc., Party A excavator to be the end of the project, acceptance of the excavator can only be withdrawn from the site after the excavator, excavator mobilization, fuel, repair, drivers, etc. are responsible for Party A, Party B to arrange the driver dormitory, Party A is responsible for coordination of excavation Party A is responsible for coordinating the location of the excavation slurry tank, and walking routes, water sources, and resolving and coordinating local conflicts. Mediation costs are the responsibility of Party A.
8. This agreement is in duplicate, A and B each party to sign a copy of the two sides, the two sides *** with the compliance, this agreement is signed by the person in charge of Party A stamped, Party B signed by the person in charge of the effective date of the agreement, the agreement is not exhausted the two sides to solve the problem.
Party A: __________; Party B: _____________
Date of establishment of the agreement: _______ ___ month ___ day
Engineering simple version of the contract 4Contractor (referred to as Party A):
Contractor (referred to as Party B):
In order to ensure that the Lingliang Township street lamps are normally illuminated for the convenience of Vehicles, pedestrians safe passage, according to the "Civil Code" and other relevant laws and regulations and the actual situation of Lingliang Township street lamps, A and B in the spirit of voluntariness, equality, the principle of mutual benefit, after friendly consultation, on the B party to undertake Lingliang Township street lamp repair work involved in the rights and obligations of both parties to sign this agreement, both parties * * * with the observance of:
I. Overview of the project:
( 1), project name: Lingliang Township street light maintenance
(2), work content: solar light maintenance
Second, maintenance, maintenance scope: agreement maintenance, maintenance scope: procurement of solar energy controllers, EDXX, maintenance and so on.
Third, repair, maintenance period: repair work completed before ________ ____ ____.
Fourth, repair, maintenance costs:
1, the two sides agreed to material supply, maintenance costs lump sum *** total: one hundred and twenty thousand one hundred and eighty-four dollars (121800.00 yuan).
2, this cost includes:
(1) repair, maintenance labor costs;
(2) in addition to the aerial working platform truck rental fee for all mechanical costs;
3, XX, controllers, and small electrical components costs;
4, management, taxes, and all other costs.
V. Repair, maintenance requirements:
1, Party B to protect the operation of the construction safety during the maintenance;
2, Party B should be commissioned at the end of the maintenance;
3, Party B to ensure that the repaired electrical equipment warranty, warranty period ________ years;
4, in the event of other related materials replacement work needs to the contracting party Separate notice;
Six, the information submitted: If the contract involves the cost of materials, machinery outside the scope of the agreement to be reported to Party A agreed and photographic confirmation of the implementation of Party B shall provide the relevant materials, machinery costs invoices as a reimbursement according to.
VII, payment:
1, the contract maintenance work is completed after notification of acceptance of Party A, the project in principle, according to the progress of payment in two.
The first payment after the completion of the repair work to 70% of the total amount of payment;
The second payment to be accepted within fifteen working days after the settlement to 95% of the total amount of payment. The remaining 5% of the project amount to be retained as a project quality assurance deposit, to be checked at the end of the warranty period of the project no quality problems after the settlement, the final settlement of the project amount approved by the audit department shall prevail.
2, the implementation of the process occurred outside the scope of the contract materials, machinery costs confirmed by the Party reimbursement.
VIII. Party A's responsibility: Party A to help eliminate obstacles that hinder the construction of Party B; pay the maintenance costs according to the content of the contract.
IX, Party B's responsibility:
1, in accordance with the agreed scope of construction, duration and requirements for construction, to ensure that the street lamps to meet the requirements of lighting and related departments.
2, according to the contract to provide relevant information.
Ten, special agreement:
1, the construction of casualties occurring due to Party B, Party B is responsible for, and bear the relevant medical, compensation costs.
2, the construction process involves . Line channel, power outage plan, etc., by both parties *** with the coordination of processing.
XI, this contract is not exhaustive by A, B negotiation.
XII, this contract by the representatives of the A and B signed, stamped and entered into force, as a legal basis for retention, both parties must *** with the observance of the contract, such as any party does not comply with the contract and the loss caused by the breach of the party to assume full responsibility.
Thirteen, the contract is four copies, A, B, two copies each.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): _________ Legal representative (signature): _________
____ ____ ____ ____ ____
____ ____
________ 201
Part A and B
The contract is a simple version of the contract. /p> Engineering simple version of the contract 5
Party A: ________________________
Party B: ________________________
According to the "People's Republic of China **** and the State Contract Law," "National Building Construction Specification" and related regulations, in the spirit of the principle of mutual benefit, by the A and B sides Consultation, Party A determined to Xing'an County Century Glacier Tourism District hotel project contracted to Party B construction management. In order to further clarify the responsibilities and rights of both parties to sign the following agreement:
First, the project overview
1, the project name: ____________________________________;
2, the project location: ____________________________________;
3, building structure: ____________________________________;
4, contracting content and scope of construction: civil engineering and water and electricity works according to the architectural construction drawings, structural construction drawings water and electricity construction drawings and design instructions. Hotel decoration another contract signed.
5, the contracting method: labor, materials.
6, the project cost tentative ____________ million.
