______ Model Hardcover Room Renovation Contract
Party A: _______ Real Estate Development Co., Ltd (hereinafter referred to as Party A)
Party B: _________________________ (hereinafter referred to as Party B)
According to the Chinese People's **** and the State of China's "Chinese People's **** and the State of China's Contract Law
According to the Contract Law of the People's Republic of China, the Construction Law of the People's Republic of China, and relevant laws and regulations, and combining the relevant contents of the Bidding Documents and the actual situation, Party A agrees to contract Party B to carry out the construction of "_______ Finishing and Remodeling Project". In order to clarify the rights and obligations of both parties, to ensure that the project is completed on time and with high quality, by both parties **** with the consultation reached agreement on the signing of this contract.
I. Project Overview
1. Project Name: _______ Refinishing and Remodeling Project
2. Project Address: ___________________________________
3. Project Structure: frame shear wall structure
4. Building Area: ______________ square meters
5, project quality: to ensure a one-time acceptance rate of 100%, the quality of excellent.
6, the construction unit: _______ Real Estate Development Co., Ltd
Two, the project contracting method
To take the package labor, package materials, package machinery, package construction period, package quality, package civilized construction, package safety, package security, package finished product protection of the contracting method.
Three, the scope of contracting
Scope of contracting: according to the construction drawings shown in _______ all the projects within the refurbishment and remodeling
Four, Party B contracting indicators
1, the construction period: _______ days
2, the quality of the project: to ensure that a one-time acceptance of the pass rate of 100%, the quality of excellent.
3, safety production:
3.1 Strict implementation of the relevant provisions of the local government industry management and Party A's rules and regulations;
3.2 Elimination of casualty accidents;
3.3 No major machinery and equipment accidents and major fire accidents;
3.4 Any safety accidents occurring in the course of the construction process due to the negligence of Party B, Party B will bear All responsibilities and losses;
4, civilized construction: in line with the requirements of the _______ city standard chemical site;
5, technical data: to achieve timely, accurate, complete file, and is responsible for the completion of the project file data according to government industry regulations to organize the file data to the Party unified archiving.
6 applicable norms:
A. Construction quality acceptance specification for building electrical works; B. Construction and acceptance specification for building ground works; C. Building water supply and drainage and heating works quality acceptance specification; D. Construction project management specification; E. Construction project document filing and organizing provisions; F. All other applicable to the project's current standards and norms, regulations, provisions.
V. Contract Duration
1. Construction Duration: Starting date _____ ___Month___, ___Year; the total construction period is _____ calendar days (including public holidays and public holidays, bad weather) to complete the project or within the period of time extended in accordance with the terms of the contract documents.
2. If Party B cannot complete the works according to the time agreed in the contract, Party B shall be liable for breach of contract and shall pay liquidated damages to Party A. If there is any increase in the works or obstruction caused by the Contracting Authority, the Contracting Authority shall notify the extension of the works in writing by the actual obstruction. If all the notices of extension plus the completion date listed above, still can not be completed on time, according to each day of delay, according to the contract amount of five ten thousandths of the compensation; Party A may be deducted from any amount due to Party B this compensation fee or other ways to recover this amount, the payment of this compensation fee does not relieve the Contractor should be completed the work of the responsibility of the Contractor or the contract provisions of the other responsibilities.
3. Party B shall organize the production according to the "construction organization design" approved by Party A, participate in the regular production meetings organized by Party A, and complete the construction tasks on time or ahead of schedule according to Party A's progress plan, and accept Party A's inspection and supervision of the progress. If the actual progress of the project is not in accordance with the confirmed progress, Party B shall put forward corrective measures according to Party A's requirements and implement them after Party A's confirmation.
Sixth, quality standards
1, the quality of the target: a pass rate of 100% acceptance; quality to achieve excellent; no acceptance criteria for the project must be achieved to the satisfaction of Party A and the designer.
