Partner: Name , ID number: Tel:
Partner: Name , ID number: Tel:
Partner: Name , ID number: Tel:
I. In order to clarify the economic relationship and responsibilities of both parties, *** with the completion of the investment partnership task, follow the equality, voluntarily, fair and The principle of honesty and credit. According to the relevant laws and regulations, the two sides repeatedly negotiated, reached the following agreement, the following contract, hope that *** with the compliance:
Second, three partners *** with the investment, contracting ________________ a renewal of the construction project works.
Project name: ________________ (a renewal) project
Project construction site: ____________________
Third, the purpose of the partnership
By the two sides *** with the agreement, under the premise of lawfulness and reasonableness, Qiqiqi *** management, the same boat ***, in order to Collective interests,
Sacrifice me, regardless of personal gain or loss, carry forward the spirit of hard work, *** seek development, this agreement is clear that the basis for the distribution of investment profits.
Fourth, the distribution of profits and debt (loss) to assume
1, investment profit and loss distribution ratio: (________ accounted for 40%, ________, ______ each accounted for 30%) project income in the deduction of labor, machinery templates materials, and other direct costs, the first to be used for the return of the partners of the investment principal, and then distribute profits. (Such as project losses, according to the proportion of investment allocation)
2, because the investment amount for the two sides with their respective relationships around the borrowing, so the interest on the return of borrowing needs to be returned from the tripartite cooperation projects, according to their respective shares to be calculated separately, to take their own responsibility, the method of self-sustaining profit and loss.
3, each project payment to the account, if you need to pay their debts, according to the investment ratio for distribution.
4, in the process of completing this project, the three parties can be the highest monthly salary ______, as their own daily expenses, the three parties in addition to the expenses of the basic salary, shall not be misappropriated public funds, or each time will be unconditionally accepted by the proportion of the shares accounted for by the deduction of 1%, paid to the abiding party.
Six, partnership management and division of responsibility:
1, the partnership affairs of the general responsible person relations and signing and approving the works of money matters.
2, in the construction process of the team to determine, material procurement pricing and other site all affairs by the tripartite partners assigned.
3, the construction site executive technical director ________.
VII. Financial management and system
1. ________ is responsible for the management of cash and bank deposits, and hires an accountant to handle the accounts.
2, any costs ________ within the spending party, the person in charge of finance ________) can be signed by the spending, reimbursement; spending invoices and costs in ________ more than (including ________), need to be through the three-party *** with the same signature before spending, reimbursement, if one of the party is not on site to notify the consent of the phone.
3, the financial accounts of the three parties need to be open, transparent, must be reconciled once a week, the time determined by the three parties to discuss.
4, the project money to the account, immediately handed over to ________ is responsible for the management, and by the appointment of the accountant into the accounts.
5, before the end of the project, the money can only be used for all the expenses of the project, and shall not be diverted to other uses.
Eight, withdrawal agreement
During the partnership period, one party shall not withdraw, if necessary, withdrawal must be agreed by the remaining two parties to withdraw.
IX. Rights and obligations
Partners *** with the consultation *** with the management, and participate in the day-to-day affairs. (Finance, safety, quality, progress).
X. Partnership period
Partnership period until the end of the project and distribution of partnership property.
XI, liability for breach of contract and dispute resolution
Both parties must abide by this agreement, such as one party default in addition to compensation for the losses of the contracting party, but also to the contracting party to bear the total amount of the project 2% of the liquidated damages. If the two sides disagree on the agreement to resolve, such as can not be resolved by negotiation can be resolved by the Court of Appeals.
XII, the documents that make up the contract
The two sides of the project negotiations, changes and other written agreements or documents are considered part of this contract.
Signature of the partners:
Month of the year
Simple three-person partnership engineering agreement 2Partners: a (name) ________, gender: ____
ID card number: ____________________________
Current residential address: ____________________________
Contact details: ____________________________
Partner: b (name) ________, gender: ____
ID number: ____________________________
Current Residential Address: ____________________________
Contact Details: ____________________________
Partner: c (Name) ________, Gender: ____
ID No.: ____________________________
Present Residential Address: ____________________________
Contact Details: ____________________________
After friendly consultation, according to the relevant state laws and regulations, on the basis of equality, voluntariness, honesty and trustworthiness, A, B and C decided to contract the construction task of _________________ project in partnership, in order to clarify the rights and obligations of both parties, the two sides have reached the following agreement for **. **The same to comply with, a, b and b partnership contracting project external to the _____________________ company name.
