A power transformer is the most expensive piece of equipment that connects a power plant to an electrical energy consumer. What about the transformer procurement contract? Below is a sample transformer procurement contract that I have compiled for you , thank you for reading.
↓↓↓ Click for more "Contracts" ↓↓↓↓
★ Medical Equipment Purchase Contracts ★
★ Equipment Maintenance Contracts Templates ★
★ Equipment Rental Contracts for Plants ★
★ Fire Equipment Purchase Contract ★
Simple Transformer Purchase Contract Sample 1
Purchaser: (hereinafter referred to as Party A)
Supplier: (hereinafter referred to as Party B)
By the friendly negotiation between the two parties, based on the "Chinese People's **** and the State Contract Law" and the "terms of the contract for the purchase and sale of industrial and mining products", agreed to sign This contract, the specific terms are as follows:
First, the scope of supply of products:
Box-type transformer: ZBW4-12/0.4-630 one.
Second, the contract amount and payment
1. Contract amount:
The total contract price of RMB: two hundred and twenty thousand eight hundred and eighty thousand yuan (￥ 228,000 yuan), for Party B to provide Party A with the construction drawings of the contract box-type transformer all the components of the price includes all the costs incurred prior to the arrival of the goods to Party A's designated delivery location, the total price of the contract is fixed during the performance of this contract. The total contract price is fixed during the performance of this contract.
2. Payment:
Contract prepayment of 30% of the total contract price, 65% of the contract amount to be paid after the arrival of the equipment commissioning operation, the remaining 5% as a warranty, the warranty period of 1 year, the warranty period expired within 10 days of a one-time payment.
Third, the delivery time and place
1. Delivery time: delivery within one month after the payment of advance.
2. Delivery location is: , packaging is not recycled. Fourth, product quality assurance and after-sales service
1. Party B guarantees that the contract equipment is new and complete, the quality, workmanship, technical performance in full compliance with the quality, specifications and performance requirements set out in the construction drawings.
2. Party B to provide Party A with equipment drawings, factory inspection certificates, test reports, use and maintenance instructions and other technical information.
3. Party B to provide Party A to meet the use of random spare parts, spare parts and tools.
4. The contract equipment from the date of delivery warranty period of one year.
5. Contract equipment warranty period, if the equipment can not run normally or damaged due to Party B's responsibility, Party B in the Party received a notice within 24 hours to the equipment installation site to deal with, and bear all the related costs.
V. Liability for breach of contract
1. Party A or Party B fails to fulfill the obligations of this contract is a breach of contract, the defaulting party shall bear all the losses caused by the breach of contract.
2. Party B does not arrive on time to pay Party A 1% of the total contract price delayed one day penalty.
VI. Contract entry into force and other
1. The contract will enter into force after the payment of advance payment, and the warranty period will expire naturally when the equipment is paid off.
2. Design drawings, equipment lists, material lists, technical agreements, supplementary notes as an annex to the contract, and the contract has the same legal effect.
3. Dispute resolution: disputes arising from this contract, A and B should be resolved through friendly consultation, and if the consultation fails, either party has the right to submit to arbitration.
4. Two copies of the original of this contract, one for each party, four copies, two for each party. This contract is effective from the date of signature and seal of both sides in the written document, the goods and the payment of two clear automatically expires, the text has the same legal effect.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ ____ ____ _________ ____ _________ Day
Simple Transformer Purchase Contract Model 2
Party A: __________
Address: __________
Phone: __________ Fax: __________
Party B: __________
Address: __________
Tel: __________ Fax: __________
In accordance with the "Contract Law of the People's Republic of China" and other relevant laws, rules and regulations, and in accordance with the principles of equality, voluntariness, fairness and honesty, A and B on the purchase of ___ Limited Liability Company dry-type transformer. Matters of consensus, the conclusion of this contract.
First, the name of the equipment and the total contract price
1, the name of the equipment, specifications and unit price and other requirements (see Annex I to the contract):
2, the total contract price: the total contract price for the whole of the RMB ________ yuan (￥ ________).