2, the quality of the project if the above requirements are not met, the contractor deducted performance bond, in the settlement of the project price directly deducted, and must be unconditionally reworked to the excellent and the party and the designer's satisfaction, if the rework is still unable to meet the requirements, to bear all the losses caused by this.
3, Party B shall undertake the quality assurance of its construction projects, quality assurance content for all construction quality issues related to the decoration works.
4, the quality warranty period is two years, during the warranty period, Party B shall send someone to repair within 24 hours of receiving the warranty notice, otherwise Party A may entrust the third party to repair, the cost incurred by Party B. Party B shall deduct the cost from the warranty. Party A deducted from the warranty, the cost of the shortfall can be regarded as a debt to Party B to claim back.
5. The warranty is a performance bond, without interest.
Seven, the contract price
1, this contract to take the lump-sum contracting, the contract lump-sum price of _______ yuan (_______ yuan whole).
2. The sales tax of the construction project shall be borne by Party A. Party A shall provide Party B with the tax exemption certificate, while Party B shall provide the official project invoice.
3. The above price has included the labor cost (including overtime, rush work and other costs), material cost, machinery cost (including the cost of entering and leaving the site), vertical transportation cost, the cost of paying the government departments, the cost of licensing, insurance, medical fee for work-related injuries, sewage, garbage removal, cleaning inside and outside of the site, safety and civilization construction costs, coordination of neighboring residents, on-site protection of seedlings, the cost of protection of urban pipeline networks and pipelines in and around the site, and the costs for the protection of city pipeline networks and pipelines in and around the site. surrounding urban pipe network and pipeline protection fee, remedial measures, risk fee, management fee and other unforeseen and other costs and so on.
4. This contract includes all renovation and remodeling items in the drawings.
5. Confirmation of the quantity of work:
①The lump sum price has taken into full consideration the increase of Party B's workload and materials due to the quality deviation of the construction of the main structure, and Party A will not apply for any visa formalities and increase in costs for this part.
②In case of design changes, technical approval, work contact (all need to be confirmed by the Design Institute) and Party A's work instructions, Party B needs to be 25 days before the end of each month to change the part of the month's budget reported to Party A, Party A in the receipt of this budget within 5 days after the contract agreed to review the completion of the verification within 24 hours after the verification of notification to the Party B confirmation of the amount of work, the amount of work and budget will be added to the final amount of confirmation of both sides! and the budget will be added to the final settlement total price, and Party A will not recognize it if it is late.
③If there is an increase in the project site visa (must be confirmed by the project manager's signature), etc., Party B needs to be in the 25th day of each month will occur in the month of the visa and the budget reported to Party A, Party A in the receipt of the budget within 30 days after the contract agreed to review the completion of the verification, and in the verification of the amount of notification to Party B within 24 hours to confirm the quantity of work, both parties to confirm the amount of work and the budget will be added to the final settlement price, after the delay in reporting, Party will not recognize. settlement total price, the Party will not recognize if it is not reported to Party A after the deadline.
4. Party A will not recognize the quantity of work exceeding the scope of design drawings and rework caused by the Contractor.
⑤ Party B will not take part in the verification of work quantity and pricing within 5 days after receiving the notice, and the result of work quantity and pricing verified by Party A will be taken as the final result.
6. The approval of the quantity of visa and change of work shall be subject to the final Party A's approval, and Party B shall assist Party A in handling visa and change.
7 The Contracting Authority has the right to arrange the amount of work of the successful bidder depending on the project situation and the ability of the construction unit; after the bid is awarded due to the reasons of the construction unit can not start on time to ensure that the construction period and to meet the requirements of the quality of the construction, the Contracting Authority will be adjusted at any time to the amount of construction work of the construction unit or the dismissal of the construction unit, the resulting losses borne by the construction unit.
4, the construction of water and electricity costs required by the Party advances; settlement by the two sides negotiated deductions; but on-site waste of electricity and other circumstances to be penalized. Accommodation and living costs of water and electricity, Party B; such as Party A to provide Party B to pay the relevant costs in accordance with the provisions of the Party.