Article I, a partnership purpose
Work together, the same boat ****; for the collective interest, give up my own, regardless of personal gain or loss; carry forward the spirit of hard work, **** seek development.
Article II, the scope of business
I. Project name: ___________________________________.
II. Scope of Contract: ___________________________________.
iii. Location of the project: ___________________________________.
IV. Project Cost: Tentative ______________ million RMB, finalized based on the audited price.
V. Partnership term:The partnership term is until the completion of the project of partnership construction, and the settlement of all parties.
Six, capital contribution agreement:
1, the three parties confirmed, agreed to before the start of the project by the ________ party to contribute _____ million (￥ ________) yuan, as the project pre-operation costs, etc..
2, the subsequent use of money and the owner of the project payment is not timely in place, the need to advance funds should be _____ party each out of ____________*** with the same commitment.
Risks: partnership contributions in various forms, can be in money, in kind, land use rights, intellectual property rights, other property rights and labor contributions, various forms of contributions to the property rights are not the same, the partnership agreement should be different on the different contributions to different agreements. The need for registration of property, in the partnership agreement should be clearly agreed for the registration procedures for the bearer of the obligation, for the time and for the cost of the bearer and so on.
Article 3, rights and obligations:
1, _____ participate in the day-to-day management of the partnership project; coordination of the units to check the acceptance of the work, the preparation of engineering and technical information; coordination of the relationship with the engineering and construction units. Responsible for the settlement and payment management of the project.
2, _____ is responsible for the project's engineering management, personnel scheduling materials procurement machinery management, equipment maintenance and coordination of local social relations,
3, the three parties to the form of package **** with the contracting of this project, after deducting a variety of costs (including engineering intermediary fees, the construction company dependency fee, taxes, the construction team labor costs, the project manager's management staff wages, bonuses and Various types of insurance, materials, construction machinery leasing costs, construction equipment purchase costs, construction utilities, office rental costs, temporary facilities, security maintenance facilities, pre-settlement costs, hospitality, and other expenses recognized by both parties for the project), the profit gained a _______% b _____% c _____%; conversely, in line with the principle of risk **** share, such as contracting this Project losses or construction. Relevant penalties, by the A B C parties according to their respective profit-sharing ratio, respectively.
4, the three parties determined that the use of project department contracting form of organization and construction, ______ party in principle does not participate in the day-to-day management of the operation of the project department, but has the right to supervise the progress of the project, quality. Project manager candidate by both parties **** with the issuance of a power of attorney.
5. ______ party and the project department have the right to select the construction team on the basis of merit and determine various unit prices. Purchase of engineering bulk materials and machinery tools, rental construction machinery, the project department reported to the competent leadership recognized before implementation. If the project department authority within the scope of responsibility, ______ party shall not interfere, or according to the provisions of the liability for breach of contract.
6, the three parties to ensure that the project funds earmarked for the project, the project set up a special account, the construction company to pay the project funds into the special account, ______ party for the partnership period of the project management responsible for the partnership project, the partnership project, all financial income, expenditure are subject to ______ party agreed to spend and into the account; to eliminate unnecessary expenditure, reduce cost expenditure.
7, material purchases and other expenditures should be issued formal invoices, part of the cost of invoices can not be issued expenses, must be verified and approved by the party in charge of reimbursement from the financial reimbursement. All reimbursement vouchers must be signed by the project department supervisor to verify the reimbursement, during the construction period, managers should pay attention to identify the collection of various types of invoices for financial management.
8, the three parties to play their respective strengths, in the project capital turnover, coordination of the relationship between the parties and construction management to do their best, to mutual understanding and mutual concessions, *** with the face and overcome the difficulties encountered in the process of construction, in order to ensure that the construction of the project is carried out smoothly.
9, ______ party has the right to the relevant departments to guide the work of the normal hospitality expenditures to be approved by the power, the relevant costs are verified and signed before reimbursement. If special circumstances due to urgent matters need to exceed the amount of money, need to report to the partnership approval before spending. When the project funds are tight, no one is allowed to use more money.
10, the distribution of surplus, according to the proportion of the distribution of this agreement;
11, the partnership, such as debt, the first by the partnership property to repay; partnership property is not enough to pay, according to the proportion of partners.
Risks: The distribution of rights and interests and the division of responsibilities between partners should be clear. Although the partnership has unlimited joint and several liability to the outside world, the internal partners still have to share the dividends and debts. Some partnerships do not agree on this, which can lead to disputes between the partners when distributing dividends or incurring debts, causing unnecessary damage to the enterprise.
