Construction contract is also known as "engineering contract" or "contracting contract". Refers to the contracting party and the contractor in order to complete the agreed construction of building and installation works construction tasks, clear mutual rights and obligations of the written agreement. Below is the building construction contract agreement 2021 that I have organized for you, more sample contracts Click " sample contracts " to view!
Building Construction Contract Agreement 1
Party A: ____________________
Party B: ____________________
According to the "Land Management Law" and the "Rural Land Contracting Law" of the According to the Land Management Law and the Rural Land Contracting Law, Party B obtains the contracting right of Party A's wasteland and barren mountain (forest land) through ______, and by the agreement of both parties *** together, the following agreement is reached, and hereby establishes this contract:
I. Party A contracts the wasteland and barren mountain (forest land) located in the area owned by ____________, to the north of ______, and to the west of the current ______, which is adjoining with ______, to Party B. The four boundaries are:
Party B has been contracting the following contracting rights
Second, after Party B's contract, the contracted period of use shall remain unchanged for fifty years, i.e., from the date of ______ ______ to the date of termination of ______ ______.
Third, Party B contracted by the barren beach barren mountain (forest land) right of use and its ground attachments to the total contract sum of RMB ____________ yuan, payment: ____________
Fourth, Party B contracted by the barren beach barren mountain should be actively managed, in the barren mountain planting, planting grass or engage in a variety of business; approved by the relevant departments can be engaged in non-agricultural production
V. Party B has the right to manage the contracted wasteland and mountains independently, but may not be subcontracted.
Sixth, Party A should respect Party B contracted by the production and management autonomy of the deserted mountains, to protect their legitimate rights and interests are not infringed upon, the development and management of the deserted mountains of all the results of Party B all.
VII, Party B in the contracted wasteland in the contract period in addition to Party B to pay the contract, Party B is not responsible for any other costs.
VIII, Party B will be the deserted mountain contract, Party A has the right to supervise, inspect and urge its governance and rational use of deserted mountain resources, found that the problem of timely written notice to Party B.
IX, Party A to ensure that the deserted mountains (forest land) boundaries, four to no dispute with others. If any dispute occurs, Party A will be responsible for coordinating and dealing with it, and Party A will be responsible for compensating the full amount of the economic loss caused by it.
X. Party A and Party B must honor the contract. If Party A defaults on this contract, it must pay Party B a penalty of RMB ____________ million, return Party B's contract for the entire price paid by the barren hills, and at the same time, Party B's governance inputs and results of governance reasonable price, the price of a one-time payment to Party B; such as Party B's default on the termination of the contract, Party A will not return the contracting money to the party.
XI, such as in the contract period in case of national construction or other development and construction of expropriation of land, should be the first from the expropriation of land in the guarantee to pay the actual economic loss to Party B and the loss of the expected benefits of the unfulfilled years.
XII, the expiration of the contract, such as Party B is willing to continue to contract, the two sides to renew the contract; such as Party B is no longer contracted to operate, Party A of the results of Party B's governance, economic inputs to the Party A reasonable price, as a one-time payment to the price of the Party B, shall not be in arrears. Otherwise, the contract period is extended to Party A will pay all the price of Party B after the termination of the contract itself.
XIII, Party A and Party B, such as differences in price, consultation fails, must be entrusted to Party A and Party B **** the same recognized intermediary institutions to assess the price, the results of which are binding on both parties.
XIV. Disputes arising from this contract shall be adjudicated by ____________.
XV. This contract is in four copies, one for each party, one for the notary public, and one for the record of the People's Government of the township of ______, and it will come into effect after it is notarized by the notary public of ______.
Party A (seal): ____________________ Party B (signature): ____________________
Legal representative (signature): _____________
______ ______ month ______ date
< strong> Building Construction Contract Agreement 2
Contractor:
Legal Representative:
Contractor:
Legal Representative:
Risk Tip: Relative Obligations of the Contractor
According to the law, the Contractor shall apply for the permits, approvals or record, including but not limited to permits and approvals for construction land use planning permit, construction project planning permit, construction project construction permit, temporary water use for construction, temporary electricity use, interruption of road traffic, temporary occupation of land and other permits and approvals. And the Contractor shall assist the Contractor in obtaining the relevant construction documents and approvals required by law.
If the Contractor fails to complete the aforementioned permits, approvals or filings in time, the Contractor shall bear the increased costs and/or delayed construction period and pay the Contractor a reasonable profit.
In accordance with the Contract Law of the People's Republic of China*** and the State of China and other relevant laws and administrative regulations, the construction of the rural highway construction project of Party A from ________ to ______ is awarded to Party B, which is responsible for the contracted construction. Follow the principle of equality, voluntariness, fairness and honesty and credit, the two sides on the construction of this construction project construction matters consensus, clear rights and obligations of the two sides, after consultation to enter into this contract.
First, the project overview
Project name:
Project content:
Second, the scope of the project contract
Scope of the contract: the construction design of all the contents.
Third, the project price and payment: the total amount of the contract price (upper case): ______ (RMB) ￥: ____ million.