5, the lump-sum price to take into full account the other professional trades and contractors to converge, cross-construction to the construction of Party B may bring all the impact and increase in workload.
6, Party B is responsible for its own construction area within the scope of the mechanical and electrical contractors for wall grooving, hole repair work, the cost is included in the lump sum price.
VIII. Payment Methods
1. Party A will not pay any prepayment, material preparation, workers' living expenses and deposit for this project;
2. 85% of the total price will be paid after the completion of the project and acceptance by Party A. 95% of the total price will be paid after passing the Party A's audit, and the warranty will be paid within 1 month after the expiration of the warranty period with a 5% warranty deposit.
3, Party B in the process of implementation of the project, the debts and liabilities arising from the debt relationship, all by Party B to settle, Party A does not assume any responsibility.
4. The increase or decrease of the contract price due to the change shall be borne by Party A. The delayed construction period shall not be postponed in general unless there is a major design change (subject to the determination of the bidders or engineers).
Nine, construction safety
1, Party B shall comply with the relevant provisions of the management of engineering construction safety production, in strict accordance with the standard chemical site standards for the organization of construction, and at any time to accept the industry safety inspectors and Party A in accordance with the law to implement the supervision and inspection, to take the necessary safety precautions, to eliminate the hidden dangers of accidents, due to the Party B does not comply with the rules and regulations on safety or measures caused by the responsibility for accidents and the cost thus incurred. The responsibility for accidents caused by Party B's non-compliance with safety rules and regulations, etc. or ineffective measures and the expenses incurred as a result shall be borne by Party B.
2. Party B, with the cooperation of Party B's on-site safety management personnel, shall carry out on-site safety education for all operating personnel at its construction site and establish corresponding information, Party B shall not allow personnel who have not received safety education to enter the construction site, and Party A shall not require Party B to carry out construction in violation of the safety management regulations, and Party A shall bear the corresponding responsibility and related costs for any safety accidents due to Party A's reasons.
3, Party B personnel in the event of major safety incidents and other safety accidents, the two sides should make every effort to rescue, and at the same time protect the scene, Party B according to the relevant departments for investigation and identification. After the characterization of the casualty accident is Party B's responsibility or Party B's unauthorized operation of the accident, Party B itself in accordance with national regulations on the injured worker or family members for economic compensation, Party A does not bear any economic and administrative legal responsibility, but Party A should actively assist Party B to do a good job after the work; belongs to Party A's responsibility for casualties caused by the accident, in addition to the provisions of the responsible person for the treatment, Party A reference to the relevant provisions of the state of the casualty of the employee or the family members of the economic compensation, but specific details of the Party B casualty workers. Family members for economic compensation, but the specific aftermath of the work by Party B to arrange and deal with, Party A does not directly to Party B employees or family members.
4. Party B shall provide and maintain at its own expense all lights, guards, fences, warning signals and watches at such times and places as may be required, or as may be required or prescribed by the authorities concerned, and for the protection of the Works or for the safety and convenience of the public.
5. Party B shall have a full-time safety management personnel and prepare safety special construction programs for the more dangerous sub-parts of the project.
6. Party B shall take all reasonable measures to protect the environment in the vicinity of the site during the implementation of the contract, so as to avoid any harm or hindrance to the public or public property, etc. caused by pollution, noise and other factors arising from its construction.
7. When unavoidable pollution and noise arising from Party B's responsibility need to be dealt with, Party B shall put forward a plan for the Engineer's approval and implement it, and Party B shall bear the costs incurred.
8, Party B must pay 20,000 yuan safety management pressure money according to Party A's site safety management regulations. Party B site management and operators violate the safety management regulations, Party B must accept Party A site safety management personnel management and penalties, fines deducted from the safety management deposit. If the deposit is insufficient, the deposit will be renewed separately.
9, put an end to casualties; no major machinery and equipment accidents and major fire accidents.