Article 4, withdrawal:
During the partnership period, one party withdraws from the partnership will seriously affect the construction of the partnership project, shall not be withdrawn from the partnership; withdrawal from the other party's consent to the implementation of the
①, need to be justified enough reasons to withdraw from the partnership;
②, shall not be withdrawn from the partnership when it is unfavorable;
③, withdrawal needs to be agreed with the other party to implement;
③, the withdrawal of three months in advance to inform the other partners in writing;
④, the withdrawal of the property status of the withdrawal of the settlement, regardless of the way of capital contribution to the cash settlement;
⑤, without the consent of the partners to withdraw from the partnership to cause losses to the partnership, should be compensated or even legal responsibility.
⑥, the transfer of capital: partners are allowed to transfer their own capital.
Article 5: Prohibited behaviors
1. Without the consent of all partners, it is prohibited for any partner to carry out business activities in the name of the partnership privately, such as the benefits of their business to the partnership, and the losses caused by the actual loss compensation.
2. It is prohibited for a partner to operate a business that competes with the partnership.
Article 6: Liability for breach of contract
1. In case of violation of the above provisions, if one party causes losses to the other party, the responsible party (the party at fault) shall compensate the other party for double the losses.
2. If one party falsifies and causes significant loss to the other party, in addition to double compensation for the loss of the non-responsible party, the non-responsible party shall have the right to decide whether to terminate the Agreement, whether to terminate the cooperation with the responsible party, and whether to contract the project separately. If the non-responsible party requires the responsible party to continue to fulfill this agreement, the responsible party must fulfill it unconditionally.
3, any party without the consent of the other party, do not give unauthorized withdrawal from the contracting of the project, or should be double compensation for the other party's losses.
4, the two sides promise: during the construction period, any party without the consent of the other party can not be proposed to the owner of the separate contracting of this project, otherwise regarded as a breach of contract, the defaulting party shall double compensation for the other party's losses, the non-defaulting party has the right to decide whether or not to continue to work with the defaulting party, which caused the loss of the defaulting party by the defaulting party to be responsible for their own, such as non-defaulting party to continue to fulfill the agreement, the defaulting party shall not be rejected, must be Unconditional fulfillment.
5, A, B and C parties and the owner, ______ party, the project department, construction team, material suppliers and other relevant departments signed the contract, has the same legal effect. Matters not covered by the A, B and C parties to negotiate a separate supplemental agreement, the supplemental agreement and this agreement has the same legal effect.
Article VII, matters after the termination of the partnership:
①, the immediate election of the liquidator, and invite the company ___________________ to participate in the liquidation;
②, after the liquidation of the surplus, if any, in the order of the collection of claims, the settlement of debts, the return of capital contributions, and the proportionate distribution of surplus property Carried out. Fixed assets and indivisible, can be sold to the partners or a third party, the price to participate in the distribution;
③, after the liquidation of the loss, regardless of how much the partners contributed to the partnership **** the same property to repay the partnership property is insufficient to pay off the portion of the partners in proportion to the contribution of the partners.
Article VIII Dispute Resolution
All disputes arising from or in connection with this Agreement shall be negotiated between the two parties first *** with each other, and if the negotiation fails, the dispute may be brought to the People's Court of the location of the Party A.
The parties are responsible for the settlement of any disputes arising from or in connection with this Agreement.
Risk communication: the agreement on dispute resolution, you can choose to the court of competent jurisdiction or choose arbitration, the essential difference between the two is that if you agree to arbitration to resolve the arbitration of a final decision, the agreement to the court of lawsuit two trials. In the agreement on jurisdiction, also note that the agreement on court jurisdiction can not be agreed in the arbitration jurisdiction, both can only choose one.
Article IX, the entry into force and termination of this Agreement.
This agreement shall enter into force on the date of signature by both parties, and shall expire on the date of completion and acceptance of the project for settlement, and profit distribution.
Article 10, this agreement in triplicate, each of the three parties a copy, with the same legal effect.
Signature of Party A: _________________
Tel: ________________
Signature of Party B: _________________
Tel: _______________
Signature of Party C: _________________
Contact number: _______________
Place of signing: __________
Date of signing: ____ ___Month___, 2013
Simple Three-Person Partnership Project Agreement 3Partner: ________ (hereinafter referred to as Party A)<
Partner: ________ (hereinafter referred to as Party B)
Partner: ________ (hereinafter referred to as Party C)
A, B and C, after equal consultation, have reached the following agreement on the contracting of the main line section of the Leya Expressway Roadbed Project for all side ditch, shoulder wall and retaining wall works for all parties to abide by.