The total contract price includes: equipment body, equipment accessories, transportation and handling costs, factory inspection and testing costs, equipment packaging costs, insurance, technical services, technical training, equipment warranty and maintenance costs, equipment related to all taxes and other costs related to the contract equipment. Risk of price increase of materials and equipment during the ordering period of the contract. And free to the scene to provide technical guidance to assist in the completion of the contract equipment installation and commissioning and acceptance of work.
The contract price for the lump-sum contract price, Party B has fully considered the future of transformer equipment itself, accessories related to materials and labor, and all the market price increase factors such as the possibility of Party A does not due to the factors of the future market price increases and give Party B any form of compensation.
If the implementation of this contract at a later stage, the contract content of the increase or decrease, for the contract has been the model of equipment and accessories, the price of the contract annexed to the unit price and the preferential percentage of the implementation of the contract, if there is no the same model, the two sides to negotiate the pricing.
Second, the equipment delivery location and delivery time
1, the equipment delivery location: __________, the project site construction red line within the scope of trucks and cranes can reach the designated location.
2, equipment delivery time: _____ year ______ month _____ before, Party A can adjust the delivery time according to the actual needs of the site, but should be ten days in advance to inform Party B in writing the specific arrival time.
Third, equipment packaging and transportation
1, the equipment and accessories provided by Party B shall be packaged in accordance with national standards and manufacturer's standards, due to poor packaging so that the equipment damage, rust, deformation, or damage to the electrical components, Party B shall bear the responsibility for the relevant responsibilities, and is responsible for the replacement or compensation.
2, Party B must be clearly marked on the surface of all equipment packaging equipment category and equipment number, in order to identify. Party B shall provide complete technical data, product certificates and factory inspection reports and other relevant information with the equipment.
3, Party B must notify Party A in writing two working days before the shipment of equipment about the specific circumstances of the shipment, the equipment arrived at the site, Party B shall be responsible for the unloading of equipment to the crane and trucks can reach the designated location.
Fourth, equipment installation and acceptance
1, the equipment arrived at the site within the same day, Party B is responsible for unloading to the crane and trucks can reach the designated location. Party B shall notify Party A, the supervisory unit, the installation unit *** with the inventory inspection on the same day, Party A shall contact the relevant units for the initial acceptance of the equipment within the same day after receiving Party B's notification. The preliminary acceptance of the equipment of this contract refers to whether the quantity of the equipment matches with the packing list, and whether the appearance of the equipment is intact and whether the nameplate parameters are in line with the requirements. The result of the preliminary inspection does not mean that Party A confirms whether the internal quality of the equipment meets the requirements of the contract, and the inspection does not exempt Party B from all the responsibilities. After the initial inspection by Party A, the installation unit **** with the signature of the receipt of documents.
2, in order to ensure that the product can be successfully commissioned and better operation in the future use of the process, the goods to the scene Party A need to arrange for the goods to be stored in a dry, ventilated place, if the storage conditions can not be met due to the cause of the temperature control and temperature display of the electronic devices such as moisture damage, Party B does not bear the loss;
3, the contract equipment, technical parameters and material requirements to meet the provisions of Annex II of the contract.
4, after the initial inspection by the buyer designated consignee to sign the receipt of documents, the documents will become the basis for the buyer's payment, the consignee of the payment of joint and several liability, the consignee in the delivery note signed will be considered as a confirmation of the terms and conditions.
5, the buyer designated receipt and inspection personnel:
V. Contract security and payment
1, the contract equipment procurement deposit of 20% of the total contract price.
2, the goods to the site by both sides of the initial acceptance and after Party B issued the relevant documents specified in the tender documents, Party A paid 75% of the contract amount of the equipment to Party B;
3, the equipment installation is completed, and through the equipment power acceptance within two weeks after the acceptance of Party B to submit the settlement application report and settlement information. Within 10 working days after Party A completes the review of the product information and construction information submitted by Party B, it will carry out the final accounting of the project volume with Party B and issue the final settlement. After completing the settlement, Party B will submit the payment application report and formal invoice and other related procedures to Party A. Party A will pay 100% of the total settlement price within 7 working days after receiving the above procedures. Party B also submitted a two-year bank guarantee of 5% of the total settlement price of the contract, after the expiration of the guarantee, Party A for the unsealing procedures of the guarantee.
Sixth, quality assurance and warranty
1, the quality of the equipment under this contract shall be in full compliance with the provisions of the relevant national industry standards as well as the contract annexed to the standard requirements expressed in all.