Ten, civilized construction
1, Party B shall organize construction according to the standard and civilized construction site standards, to ensure that the construction site to create a municipal standard construction site, municipal civilized construction site, if Party A, the supervision and the relevant government departments in the inspection of the civilized construction of the fines caused by the failure to meet the standards, Party B shall bear the fines caused by their own reasons.
2, Party A and Party B sign the contract of the project shall be reported by Party B to the municipal construction management office for registration and related procedures.
3, party B must provide a roster of workers before entering the field, with copies of ID cards of workers, temporary residence permit (original), the work unit record card (original), special operators on the certificate (original), and pay the industry-related fees on time (including changes in the personnel of party B, must be declared in time to party B, due to labor irregularities caused by fines and other related costs by party B is responsible for.
4, according to Party A's requirements, Party B must be equipped with the site responsible for the general manager, technicians, quality and safety personnel, materials, construction workers, logistics, electricians and other full-time personnel for self-management, the corresponding personnel have the appropriate certificate. And the actual management in line with the standards of the general contractor to ensure the fulfillment of this contract.
5, Party B should strengthen the management of labor cost allocation to avoid labor disputes.
6, must abide by the Party A unit of the rules and regulations, shall not occur gambling, fighting and other disciplinary actions, Party B in the project should be used more than 18 years old, 50 years of age below the health of male citizens, shall not be used in foreign blind and Party A unit workers, such as the occurrence of all the consequences caused by Party B bear.
7, the company provides housing and workers to eat places, but the construction unit needs to obey the company's unified arrangements for management. Party B lodging personnel must comply with the dormitory hygiene, shall not damage the dormitory of the public **** items, Party B lodging area of the health and cleaning work and personnel wages by Party B arrangements.
8, Party B shall not bring their families, children to the site accommodation, all employees are in the canteen meals, not in the dormitory using electric stoves, electric rice cookers, electric frying pans, kerosene stoves and other cooking and frying tools.
9, the construction process of each floor support frame and template removal should be immediately arranged for personnel to clean up until the Party acceptance.
10, Party B on-site personnel accommodation and office space, provided by Party A.
Eleven, materials, equipment management
1, by Party B's own procurement of materials control:
A, material brands are in accordance with the standards of the first-line brands for procurement.
B. Comply with the types and standards stipulated in the contract documents.
C, Party B's self-supplied materials shall be recognized by Party A before use; before ordering bulk materials, Party B shall provide free samples for recognition.
D. Party B shall keep the samples approved by the contractor at the site as the standard for acceptance of the project.
E. Approval of any samples by us shall not relieve you of your obligations under the Contract.
F. In the event that the materials or techniques originally specified for use are not available due to shortage of sources or time constraints or better alternatives, you may submit a proposal for substitution of the materials or techniques to be used to the Contractor for consideration, which the Contractor shall have the absolute right to approve or disapprove. A proposal in lieu cannot be effected until approved and an approved proposal cannot increase the cost unless it is accepted at the time of approval. Any approval or disapproval by the Contractor will not relieve the Contractor of its responsibilities under the Contract Documents. Approvals shall be in writing or they shall be null and void.
G. The original or additional price of the Work shall include royalties in respect of any patented article, process or invention. Party B shall indemnify Party A against claims, suits, indemnity costs and expenses incurred by Party A as a result of Party B offending or being suspected of offending the patent rights of any article, program or invention.
H. Party A does not take into account the loss of materials supplied by Party B and the loss of labor and materials due to sectional construction, which Party B has taken into account and included in the unit price, and shall not be excused from claiming for compensation or on a per-point work basis.
2. Party B shall be responsible for the safety and security of the site.
3. The materials, machinery and equipment entering the site shall be managed by Party B itself.
4, Party B is equipped with licensed electricians responsible for the site outside the secondary box electrician operations (including switching line maintenance site duty, lighting, maintenance).
5. The inspection cost of various materials shall be borne by party B.
6, the site site of various materials transfer (including horizontal and vertical transportation) by Party B is responsible for, and according to the construction site layout map of the classification of stacking, in order to keep the construction site clean and civilized, smooth roads.