First, the purpose of partnership
In the legal and reasonable premise, good engineering construction, and then maximize the profits of all parties.
Second, the partnership project and scope of operation
Loyal Expressway mainline section of the roadbed project all side ditches, shoulder walls, retaining walls.
Third, the partnership period
The partnership period until the completion of the project of the partnership construction, the parties to the settlement of the end.
IV. Method, amount and time of capital contribution.
1, Party A to the previous contracted works and existing machinery contribution;
2, Party B to the cash contribution of two million yuan;
3, Party C to the cash contribution of eighty million yuan;
4, the shares of the equal share;
5, in June 15, 20xx before the Party B to contribute the amount of two million yuan and the Party C to contribute Funding amount of eighty million yuan can not be fully in place, the previous part of the capital does not calculate the shares, do not calculate the interest, to be completed after the completion of the project does not have a loss on the return of the principal, if there is a loss, as usual, to bear the loss of the part.
Fifth, the distribution of surplus and debt
1, the distribution of surplus: equal shares;
2, the partnership, such as debt, the first by the partnership property repayment; partnership property is insufficient to pay, according to the proportion of the bearer.
Sixth, withdrawal
During the partnership period, one party withdraws from the partnership will seriously affect the construction of the partnership project, shall not be withdrawn from the partnership; withdrawal from the other party's consent to the implementation of; without the consent of the partners to withdraw from the partnership to the partnership losses caused by the partners, shall be compensated.
VII, rights and obligations
1, Party A for the partnership period of engineering, internal work, the person in charge of finances, partnership projects, all financial income, expenditure need to be signed by Party A agreed to spend and enter the accounts; at the same time, Party A to participate in the day-to-day management of the project;
2, Party B is responsible for the project's materials,
2, party B is responsible for the project's materials, engineering quality, progress, equipment maintenance and coordination of local social relations, and participate in the day-to-day management;
3, party C is responsible for the project personnel, progress, safety, and participate in the day-to-day management;
4, party A, B, party C **** with the decision of the major matters of the partnership.
Eight, prohibited behavior
1, without the consent of all partners, prohibit any partner to carry out business activities in the name of the partnership;
2, prohibit the partners to withdraw from the partnership in the case of partnership disadvantage.
Nine, the expiration of the partnership
The expiration of the partnership period, the two sides in accordance with the partnership agreement for the settlement of profits and losses are borne in proportion to the distribution.
X. Dispute resolution
Disputes between the partners should be *** with the consultation, in line with the principle of the development of the partnership to be resolved. If the consultation fails, you can resort to the court.
1, this agreement shall enter into force upon signature by all parties, each party to sign a copy;
2, the outstanding matters, separate consultation, and enter into a supplementary agreement.
Partner: _________ ID No. _________ Tel: _________
Partner: _________ ID No. _________ Tel: _________
Partner: _________ ID No. _________ Tel. Contact phone number: _________
___Year ___Month ____
Simple three-person partnership engineering agreement 4Party A:
ID card number:
Party B:
ID card number:
Party C:
Party A, B, and C through Friendly consultation, on the partnership contracting Xiantao City and the International City residential building project, reached the following agreement for all parties to abide by.
First, the purpose of partnership
In the legal and reasonable premise, good construction, and then maximize the profits of all parties.
Second, the partnership project and scope of business
The partnership project to the winning contract to confirm the content and scope of the project shall prevail; a, b, c three-party partnership contracted projects, external to the nominal appearance.
Third, the term of partnership
The term of partnership until the completion of the project of partnership construction, the parties to the settlement is completed.
Fourth, the amount, mode and proportion of capital contribution
1. A, B, C, the three sides of the partnership matters of the investment amount of RMB 10,000 yuan, Party A, 40% of the proportion of investment that is 10,000 yuan, Party B, 30% of the proportion of investment that is 10,000 yuan, Party C, 30% of the proportion of investment that is 10,000 yuan.
2. If the partnership process of ten thousand investment amount is insufficient to require additional contributions, party C due to limited funds do not bear the additional investment, by party A, party B, the two sides negotiated on the additional investment contribution, party C according to the annual interest rate of % of the additional investment to the additional investment contributions to the party to pay the total additional investment in the part of party C accounted for the proportion of the 30% interest.