2, the protective shell of the equipment is determined to be made of aluminum alloy material, protection level IP30.
3, the equipment free warranty period: the contract equipment to the site and after installation and commissioning power acceptance of the date of acceptance of the contract for a period of twenty-four months.
4, Party B shall provide Party A with the quality of the equipment warranty and after-sales service commitment, after-sales service commitment must be clear equipment warranty content, warranty period, warranty measures, and after the warranty period of the service items and charges.
5, in the warranty period, the equipment damaged parts such as non-man-made failure problems, Party B shall be responsible for the replacement of free of charge.
VII, liability for breach of contract
1, the notice of the document and delivery: the two sides of the contract implementation process, involving the content of the contract, the business terms of the content of the change or the impact of the content should be in a written format document sent to the other party, and require the other party to sign. The form of documents can be faxed, letter mode, the document should be signed on the name of the person in charge of the project and the company's official seal.
2, Party A and Party B should be based on the principle of friendly cooperation, Party B in the contract within the agreed time to provide quality products in line with the contractual agreements and the provisions of the relevant quality standards of the national industry, if the equipment provided by Party B material does not meet the technical requirements of this contract and all the contract annexes agreed upon, Party B shall compensate for all the direct economic losses caused by Party A. Party B shall not be liable for any loss or damage caused by Party B. Party A reserves the right to further recovery.
3. Party B shall guarantee that the equipment products of this contract are the products produced by __________, and the after-sales service shall be completed by this company. Party B should provide after-sales service commitment and factory on this content of the prescriptive documents.
4, the contract equipment in the process of installation and commissioning, all the technical parameters of the test must be in line with the requirements expressed in the contract and the contract annex, or Party B shall compensate Party A for all the direct economic losses caused by this. Party A reserves the right to further recovery.
5, in addition to force majeure reasons, Party B must supply goods at the time required by Party A, Party B shall not delay the delivery time without reason; if Party B fails to deliver the goods on time for any reason, Party B shall compensate for the compensation, which can be deducted from the amount payable by Party A under the contract; the compensation rate is only limited to the calculation of the contract for the late part of the delivery of the goods, according to the deduction of $ 20_ for each day of delay, but the cumulative amount of compensation under the paragraph shall not exceed the total amount of delayed delivery of the goods involved. exceed 3% of the total value of the delayed goods involved.
6, Party A, in addition to force majeure and Party B's equipment itself there are quality or other defects and other reasons, shall not refuse to accept the goods, otherwise, Party B has the right to pursue Party A's losses arising from the Party A can not pick up the goods on time, Party A should be requested in writing to agree to the late part of the goods on behalf of the goods for safekeeping by Party B to rent warehouses, warehousing, storage, insurance, and other expenses paid by Party A. Party A agreed to pay the agreed compensation for the loss of the part of the contract, the cost of each day of delayed delivery of 20_ yuan. Party A agrees to pay the agreed compensation for damages. Agreed compensation for damages shall be 1% per month of the price of goods for the late part of the goods.
7, quality assurance and service commitment: in line with the expression and requirements of all the annexes to this contract.
8. Party B shall provide true and effective invoice within two days after receiving the payment notice from Party A. If Party B is found to provide false invoice or invalid invoice, Party B shall bear the liquidated damages of RMB 30,000 yuan.
9, confidentiality agreement: any party to the contract for the contract negotiation, signing or fulfillment of the process of commercial secrets and technical secrets have been obliged to keep confidential, even if the contract has been performed. Without the permission of the other party, a party shall not disclose, use or allow others to use the trade secrets and technical secrets in their possession. If the provisions of this clause are violated, the defaulting party shall be responsible for compensating the other party for all losses suffered as a result.
VIII. Dispute Resolution
1. Except as otherwise provided in the contract, any change or termination of this contract (except for force majeure) shall be effected only by mutual consent and a written agreement signed by both parties. Due to a party's violation of this contract agreement leads to changes in this contract, the termination of this contract, such as the other party to the contract suffered losses, the defaulting party is responsible for compensating the losses.