The price of the project is paid in installments and batches according to the progress of the project, and the final account after acceptance of the project. Party A deducts 5% of the total price of the project as a quality deposit, which is paid to Party B after the completion of the project without quality defects.
Fourth, the rights and obligations of the two sides:
1, the drawings provided by Party A, Party B must be in accordance with the drawings and technical specifications for highway reconstruction project construction, Party B to ensure that the quality of qualified.
2, Party B must start construction within 3 days from the date of signing the contract.
3, Party A has the right to supervise and manage Party B's construction, Party A accepts Party B's construction according to the progress of construction, and after acceptance, the construction of the next process can be carried out.
4, without the consent of Party A, Party B shall not replace the project manager, otherwise, Party A has the right to terminate the contract.
5, Party B shall not subcontract the project, without Party A's consent, no subcontracting. Otherwise, Party A has the right to terminate the contract, and will not bear any legal responsibility arising therefrom.
6, Party B in the construction process, to ensure construction safety. If there are work-related injuries and other safety accidents, Party B will be responsible. If Party B's construction of the state, collective, individual property or personal damage, Party B is responsible for compensation.
7, Party A is responsible for the coordination of disputes around the construction process.
8, the construction of a variety of taxes to be paid by Party B.
V. Liability for breach of contract:
Risk Tips: clear responsibility for breach of contract
In the signing of the contract, the two sides should think of possible violations of the contract, and the corresponding penalties provided for in the contract, through a clear breach of the responsibility to be borne by all parties to urge the true fulfillment of the obligations to be borne once the default occurs, but also to have a basis to rely on.
1, Party B must be completed on time, otherwise, every day overdue, according to ____ yuan / day to pay liquidated damages.
2, if Party B terminates the contract in the middle of the day, then the input of its preliminary construction, Party A will not be compensated, the price of the project allocated by Party A will be returned by Party B.
3. If Party A fails to accept the quality of the project and needs to rework and repair, Party B will unconditionally rework and repair the project until it reaches the required standard, and Party B will be responsible for its loss.
4. If Party A terminates the contract halfway without any reason, causing losses to Party B, Party A is responsible for compensating Party B for the losses. If the quality of the project does not meet the standard, need to rework, repair, and Party B does not rework, repair `, then Party A has the right to terminate the contract, terminate the contracting relationship, Party B's input losses at its own expense, Party A's allocation of the price of the project by Party B back.
Sixth, the contract duration:
Start date: _____ year _____ month ____;
Risk tips: the provisions of the actual completion date
When disputes arise due to the confirmation of the actual completion date, you can refer to the relevant provisions of the specific circumstances:
The project was completed and accepted by the contractor to submit a report on the application for completion and acceptance. Completion and acceptance of the application report for the actual date of completion, and in the certificate of acceptance of the project; due to the reasons of the contractor, the completion and acceptance of the completion and acceptance of the application report submitted by the contractor is not received by the supervisory contractor within 42 days, or completion and acceptance of the completion and acceptance of the project will not issue a certificate of acceptance of the project, to the submission of the report of the application for the completion and acceptance of the actual date of completion of the date of the completion of the report; the project has not been accepted for completion and acceptance of the unauthorized use by the contractor to the transfer of possession of the project to the date of actual completion of the project. The date of transfer of possession of the works for the actual date of completion.
Completion date: _____ year _____ month ____ day;
Total calendar days of the contract duration ______ days.
VII. Quality Standards
Risk Note: Attribution of Responsibility for Failure to Conform to Standards
If the quality of the work fails to meet the contractual standards due to the contractor, the contractor shall bear the increased costs and/or delayed construction period thereof, and shall pay the contractor a reasonable profit.
If the quality of the work does not reach the contractual standard due to the contractor's reasons, the contractor has the right to require the contractor to rework until the quality of the work reaches the contractual standard, and the contractor shall bear the increased costs and/or delayed work period.
1. Project quality standard: qualified.
2, Party B must carefully organize the construction, such as not in accordance with the design requirements and specifications for construction and cause rework to redo, all the resulting economic losses are borne by Party B, Party A will give a certain amount of economic penalties.
3, due to Party B cutting corners and other construction causes engineering quality problems, resulting in all the economic losses and all the responsibility is borne by Party B.
Risk Tips: the start of the warranty responsibility
The warranty period of the project starts from the date of acceptance of the completion of the project, and the warranty period of specific sub-projects is agreed by the contracting parties in the special contract terms, but it shall not be lower than the statutory minimum warranty period. During the warranty period, the contractor shall bear the warranty responsibility in accordance with relevant laws and regulations as well as the contract.
The warranty period shall be counted from the date of transfer of possession if the contractor uses the works without completion and acceptance.
VIII, the contractor to the contractor in accordance with the contract for construction, completion and in the quality warranty period _____ years to bear the responsibility of engineering quality warranty.
IX, the contractor to the contractor in accordance with the contract agreed period and way to pay the contract price and other payments due.
X. Disputes
1, the occurrence of disputes between the two sides should be coordinated under the auspices of the supervision team to solve the problem, and if the consultation is not consistent, either party can sue the people's court where the project is located.
2, consultation or prosecution period shall not affect or stop the construction, except for litigation preservation.
