Ship maintenance contract

With the continuous development of the spirit of the rule of law, people pay more and more attention to contracts, and the binding force of contracts on us can not be ignored. Contracts are both a guarantee and a constraint for both parties. So what is a formal and standardized contract? The following is a sample ship maintenance contract I collected for you. Welcome to share it. Model ship maintenance contract 1

Party A: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Company

Party B: _ _ _ _ _ _ _ _ _ _ _ _ Company

According to the Contract Law of the People's Republic of China and relevant laws, through friendly negotiation between Party A and Party B, It is unanimously agreed to sign this contract according to the following terms:

Article 1: General situation of the project

1. Name of the project: _ _ _ _ _ _ _ _ _ _

2. Location of the project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _. The duration of this contract is _ _ _ _ _ _ days

2. The total project cost is _ _ _ _ _ _ _ _ _ _ _ _, in words: _ _ _ _ _ _ _ _ _ _ _. After this contract comes into effect, Party A shall pay the full amount by cheque within _ _ _ _ _ days after Party B's production and installation are completed, and after Party A's acceptance is qualified and there are no deductions, and Party B shall issue a valid invoice supervised by the tax bureau.

article 3: responsibilities and obligations of both parties

1. Party B must carry out the construction with good quality and quantity according to the design drawings and Party A's requirements. If the project quality does not meet the relevant regulations, Party B shall be responsible for repairing or reworking it free of charge, otherwise it will compensate Party A for all losses.

2. Party B must complete the project according to the time agreed by both parties. In case of force majeure, the construction period will be postponed. Otherwise, it will be regarded as a breach of contract and compensate Party A for _ _ _ _ _% of the total project cost as liquidated damages.

3. In case of quality problems during use, Party B shall be responsible for maintenance in time after being notified by Party A..

article 4: liability for breach of contract

1. the materials purchased by party b must ensure the quality and be qualified products that meet the design requirements. Otherwise, it shall be replaced in time and free of charge according to Party A's requirements and compensate Party A for its losses.

2. settlement of contract disputes: court prosecution.

the original of this contract is in quadruplicate, with Party A holding three copies and Party B holding one copy, all of which have the same effect, and this contract shall come into effect as of the date of signing.

party a: _ _ _ _ _ _ _ _ _ _ _ company

party b: _ _ _ _ _ _ _ _ _ _ _ _ company

______ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

article 1 scope of work: the repairing party shall, according to the ship repair work list proposed by the entrusting party, take it as the basis of the scope of repair work of this ship after being checked and signed by both parties.

article 2 project of adding and subtracting accounts

1. the project of adding accounts shall be submitted to the contractor in writing by the representative of the entrusting party within one quarter of the project period after the commencement of construction and confirmed by both parties. If the cost of the additional project does not exceed 1% of the total repair cost of the ship, and its single project does not affect the project period, the contractor can repair it according to the conventional repair project. If the cost of the additional project exceeds 1% of the total repair cost of the ship, or if the additional project is proposed by the entrusting party after a quarter of the project period is started, and its single project will affect the project period, both parties may separately negotiate and determine the repair price and project period and sign a supplementary agreement according to the specific situation.

2. The account reduction project shall be put forward by the entrusting party's representative to the contractor in writing and confirmed by both parties. If the contractor has incurred the cost for the account reduction project of the entrusting party, the cost shall still be borne by the entrusting party.

article 3 project price: the repair fee of this ship does not include the addition and subtraction of accounts. the project is scheduled to be RMB xx million xx million xx million xx million xx million xx yuan, and the final total price will be settled according to the actual repair project of this ship after completion.

article 4 project duration: this ship is scheduled to enter the factory on xx, xx, xx, xx, xx, xx, xx, xx, xx, xx days, including xx days in the dock row and slipway.

article 5 project acceptance

1. the items that need to be submitted to the ship inspection bureau for repair of this ship shall be applied by the entrusting party. The repair of a single project is completed or passed the inspection, which shall be signed and accepted by the representative appointed by the entrusting party. After all the repair works are completed or the dock test is completed, the representatives of both parties shall sign the General Acceptance of Ship Repair Completion as the basis for delivery.

2. The technical requirements and acceptance criteria of the ship's repair works shall be implemented according to the Technical Agreement signed by both parties. During the test and trial voyage, the ship inspection bureau and the entrusting party put forward the defects and missing items in the repair project of the repairing party, and the repairing party should repair and complete them in time. If it is not within the scope of the contractor's repair project and needs to be repaired by the contractor, it can be treated as an additional project.

3. after the dock test, sea trial and other related tests of this ship are qualified, the repairing party shall provide the entrusting party with relevant supporting documents and materials within xx days.

article 6 quality assurance

1. after the ship is repaired and accepted, the warranty period of the fixed parts repaired by the repairer is six months, and the warranty period of the moving parts is three months. During the warranty period, if the fault or defect is caused by the repair quality problem of the contractor, the contractor shall promptly repair it free of charge.

2. if the quality problems or improper operation of the accessories, spare parts and equipment provided by the entrusting party cause faults, defects and losses, the entrusting party shall be responsible.

article 7 engineering repair

1. the waste equipment, materials and other articles removed during the ship repair construction, except the stern shaft and propeller, shall be handled by the contractor. If the old parts and equipment are needed by the entrusting party, the entrusting party shall submit them to the repairing party in writing before disassembly, and the consent shall be obtained. After disassembly, they shall be transported away in time.