7. During the construction process, Party B is responsible for the loss of materials caused by rework and other reasons.
Twelve, the rights and obligations of both parties
(A) Party A's rights and obligations
1, Party A entrusted ______ comrades responsible for the full implementation of the content of this "subcontract" to supervise the full implementation of the contract, the performance of the contract of Party B to carry out a full range of all-round, whole process of support, services, supervision, management, coordination and control.
2, Party A is responsible for all kinds of approvals and certificates for the construction of ____ city, and the cost is borne by Party B.
3, check and urge Party B to do a good job in accordance with the relevant provisions of the state and the ____ city, project quality, safety production, civilized construction, comprehensive governance, standard and other management work, to achieve the goal of the enterprise's famous brand.
4, review the construction organization design prepared by Party B, participate in the construction process of major technical issues in the discussion and implementation of the program; the construction of the construction program and the construction sequence of the project has the right to finalize.
5, participate in the handling of safety and quality accidents, the costs incurred in the handling of accidents borne by Party B; grasp the construction progress, to help Party B to achieve the scheduled program goals, on time to the owner of the project progress payments. Control the rational use of funds to ensure the smooth progress of the project.
6, Party B in the construction site, the works consumed by the water, electricity costs according to the quota content of the amount deducted at the time of settlement.
7, Party A in a timely manner for the progress of the project, the final payment of the project, and timely disbursement of funds for the project.
8, guide and supervise Party B to make a good helmet Division label, badge, management system, image layout, the costs incurred by Party B.
9, according to the list of materials supplied for the supply of A material, in the payment of the project will be deducted according to the fact.
10, provide Party B with a set of construction drawings, and timely provision of design modifications and other drawings.
11, if Party B's construction progress can not meet the requirements of the schedule, Party A has the right to part of the workload within the scope of Party B's contracting out to other contractors to complete, Party B according to the actual amount of work completed and bear all the losses caused by the settlement. Party B shall not raise any objection.
12, Party A enjoys the right to impose all kinds of penalties on the works constructed by Party B due to quality, safety, civilized construction and other factors, and such penalties must be signed by the project manager, notified or delivered to the representative of Party B. Party A's penalties will come into effect soon, and the amount of which will be directly deducted in the settlement payment after checking.
(2) Party B's rights and obligations
1, Party B entrusted ______ comrades to be fully responsible for the implementation of this Contract, should be in accordance with the scale of the project and Party A's requirements to form a strong project management team.
2, Party B has the right to organize independent construction independently, but must be carried out under the unified leadership of Party A. According to Party A's construction progress plan, it must organize enough labor force and equip enough machinery to ensure that the project is completed on schedule, otherwise, all the impacts and losses caused will be borne by Party B.
3, Party B should be based on Party A's requirements and the actual situation of the construction site, in advance to do a good job of the construction program and report to the project technical section for approval, the arrangement of the construction sequence and the cooperation of the various types of work, a full understanding of the situation at the construction site and make reasonable arrangements to ensure the efficiency of the work.
4, Party B in the project started at the same time to provide Party A with a quality and safety officer, required to hold a valid certificate on duty, by Party A unified work arrangements.
5, Party B in the construction process, if the construction site conditions due to limitations or other special requirements, resulting in the construction sequence and construction parts of the cross, reversed, Party B must be responsible for the construction of the requirements of the cost will not be increased; if a large area of the project parts of the construction is completed, leaving a small number of sporadic parts of the abandonment of the construction, the Party will arrange for the construction of the other team, deducting the part of the Party B shall be settled The price of this part shall be deducted 3 times of the amount due from Party B.
6, Party B must ensure that the construction according to the drawings.
7, accept Party A, the supervision of safety, quality, schedule requirements of the instructions, caused by this economic responsibility, legal responsibility by Party B is fully responsible for.
8, Party B is responsible for the management of family planning of its own team, and Party B will be responsible for any penalties and fines imposed by any party as a result.