2, this contract in the performance of the period, the two sides of the dispute, the two sides should be in a friendly attitude of negotiation to resolve, such as mediation is not, either party has the right to the project location of the Arbitration Commission to apply for arbitration, arbitration can not be resolved, can be to the legal process.
IX, the contract takes effect
1, the contract by the two sides signed and sealed and with the contract annexed to the riding seal after the entry into force. Both parties to fulfill all the obligations of the contract, Party B to Party A delivered by the government power supply department after acceptance of the products, Party A to pay the full contract payment, the contract will be terminated.
2, after the termination of the power and obligation of this contract, the two sides should follow the principle of good faith, to fulfill the obligations of notification, assistance, confidentiality and so on.
3. This contract is in eight copies, Party A executes six copies, Party B executes two copies, with the same legal effect.
X. Annexes to the contract
Other contract information is not attached to the content of this contract, but also constitute part of the contract. Such as bidding documents, tender documents, notice of award and related negotiation documents, etc., the development of this contract is based on the content of other contract information and add the implementation of the contents of the specific contents of both complement each other, but also to the most stringent content of the provisions of the final implementation of the terms of the Party B.
Annexes to this contract is dependent on the content of the main body of this contract, is an integral part of this contract, and this contract has the same legal effect, part of the contents of the annexes have been formed or will be formed in the follow-up process.
Annexes constituting this contract include but are not limited to the following:
1. Annex I: Contract List Quotation Form
2. Annex II: Technical Requirements for Equipment
3. Annex III: Quality Warranty Agreement
Signatures and seals of both parties to the contract:
Party A (Chapter): __________ Party B (Chapter): __________
Representative: __________ Representative: __________
Date: __________ Date: __________
Simple Transformer Purchase Contract Sample 3
Buyer: (hereinafter referred to as Party A)
Seller: (hereinafter referred to as Party B)
After full and friendly consultation between A and B, on the purchase of ___ transformer _______ project hereby enter into this contract in order to *** with compliance.
First, the name of the equipment, specifications, quality and quantity
Second, the contract price
The total price of the equipment is RMB (capitals): _________ The total price includes the amount of the equipment, packaging, transportation and insurance, loading and unloading costs, installation and related materials, commissioning costs, software costs, inspection fees and training required and taxes.
Third, the entry into force of the contract This contract shall enter into force upon signature by both parties.
Fourth, payment
Goods acceptance, equipment installation, commissioning and normal operation, Party B for the end of Party A training, Party A without question, Party A to pay Party B 100% of the total contract price.
V. Delivery, packaging and acceptance
1. Delivery location: according to the location specified by Party A.
2. Delivery time: after the contract comes into force ____ when _____ days.
3. Party B will transport the goods to the delivery place at one time. And 24 hours before the arrival of the arrival of the name, model, quantity, external dimensions, unit weight and notes, etc., to notify Party A in writing.
4. Equipment packaging should be in line with national standards to ensure that the equipment is not damaged during transportation, due to improper packaging caused by any damage or loss of equipment during transportation, Party B is responsible.
5. The equipment will be delivered to the construction site by Party B, and Party B will be responsible for transportation and unloading.
6. When the equipment arrives at the site, Party A and Party B must be present and confirm the integrity of the packaging, then Party A will inspect the goods. Party B shall send someone to the site according to the time arranged by Party A, count and accept the goods, and sign to confirm. If the goods are found to be inconsistent with the packing list, Party B shall be responsible for making up or taking back the goods. If Party B can't arrive on time, Party A has the right to open the box for inspection and make records of missing pieces and damages, and Party B should recognize and be responsible for solving the problem.
7. Party B is responsible for equipment installation and commissioning, until the equipment runs normally. Final acceptance after this. If the equipment can not pass the acceptance, Party B should return the equipment and refund Party A all the money.
8. Party B should be used to install, debugging process required for a variety of tools, instruments and perishable parts.
Sixth, product quality assurance and after-sales service
1. Party B should be strictly in accordance with the relevant national standards and regulations for manufacturing and testing, materials and components are new and unused, and in line with the provisions of the Annex to this contract. To ensure product quality. The equipment shall be technically inspected and meet the relevant national standards before leaving the factory.
2. Party B is responsible for free training for Party A's operation and maintenance personnel. Including: basic principles, operation, use and maintenance.