2. During the ship's repair in the factory, the entrusting party shall not hire laborers to carry out the repair of relevant projects on the ship without the consent of the repairing party. Without affecting the construction of the contractor, the contractor shall support the self-repair work of the crew of the entrusting party. However, the entrusting party must notify the repairing party in writing of the repair project and schedule on this ship.

article 8 project payment

1. after this contract comes into effect, the entrusting party shall pay the contractor an advance payment of 3, yuan of 4% of the total repair cost within days. when the repair progress reaches half of the project period, the entrusting party shall pay the balance of 3, yuan of the total repair cost to the contractor in one lump sum within xxxx days after completion. If the entrusting party makes overdue payment, it shall be handled in accordance with the relevant provisions of the People's Bank of China on overdue payment.

2. The repairing party shall collect money from the entrusting party's bank with the Statement of Account. Article 9 When the ship repair project is completed ahead of schedule or overdue, both parties shall pay the other party the quick repair fee or the delayed repair fee, and the calculation method is as follows: for every day that the repairing party completes the project ahead of schedule, the entrusting party shall pay the repairing party the quick repair fee separately according to xx of the total repair fee of the ship, but the maximum amount shall not exceed xx of the total repair fee. If the completion is delayed due to the reasons of the contractor, the contractor shall pay the client a delay fee according to xx of the total repair fee for each overdue day, but the maximum amount shall not exceed xx of the total repair fee. The contractor shall automatically deduct the overdue repair fee in the bill and notify the entrusting party.

article 1: fire safety work the fire safety work during ship repair must strictly implement the regulations on fire prevention and explosion prevention in ship repair jointly issued by the people's Republic of China, the Ministry of communications, the Ministry of public security and China state shipbuilding corporation on may 25, 1991.

article 11: settlement of disputes during the execution of the contract, both parties shall settle disputes through consultation. If negotiation fails, the dispute shall be submitted to China Maritime Arbitration Commission for arbitration in accordance with its arbitration rules in effect at the time of applying for arbitration. The arbitral award is final and binding on both parties.

article 12 other

1. for matters not covered in this contract, both parties may make a supplementary agreement, which has the same effect as the original contract.

2. this contract shall come into effect as of the date of signature.

3. the original of this contract is in duplicate, each party holds one copy, and xx copies, one of which is sent to the contract management authority where the contractor is located for the record. If both parties request to authenticate the contract, they shall go through the authentication procedures at the contract management authority where the contractor is located.

the name and seal of the employer's unit address:

legal representative:

entrusted agent:

telephone number:

cable registration:

bank of deposit: bank of deposit:

account number.

ContractNo.: _ _ _ _ _ _ _ _ _ _ _

Signing place: _ _ _ _ _ _ _ _ _ _ _ _

Entrusting party: _ _ _ _ _ _ _ _ _ _ _ _ _ _

article 1 scope of works the contractor shall, according to the ship repair work list proposed by the entrusting party, take it as the basis of the scope of repair work of this ship after being checked and signed by both parties.

article 2 project of adding and subtracting accounts

1. the project of adding accounts shall be submitted to the contractor in writing by the representative of the entrusting party within one quarter of the project period after the commencement of construction and confirmed by both parties. If the additional project cost does not exceed _ _ _ _ _ of the total repair cost of the ship, and its single project does not affect the project period, the contractor can repair it according to the conventional repair items. If the cost of the additional project exceeds _ _ _ _ _ of the total repair cost of the ship, or if the additional project is proposed by the entrusting party after a quarter of the project period is started, and its single project will affect the project period, both parties may separately negotiate and determine the repair price and project period according to the specific circumstances, and sign a supplementary agreement.

article 3 the project price, excluding the repair fee of this ship, is scheduled to be RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

article 4 construction period: this ship is scheduled to enter the factory on _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _

article 5 project acceptance

3. after the dock test, sea trial and other related tests of this ship pass the inspection, the repairing party shall provide the entrusting party with relevant supporting documents and materials within _ _ _ _ _ _.

article 6 quality assurance

article 7 engineering repair

article 8 project payment

1. after this contract comes into effect, the entrusting party shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ If the entrusting party makes overdue payment, it shall be handled in accordance with the relevant provisions of the People's Bank of China on overdue payment.

2. The repairing party shall collect money from the entrusting party's bank with the Statement of Account.

article 9 quick repair fee and delayed repair fee. when the ship repair project is completed ahead of schedule or overdue, both parties shall pay the quick repair fee or delayed repair fee to the other party, and the calculation method is as follows: for every day that the repairing party finishes ahead of schedule, the entrusting party shall pay the repairing party an additional quick repair fee according to the total repair fee of the ship, but the maximum amount shall not exceed _ _ _ _ _ of the total repair fee. If the completion is overdue due to the reasons of the contractor, the contractor shall pay the client a delay fee of _ _ _ _ _ of the total repair fee for each overdue day, but the maximum amount shall not exceed _ _ _ _ _ of the total repair fee. The contractor shall automatically deduct the overdue repair fee in the bill and notify the entrusting party.

article 1 fire safety work fire safety work during ship repair must strictly implement the regulations on fire prevention and explosion prevention in ship repair jointly issued by the people's Republic of China, the Ministry of communications, the Ministry of public security and China state shipbuilding corporation on may 25, 1991.

article 11 settlement of disputes during the execution of the contract, both parties shall settle disputes through consultation. If negotiation fails, it should be