V. Distribution of surplus and debt
1. A, B, C, respectively, 40%, 30%, 30% of the three parties to distribute the surplus, shall not be due to the party C did not add the investment to change the above distribution ratio; but the party C to be in the project back to the project or the three parties to allocate the profit of the first deduction of additional investment in the proportional part of the principal of the proportional part of the principal of the C party and the interest to the additional investment in the capitalist.
2. If the partnership has debts, the debts shall be repaid by the partnership property first; if the partnership property is insufficient to fulfill the debts, the partners shall bear the debts on the basis of the distribution ratio of each partner ****.
VI. Rights and obligations
1. The financial affairs during the partnership period shall be accounted for by A, B and C*** together, and all financial income and expenditure of the partnership project shall be agreed by A, B and C before spending and entering into the account;
2. A is responsible for the project's project management, equipment maintenance and coordination of the local social relations, and participates in the day-to-day management;
3. 3. Party A, B and C **** the same decision on major partnership matters.
VII. Prohibited behavior
1. Without the consent of all partners, any partner is prohibited to carry out business activities in the name of partnership;
2. Partners are prohibited from withdrawing from the partnership when the partnership is unfavorable.
VIII. Expiration of partnership
At the end of the partnership period, the three parties shall make settlement according to the partnership agreement, and the profit and loss shall be borne and distributed proportionally. Fixed assets and other indivisible things can be sold to the partners or third party at a price, and the price will participate in the distribution.
IX. Settlement of disputes
If there is any dispute between the partners, they should **** consult with each other and settle it on the principle of favoring the development of partnership business. If the consultation fails, the court may be resorted to.
X. Effective and supplementary
1. This agreement shall enter into force after the signature of the three parties, A, B, C, each of the three parties to sign a copy of;
2. Matters that are not yet concluded, the three parties to consult separately, and enter into a supplementary agreement.
Party A:
_____ year _____ month _____ day
Party B:
_____ year _____ month _____ day
Party C:
_____ year _____ month _____ day
Simple three-person partnership engineering agreement 5Partner: ________ (hereinafter referred to as Party A)
Partner: ________ (hereinafter referred to as Party B)
Partner: ________ (hereinafter referred to as Party C)
A, B, C, the three parties, after equal consultation, on the partnership contracting ____ project windows and doors, reached the following agreement.
a, a, b, c, three parties selected ________ as a representative of the signing of ________ year ________ month ________ contract, this contract for the a, b, c, three parties **** with the partnership project contracting contract. The original shall be kept by the representative signatory and two other copies shall be made and handed over to the partners.
Second, the purpose of partnership. Under the premise of lawful and reasonable, get the project, and then maximize the profits of all parties, *** enjoy the benefits, *** bear the risks.
Third, the partnership period. The partnership period until the completion of the construction project, the parties to the settlement is completed.
Fourth, the proportion of capital contribution and bank account:
A, B, C three-party cash contribution, the proposed total project contribution of ________ million yuan, Party A contributed ________ million yuan, accounting for ________% of the total capital contribution, Party B contributed million yuan, accounting for ________% of the total capital contribution, Party C contributed ________ million, accounting for ________% of the total capital contribution.
Now, according to the project, the capital contribution is completed in two times, one for the deposit of the preliminary project, and the other for the purchase of materials and subsequent expenditures.
The first engineering deposit of 10,000 yuan by the three parties *** with the contribution, of which party A contributed 10,000 yuan, party B contributed 10,000 yuan, party C contributed 10,000 yuan, the deposit returned to continue to do for the three parties to contribute to the account;
A, B, C, the three parties to open a joint bank card, this card for the three-party funds to deposit, withdrawal and the project's only account number, the project and the deposit after the refund of the unified directly into this account. account. The account of the cash, transfer and other funds to reduce the situation, must be signed by the three parties to deal with. No party has the right to ask the engineering party to pay cash to someone or into their private account, if it happens, resulting in all the losses borne by their party.
A, B, C three-party joint bank card: account bank: ________ bank, ________ account name: account account number: ________ (here can be followed up for the bank card added, A, B, C three-party hand-printed to confirm)
V. Distribution of surplus and assumption of debt:
1, surplus distribution. p> 1, surplus distribution: surplus to the A, B and C tripartite capital based on proportional distribution.
2, the partnership such as debt, the first by the partnership property to repay, partnership property is not enough to pay off, to the partners of the agreed capital based on a proportional assumption.
3. During the period of partnership, any party shall not act in such a way as to gain personal benefits to the detriment of the partners, and if any such act occurs, he/she shall bear all the losses incurred by the partners.