3. After the equipment is put into normal operation, Party B should regularly visit the user.
VII. Responsibilities and Obligations
1. In the installation and commissioning of equipment, such as Party B, Party A should facilitate the diet of Party B's personnel, the cost of which is at your own expense.
VIII. Liability for breach of contract
1. Party B can not deliver the goods on time, in addition to the force majeure, Party B shall pay to Party A for the extension of liquidated damages, the daily amount of 0.3% of the total contract price of ￥ _________ calculated.
2. Party A delayed payment (except for justified refusal to pay). Party B shall pay the delayed payment amount of the delayed liquidated damages, the daily amount of the delayed payment of 0.3% of the amount calculated, the payment processing period of 10 working days.
3. Both parties must strictly implement the "Chinese People's *** and State Contract Law" of the relevant provisions of the liability for breach of contract.
IX. Cancellation and change of the contract
1. When one party to the contract requests to change or cancel the contract, the original contract is still valid until a new agreement is reached. The party requesting the change should promptly notify the other party, the other party to give a reply within 15 days of receipt of the notice, and if the reply is not given after the deadline, it shall be deemed to have agreed.
2. If Party B requests to change or terminate the contract, Party B shall be responsible for the losses caused.
X. Settlement of contractual disputes
1. Party A and Party B, in case of contractual disputes, should be based on the principle of mutual understanding and mutual accommodation, mutual respect, peace and friendship.
2. The place of performance of this contract is _________, if the two sides can not reach an agreement through negotiation, according to the "Chinese People's *** and the National Code of Civil Procedure" and "Chinese People's *** and the State Contract Law" of the relevant provisions of the Arbitration Institution of the _________ to apply for arbitration or bring a lawsuit.
3. If there is an attachment, the attachment is also an indispensable part of this contract has the same legal effect.
XI, Disclaimer
This contract can not be performed due to force majeure, the two sides in accordance with the relevant state laws and regulations.
XII, other agreed matters
This contract is not exhaustive, can be agreed by both parties and sign a written supplementary agreement.
This contract in one _________ copy, of which the original _________ copy, copy _________ copy, all have the same legal effect.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ ____ ____ _________ ____ _________ Day
Simple transformer procurement contract 4
Buyer: (hereinafter referred to as Party A)
Seller: (hereinafter referred to as Party B)
The buyer and seller according to the equipment project on March 20__ (Bidding No.: ( HNQSZB20__0045 ) bidding results and the tender document requirements, and according to the "Chinese People's *** and State Contract Law" and other relevant laws and administrative regulations, while in equality, fairness, honesty and credit principle, by mutual consensus, to enter into this procurement contract.
First, the contract documents: bidding documents, bidding documents, technical clarifications and responses to the inquiry, all the contents of the contract is an integral part of the contract, and the contract has the same legal effect, when the documents are quite contradictory to the time the latter shall prevail.
Second, the transformer model specifications parameters:
See the technical requirements of the bidding documents
Third, the contract amount (unit: yuan)
The above price is settled in RMB.
Fourth, the quality of equipment requirements and the seller is responsible for the quality of conditions and deadlines: the seller to provide the equipment must be in line with the requirements of the bidding goods specifications and technical indicators. Seller of the equipment to provide not less than 24 months of warranty (equipment and other more than 24 months warranty provisions in accordance with the original provisions of the implementation), the warranty period is not due to the buyer's man-made reasons for quality problems, the seller is responsible for the package repair, replacement or refund, and to bear the actual cost of the exchange or return. If the seller cannot repair or exchange the product, it will be treated as a breach of contract. If the failure is caused by the buyer's improper use, the seller is responsible for repair, replacement or refund, the cost of both sides to negotiate.
V. Delivery appointment period: 30 days, if there is any change, the buyer according to the progress of construction, the need for early delivery, half a month in advance to inform the seller delivery, the seller must be required by the buyer to deliver the goods to the designated location. If you need to delay delivery more than one month, three months or less, by the seller to keep no additional charges for storage.
Six, unit installation and commissioning and technical services:
6.1 The contract for the goods seller in the production of the buyer should confirm the specifications before the model parameters, the buyer has the right to change the bidding documents in the bidding for the type of goods specifications, the price of the change in reference to the original the same or similar to the bidding for the type.