9. Party B shall be responsible for cleaning the inside and outside of the construction site and accommodation in accordance with the requirements of Party A, so as to make it in accordance with the relevant regulations of ____, and Party B shall be responsible for any penalties and fines imposed by any party as a result.
10, Party B is responsible for cooperating with the local government departments on various inspections of the labor team, to ensure that the employment of lawful and complete formalities, and if any party to be subjected to any penalties and fines shall be borne by Party B.
11, Party B in the construction process, in the event of Party A, the supervision of the temporary increase in the project, need to be confirmed on-site, Party B can not stop the construction because of Party A failed to visa in time, or as a breach of contract.
12, Party B must be in accordance with Party A's requirements for all personnel to register and submit the project for the record, and to do a good job on the entry of the workers of the three levels of education.
13, Party B must be engaged in the construction site of its own personnel life and property and construction machinery and equipment for insurance, pay the insurance costs.
14, Party B undertakes to Party A to carry out the construction and completion of the construction in accordance with the contract and to bear the responsibility for the quality warranty of the project during the quality warranty period.
15, in the process of construction of all materials involved in the recognition of samples, price recognition, the use of materials, etc. must be in accordance with the requirements of the project department of the unified implementation.
16, bear all the risks of the corresponding construction works in the process of performance.
17, with Party A directives subcontractor work, into the management of Party B if the resulting delay in the work schedule, quality does not meet the standard and other losses are borne by Party B.
Thirteen, other agreements
1, Party B to set up the project manager, including the project management personnel project management team must be no less than five people to meet the needs of on-site construction, the formation of the list of personnel and resumes and certificates of qualification copies, in the week after the signing of the contract reported to the Party to confirm the confirmation of Party A, confirmed by the Party's main management personnel in the absence of consent of the Party A before, shall not be changed on their own. If Party B replaces the key management personnel confirmed by Party A on its own or if Party B fails to replace the unqualified management personnel according to Party A's requirements, Party A shall impose a penalty of 5,000 RMB per day on Party B.
2. Party B shall not subcontract this project to others in any form. If Party A regards this project as a subcontracting project or Party B subcontracts to others without the consent of the owner for special specialized construction projects, Party A has the right to give Party B financial penalties.
3. If Party B is not satisfied with Party A in the process of performance, Party A has the right to unilaterally terminate the construction of the subsequent project contract at any time, which will cause direct or indirect damage to Party A and Party B shall be borne by Party B.
4, any change of this contract, must be indicated in writing, and signed by all parties to be valid.
Fourteenth, the project delivery and warranty
1, the project has the conditions of completion and acceptance, Party B in accordance with the relevant provisions of the national completion of the project, to the representative of Party A to submit the complete completion of the information and completion report, and at the same time, to provide Party A with three as-built drawings.
2, Party A's representative shall organize acceptance within 10 days after receiving the completion report.
3, the inspection and acceptance of the project failed, Party B is responsible for repair and bear all the costs. If the quality of the project does not meet the requirements of the right, all the fines and penalties incurred as a result of any party B shall bear.
4, completion and acceptance of the two sides should be completed within 2 days of the handover procedures, within 2 days after the completion of the handover procedures, Party B shall be evacuated from the site, and in accordance with the relevant provisions of the national project completion, hand over to Party A all relevant completion information.
5, the project in the completion of acceptance into the warranty period, Party B shall be in accordance with the "project quality warranty" within the scope of the warranty agreed to carry out the project warranty, in the warranty period due to the warranty reasons for the costs and liabilities are borne by Party B.
Fifteen, file management
1, Party B is required to provide a complete set of information, including copies of identity cards, copies of information on performance, so that Party A archives for inspection.
2, Party B in the construction process, must be strictly in accordance with the construction procedures and specifications for construction, hidden acceptance, intermediate acceptance, construction logs and other information, to assist Party A to do a good job in the completion of the project acceptance data.
3, the project's information from Party B, Party A unified preparation and management, if the information is incomplete due to Party B's reasons need to contact the relevant departments, the connection of the travel and its costs by Party B.