4, the three-party cash into the account, must be on time, in place in full, any party funds can not be in place in a timely manner, such as to the partners caused by the loss of one of the party to bear.
Sixth, withdrawal: the partnership period in principle shall not be withdrawn; such as encountering special reasons for withdrawal, should be agreed by the three-party consultation;
Seven, the project's day-to-day management
1, a natural month must be inventory of materials inventory, tools inventory, staff payroll, miscellaneous expenditures list.
2, all expenditures need to be signed by three parties before the next account. Expenditures for the month need to be accounted for the same month, more than two months without accounting for the expenditure of personal responsibility.
3, major expenditures and major partnership matters should be decided in advance by the A, B and C tripartite **** with the decision of the tripartite phone decision should be made in the most recent accounts under the date of the supplementary signing of the written resolution.
Eight, the expiration of the partnership. At the end of the partnership period, A, B, C, C, three parties according to the partnership agreement for settlement, profit and loss are proportionate to the distribution, bear; a party to the distribution of the receivables of the other party to assist in the recovery of the obligation.
IX. Liability for breach of contract.
1, without the consent of the partners and unauthorized withdrawal, causing losses to the partnership should be compensated.
2, one of the partners in violation of other agreements of this Agreement, causing losses to the other party, shall be liable for compensation.
X. Others. In case of disputes between partners, they should **** consult with each other and solve them on the principle of favoring the development of partnership business. If the consultation fails to arbitrate to the Arbitration Commission to submit to arbitration.
Signature of Party A: ________ Signature of Party B: ________ Signature of Party C: ________
________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________ ________
Simple Three-Party Partnership Engineering Agreement 6A: ________
B: ________
C: ________
According to the Contract Law of the People's Republic of China and relevant laws and regulations, and in the spirit of long-term cooperation, the principle of mutual benefit and reciprocity, and through friendly consultation, A, B, C Three parties to cooperate in construction projects, on matters related to cooperation, hereby enter into this contract.
First, the proportion of capital:
A: 300,000 yuan
B: 300,000 yuan
C: 300,000 yuan.
Second, the distribution of shares: a *** divided into three shares, the distribution of shares as follows:
A: 1 share B: 1 share C: 1 share
Third, the responsibility of the parties:
1, the responsibility of the A and B:
1.
(1), responsible for the contact of the construction project, and coordination with the project contributor and the engineering agency
(2), coordination of the whole project in the middle of the problem
2, C is responsible for:
(1), is responsible for the qualification of the company to negotiate with the qualification of the company as well as the relevant contractual matters.
(2), responsible for the qualification of the company's bid, qualification and other related materials for bidding.
(3), the qualification company to do the work, responsible for negotiating with the qualification company profits.
(4), the qualification company does not do engineering, engineering subcontracting, responsible for negotiating profits with the qualification company.
(5), the qualification company does not do the project, the project is not subcontracted that the shareholders to do the project, responsible for negotiating with the qualification company profits. To manage and supervise the construction works.
3, A, B, C tripartite to the construction project to save costs, honest cooperation.
Fourth, the related costs and expenses:
1, A, B and engineering funders and engineering agencies to coordinate you, public relations costs first self-care, settlement is included in the cost of the project.
2, C for bidding the registration fee, buy bids, do the bidding costs, etc., included in the cost of the project.
3, engineering bidding for the deposit, with the contributor's bank for the same period of medium interest, all interest is included in the cost of the project.
4, the construction of materials, machinery, wages, etc. are included in the cost of the project.
5, the qualification company to do the work, not to do the work, the interest given to the qualification company is included in the cost.
V. Liability for breach of contract
1, after the signing of this agreement, any party to the contract does not fulfill their respective obligations in accordance with this agreement, infringement of the interests of other shareholders, resulting in losses, you need to compensate for the relevant losses.
2, disputes can be resolved through negotiation, and if the negotiation fails, a lawsuit can be filed with the People's Court of New Caijing with litigation jurisdiction.
Six, changes and termination of the agreement:
1, the three parties must be initiated at the same time to modify, other modifications are invalid.
2, the termination of this agreement must be agreed by all shareholders.
Seven, the agreement is supplemented:
This contract has not been concluded with the three parties **** with the consultation of the signing of the supplementary agreement, the supplementary agreement and the agreement has the same legal effect.
VIII, the contract takes effect:
This contract is in triplicate, each person holds a copy, since the three signatures take effect.
Signature of the first party: ________ Signature of the second party: ________ Signature of the third party: ________
____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____ ____