6.2 Equipment production process, the seller should cooperate with the buyer to supervise the manufacture of equipment production process by the quality inspection.
6.3 Installation and commissioning in accordance with relevant standards.
6.4 The seller is responsible for the costs of the seller's personnel during the installation and commissioning.
6.5 The seller shall submit product instruction manuals, product certificates, warranty cards and related accessories and technical data to the user units along with the equipment, as well as train maintenance personnel for the user units free of charge.
VII. Quality Assurance:
7.1 After the seller delivers the equipment to the designated place of the site, the equipment should be properly stored to ensure smooth installation and prolong the service life.
7.2 The seller's equipment installation and commissioning, and in the completion of the project by the local Bureau of Technical Supervision acceptance for the transfer of formalities for the date of completion of the project (not less than 24 months), to provide free service to the buyer.
7.3 In case of failure, the buyer should notify the seller, the seller will reply immediately after receiving the notification, and arrive at the buyer within 24 hours for maintenance.
7.4 The seller shall be fully responsible for the quality of the equipment supplied and its internal installation.
VIII. Payment
8.1 After signing the contract, the seller to provide to meet the design requirements of the design institute drawings, information within ten days after the buyer to pay 20% of the total contract price of 180,000 yuan.
8.2 After the equipment arrives at the site and passes the installation and inspection, and the buyer receives the seller's full 17% VAT invoice and audited within one month after the payment of 65% of the total contract price of 585,000 yuan.
8.4 The balance of 15%, 135,000 yuan as a quality warranty, equipment installation and commissioning is completed and put into operation within 24 months, during which the product is damaged due to design and manufacturing quality problems, the seller is responsible for the replacement, replacement, equipment quality assurance period (24 months) is full, no quality problems, the buyer to pay within seven days.
IX. Acceptance
9.1 Acceptance criteria see the third part of the bidding documents and the seller to provide equipment acceptance standards, safety and technical specifications.
9.2 After the equipment arrives at the site, the buyer will participate in the acceptance of the equipment together with the seller, the receiver and the supervisory unit***.
9.3 After the equipment installation and commissioning by the self-inspection, the buyer, the installation company, the supervision company and the local quality inspection department is responsible for acceptance.
X. Warranty period
Warranty period from the date of completion and acceptance of the project for handover procedures, a total of *** 24 months.
XI. Liability for breach of contract:
The buyer shall have the right to reject the varieties, models, specifications, quantities, and qualities delivered by the seller that do not conform to the standards stipulated in the contract. As a result of late delivery (including the delivery of the contract agreed delivery period) should also be liable for late delivery of liquidated damages for the total contract price of five thousandths of a day; at the same time, the buyer will be forfeited performance bond, while retaining the right to pursue compensation.
XII, the buyer and seller of any party due to force majeure reasons can not fulfill the contract, should promptly inform the other party can not perform or can not fully perform the reasons, and after obtaining the proof of the relevant departments, can be exempted from the responsibility of the other party in whole or in part.
xiii. Disputes over the quality of the equipment shall be appraised by Kaifeng Municipal Bureau of Technical Supervision or its designated technical unit for quality appraisal, and the conclusion of such appraisal shall be final.
XIV, the contract dispute, the two sides to negotiate a solution, consultation fails by the Kaifeng City Arbitration Commission arbitration.
XV, this contract in six copies, the buyer and seller of three copies, are equally valid.
XVI, this contract, the two sides can be supplemented in the form of supplementary agreement. Supplementary agreement and this contract has the same legal effect.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ ____ ____ _________ ____ _________
Simple Transformer Purchase Contract Model 5
Purchaser (full name): (hereinafter referred to as Party A)
Supplier (full name) (hereinafter referred to as Party B)
Place of signing:
In order to clarify the rights and obligations of Party A and Party B in the project contracting and construction, in accordance with the "Chinese People's In order to clarify the rights and obligations of A and B in the project contracting construction, in accordance with the "Chinese People's *** and State Contract Law" and "Construction and Installation Contracting Regulations" and other relevant provisions, A and B in accordance with the principle of voluntariness, equality and honesty, by consensus, signed this contract.