4, Party B's production statistics, financial accounts, labor, equipment and other reports were submitted to the departments under the establishment of archives.
5, Party B with Party A to prepare construction management information, the final completion of the information prepared by Party A unified.
Sixteen, breach of contract and disputes
1, this contract in the fulfillment of the process of breach of contract, in accordance with the relevant laws of the People's Republic of China **** and the State.
2, such as Party B without Party A's permission, leaving the field, resulting in all losses are responsible for Party B outside, while Party B has completed the project settlement price by 20% down.
3, one party default, the other party requires the defaulting party to continue to fulfill the contract, the defaulting party to assume the responsibility for the above breach of contract must continue to fulfill the contract.
4, Party B fails to timely completion of the contract by the agreed period of time or the quality of construction does not meet the agreed conditions of the contract, as well as the occurrence of non-performance of other obligations under the contract, the representative of Party A may notify Party B, according to the terms of the agreement to pay liquidated damages, compensation for default to the loss of Party A due to the period of breach of contract.
5. Party A and Party B agree that the liquidated damages are 10% of the final settlement cost of the contract.
6, in the performance of this contract in the course of the dispute, the parties should be based on the principle of seeking truth from facts and amicable, consultative settlement, consultation fails, you can apply to the Arbitration Commission of the location of the construction project arbitration, but must be:
① does not involve the arbitration part of the project should be continued as usual;
② involved in the withdrawal of Party B should be withdrawn before the arbitration;
p> ③ the completion or expiration of the contract shall be handed over before arbitration;
④ if Party B refuses to fulfill the provisions of Article 11, paragraph 2, paragraph ② and ③ of this Agreement by other means or reasons, Party A may apply to the Arbitration Commission (or the court) for prior enforcement to remove the obstruction, and all the damages incurred therefrom shall be the responsibility of Party B.
17, force majeure
1, force majeure refers to the war, unrest, falling objects in the air or other non-Party A responsibility for the explosion, fire, and the following aspects of natural disasters affecting the works of the fact or reason:
(1) earthquakes of magnitude 7 or more on the Richter scale;
(2) Hubei Provincial Meteorological Station issued by the 48 consecutive hours above 10 wind gusts and winds. hours or more of wind and rain of magnitude 10 or more;
(3) rain, snow, flooding, etc., which the municipal government has declared to have formed a natural disaster;
(4) other reasons of force majeure.
2, force majeure event occurs, Party B shall immediately notify Party A, and under the conditions of ability to take measures quickly, try to minimize the loss, Party A considers it necessary to temporarily stop the construction, Party B shall suspend the construction, the force majeure event is over within 48 hours, Party B shall notify Party A of the victimization of the loss of the situation; force majeure event continues to occur, Party B shall report to Party A every 7 days victimization; within 14 days after the end of the force majeure event, Party B shall submit to Party A the official report of cleanup and restoration and relevant information.
3. Costs and delayed time caused by force majeure events shall be borne as follows:
(1) Party A shall be responsible for the damage of the project itself.
(2) The casualties of both parties shall be borne by their organizations and the related costs.
(3) The cost of cleaning and repairing required for the works shall be borne by Party A.
(4) The delayed construction period shall be postponed accordingly.
Eighteen, the entry into force of the agreement and termination
1, this agreement in six copies, Party A and Party B each three copies, with the same effect.
2, this agreement shall come into effect from the date of signature and sealing by the representatives of both parties, and shall be automatically terminated after the fulfillment of the Project Contracting Agreement, the expiration of the warranty period of the project, and the settlement of all kinds of payments. Matters not covered in this Agreement shall be resolved by both parties through consultation.
3, other outstanding matters A and B parties to negotiate and resolve.
Construction unit: ______ Real Estate Development Co. Contracting unit: ____________
Representative: ____________Representative:____________
The above is the small make-up for you to bring you how to write the contract for the decoration of the hardcover room? Hardcover room decoration contract model of the whole content.