Second, the payment method and settlement
1, the scope of this contract, the project based on the design drawings provided by Party A documents. And Party B actually completed the amount of work pricing standards. Civil construction, water and electricity installation according to the xx year "Guangxi Zhuang Autonomous Region construction project consumption quota" pricing, floating ______% after the settlement to party B.
2, materials used in the scope of the project according to the construction period of Guilin construction project cost management station issued by Xing'an County cost information for price adjustment. Xing'an is not included in the material according to Guilin City, the corresponding period of cost information to adjust. Information price is not available, the two sides according to the market price of friendly negotiation to determine, according to the actual amount of work occurred pricing settlement.
Third, the duration
1, the effective duration of the project is ______ days.
2, the start of work: ___________ year _________ before ________ (subject to Party A's notice of entry).
3, completion time: (according to the actual start date)
Fourth, the quality and material requirements
1, the quality of the requirements of the national construction quality standards and norms, the grade is qualified.
2, Party B each completed a sub-project, must be reported in a timely manner on behalf of Party A, supervisors, technical personnel, quality inspection personnel for acceptance. And according to the acceptance of the opinions collated and signed before entering the next process.
3, Party A must be received in Party B's written application within 48 hours of the organization in place to acceptance, otherwise, according to the acceptance has been accepted, in Party B after the construction of Party A must be given to sign the approval.
4, the material must be quality and quantity. All incoming materials must have factory certificates of conformity, the state has provisions requiring review of the material must be tested to the quality inspection station before use.
Fifth, the project payment method
1, the project by Party B advances the project: from the foundation earth excavation advances to __________ ground (casting completed)
2, in Party B advances in place, Party A according to the actual completion of the amount of work to be paid to the progress of the project _____% to Party B. Later, every layer of the completion of the project, the amount of work to be paid to Party B. The amount of work to be paid to Party B is $20 million. Later, each completed layer, pay a progress payment, and so on.
3, in Party B is responsible for advancing the period of Party B's capital causes suspension of more than 20 days due to Party B's funds, Party A has the right to terminate the contract, and all the losses are borne by Party B.
4, after the completion of the project acceptance, Party B qualified information and settlements reported to Party A for review, Party A must receive the declaration of information within 30 working days to complete the audit, if there is a dispute, can *** with the commissioned relevant costing firms audit. After the settlement is approved by Party A's audit, in addition to leaving the warranty deposit _____%, a one-time payment shall be made within three months, and no delinquency shall be allowed.
5, such as Party A does not pay according to the contract, each day must be 3 ‰ of the total amount of arrears compensation to Party B, and so on.
6, the project all construction money must be transferred to Party B account unit:
Opening bank: __________ bank: __________ account.
Six, the project completion acceptance and delivery
1, before the delivery of the project, Party B must do a good job before the delivery of the details of the rectification, sanitation and cleanup, safety and security, engineering custody and other related work. Self-inspection after passing the written declaration of Party A and supervisory engineers re-inspection, sign to confirm the re-inspection of qualified before the delivery of the project, otherwise the losses arising from the contractor is responsible for.
2, Party A in the receipt of Party B qualified information and written declaration within 10 days must be organized to the site for completion of acceptance, visas, otherwise, deemed to acceptance.
3, in the two sides did not accept the visa delivery of the use of Party A shall not be occupied, or else deemed to be accepted for delivery to the use of Party A.
Party A is not allowed to use the site.
VII, A and B rights and responsibilities
1, Party A must provide accurate geological underground pipeline information before construction, to ensure that the protection of supplies without loss, and to ensure that three days before the B party to do a good job of three passes and one leveling.
2, Party A with Party B for construction noise and environmental health management procedures.
4. Provide standard leveling points and detailed coordinate control points, and guide Party B to carry out construction on site. During the construction period Party A must negotiate, all social relations around. Ensure the smooth progress of construction.
5, Party A in the payment of the project into can not be any reason and excuse to delay payment time.
6, Party B must strictly according to the drawings of the design requirements and construction specifications for construction, Party A management personnel found that the quality of construction is not up to the requirements of the design and construction specifications, the right to require Party B to stop rectification, and the corresponding punishment.
7, waterproof materials, aluminum alloy window materials must be designed according to the drawings, agreed to by Party A can be used.
8, during construction, Party B must do a good job of safety education. To achieve safe production, civilized construction, such as Party B reasons for all safety accidents, all the responsibility borne by Party B and Party A has nothing to do.
VIII, breach of contract
1, the terms of this agreement with both sides *** with compliance, Party A must coordinate the construction of the party to deal with all the surrounding social relations, such as the villagers and other people to make unreasonable and obstruct the construction of the project stoppage of all the losses borne by the Party A (in addition to the Party B's own reasons).
2, Party B strictly according to the contract duration of construction, shall not delay the construction period and stop work for no reason, such as violation of the contract, Party A has the right to terminate the project contract, and all the losses by Party B itself.
3, Party B in this contract and the party signed the effective, must be paid to Party A engineering warranty deposit of three million yuan. This amount of money in the party B advances the completion of a one-time return to the party.
4, this contract in quadruplicate, the A and B sides of two copies. Both sides signed the immediate effect, both sides must *** with the compliance with the implementation, at the same time have the force of law.
Party A (signature): __________________ Party B (signature): __________________
___________ year _________ month ________ day ___________ year _________ month ________ day