Article I. Overview of the contracting project
I. Name of the project: Zhangzhou Tiantong Real Estate Company Limited 800kva temporary power box-type dry-type transformers
II. Location of the project: Zhangzhou City, Longwen District, Lantian District, Lantian Village, Dongyu Village, National Trade Run Park project
Third, the procurement of content:
Article II box-type transformers within the equipment components brand requirements
First, the transformer selected in the Jun electrical transformer, transformer manufacturing in line with the technical requirements of the design and construction drawings;
Second, the low-voltage distribution components selected Changshu switchgear factory or the Shanghai People's brand products, high-voltage power distribution components selected lk or VEI brand.
Third, box-type transformer size: according to the actual needs of the bidding unit to provide programs (shell material thin steel, steel thickness of not less than 2mm, door pins for stainless steel, with lock. Warning lights, cooling, lighting and other supporting facilities are complete).
Fourth, the technical information provided by the bidding should contain: product certification, installation, use and maintenance instructions, equipment, a system diagram, installation of the base map, factory test reports and other installation and maintenance of the necessary documents;
Fifth, the manufacturing process in line with the current national and industry norms and standards, in line with the acceptance requirements of the Zhangzhou City Department of Electricity;
Sixth, the other material Must also have a 3c certificate of conformity.
Seven, according to national standards, the date of arrival, the quality of three packages for one year.
Article III of the contract price
First, the total contract price of the contract dry tax-inclusive CNY for the project: yuan whole (yuan whole). The price includes transportation, design, testing, installation and acceptance, handling, insurance, security, taxes, necessary to complete the installation of the transformer with the work and other costs.
Second, the price of payment: the completion of the project, by the Party and the city power supply department acceptance and power supply operation within five working days after the payment of 95% of the total contract price, the rest of the amount from the date of acceptance of the project power supply one year after the payment, non-interest-bearing. Bidder payment before the bidder to provide the appropriate amount of legal invoices, otherwise the payment time will be postponed.
Article IV supply time: 30 calendar days after the signing of the contract.
Article V packaging standards, packaging supply and recycling: in line with the requirements of transportation and temporary storage in the open air environment, sun, moisture, water and other requirements.
Article 6 Acceptance standards, methods and objection period: If there is any objection, it shall be raised within three days after the arrival of the goods, after which it shall be treated as acceptance.
Article VII random spare parts, accessories, tools, quantity and supply method: to provide products factory test reports, certificates.
Article VIII Responsibility for breach of contract
First, the supplier can not be supplied overdue, must obtain the consent of Party A in advance, if not agreed to unilaterally delay the delivery time, Party B will be 1% of the contract price / calendar day price to pay liquidated damages. Late more than 15 days, Party A has the right to terminate the contract, requiring Party B to bear 20% of the total contract price of liquidated damages.
Second, Party A did not pay the date agreed in this contract, every day late, the contract price of 1% / calendar day price to pay liquidated damages
Article IX dispute resolution
All disputes arising out of the implementation of this contract shall be resolved through consultation between the two parties. If the dispute cannot be resolved through consultation, both parties may file a lawsuit to the People's Court of the place where this contract is signed.
Article 16 Effect of the contract
This contract in quadruplicate, Party A will hold two copies, Party B will hold two copies. This contract shall enter into force on the date of signature and seal of both parties (date of signing), and shall expire when all the terms of this contract are fulfilled. This contract is not exhaustive by the two sides can sign a separate supplementary agreement.
Party A: Party B:
Year Month Day:
Simple Transformer Purchase Contract Article:
★ Purchase contract model Daquan
★ Selected transformer purchase contract model
★ Transformer Purchase Contract
★ Simple stone procurement
★ Transformer Purchase Contract
The most important thing is to purchase a transformer. The latest 3 model contracts
★ Simple version of the lamps and lanterns purchase and sale contract the latest model
★ 2019 procurement department's personal year-end summary of the work of the 5 model procurement department work summary
★ Standard version of the food procurement contract model
★ Simple construction commissioning contract model 3 the latest
var _hmt = _hmt || []; ( function() { var hm = document.createElement("script"); hm.src = "/hm.js?fff14745aca9358ff875ff9aca1296b3"; var s = document. getElementsByTagName("script")[0]; s.parentNode.insertBefore(hm, s); })();