XI, the contract changes and termination
1, the contract performance, due to the lack of exhaustion or change of design to increase the amount of work, the two sides can sign a supplementary contract, supplementary contract and the main contract has the same effect.
2, the contract performance, due to Party B's inability to continue to fulfill the obligations set out in the construction contract, apply for the termination of the contract, take the initiative to assume the responsibility for breach of contract, the two sides can negotiate the termination of the contract, the negotiation of the inconsistency, you can apply to the court to resolve.
XII, other
1, the contract signed by both parties to enter into force, the completion of the final audit of the completion of the project to pay off the project naturally expires.
2, the original _____ of this contract, A and B each hold ____ copies, copies of ____ copies, by A and B were sent to the relevant departments, the original and copies have the same legal effect.
Contractor: (official seal)
Legal representative:
_____ year _____ month ____
Contractor: (official seal)
Legal representative:
_____ year _____ month ____
Agreement on Contract for the Construction of Building Works 3
I. Name of the project:
II. Purpose
In order to safeguard the ****same interests of A and B, to ensure the quality of the construction and safe production, and to maintain a good working order and a hygienic environment in the construction site, A and B, through equal consultation, sign this construction safety agreement.
Third, the content of the agreement
(a), Party A's safety production management responsibility
1, Party A must strictly implement the national and provincial laws, regulations and norms and standards related to safety production, the development of the unit's safety production regulations and operating procedures, the establishment of sound safety production management system, the implementation of the requirements of the safety and technical measures to ensure that the construction of the safety production inputs. The effective implementation of the construction safety inputs.
2, Party A should provide Party B with the existing technical information required for construction.
3. The design documents provided by Party A should meet the safety and health requirements of construction workers.
4, Party A should be Party B construction site safety supervision and management work into the unit's safety system within the unified management, the development of production safety accident emergency rescue plan must have Party B construction safety content.
5, Party A shall not put forward Party B requirements that do not comply with the laws, regulations and mandatory standards of work safety, and shall not arbitrarily compress the contract period.
6, Party A shall provide rescue and medical facilities for Party B's injured workers.
(B), Party B's responsibility for production safety management
1, Party B shall establish a construction safety system, the implementation of construction safety job responsibility system, the implementation of production safety target management and standardization of construction site operations.
2, Party B should be the project leader by obtaining the appropriate licensing personnel, responsible for the production safety of mining projects, the implementation of production safety rules and regulations and operating procedures, to ensure the effective use of production safety inputs.
3, Party B shall designate the person in charge of on-site construction safety, and the number of safety supervisors shall meet the production requirements and supervise the whole process of on-site construction safety.
4, before the start of the project, adhere to the "one project, one measure, first reported measures after the construction" principle, approved by the competent authorities of Party B construction organization design, operating procedures, safety and technical measures must be reported to the Party for approval after the implementation.
5, Party B shall implement the labor production education and training system, strengthen the unit's production safety education and training of personnel, truthfully inform the workplace and the workplace of the existence of dangerous factors, preventive measures and emergency response to accidents, to ensure that employees are familiar with and strictly implement the relevant rules and regulations on production safety and safety regulations and procedures, to master the post of the safe operation of the skills, with the necessary safety precautions. Knowledge of safety precautions. The special operators shall be given special training by the relevant departments organized by the state, pass the examination and obtain the induction certificate before they are allowed to work on the job. The project department should establish the staff training file, and report to Zhonghe Coal Company and Supervision Company for record.
6, Party B according to their own needs to organize their employees to participate in the construction unit arranged safety education and training and other activities, and bear the relevant costs incurred.
7, Party B must participate in social insurance for work-related injuries in accordance with the law, and pay insurance premiums for its employees.
8, construction personnel must wear documents, uniform uniform work clothes, according to the provisions of the correct use of qualified safety protection tools, to prevent the occurrence of object strikes, falling accidents. Construction team safety protection equipment must be configured in place, the safety measures are effective, or not start operations; construction unit must be the safety production license, project manager qualification certificate, special types of operating certificates duplicate in accordance with the requirements of the Party reported to the Department of Safety Supervision for the record.
9, Party B should conscientiously implement the provisions of Party A's safety management, strengthen safety management. If Party B violates the rules or Party A's management regulations, Party A has the right to stop Party B's work, resulting in certain consequences, Party B to pay full responsibility.
10, Party A has the right to carry out inspections at any time, the right to stop illegal operation, the right to violate the safety provisions of the act of punishment or order the construction team to stop work for rectification. The hidden safety hazards identified by Party A shall be rectified and completed within the specified period, and the rectification situation shall be promptly fed back to Party A in writing.
11, Party B shall sign a production safety management agreement with the third party operating in the same operation area or the same production system. If a safety accident occurs, the consequences are borne by the responsible party, and when both parties are responsible, they shall bear the corresponding responsibility in terms of the size of the responsibility.
12, in the event of a disaster, Party B personnel, materials, equipment, etc., should unconditionally obey the scheduling, the costs incurred, the accident is dealt with after a separate agreement.
13, strict implementation of the accident reporting system. Party B occurs safety production accidents, in strict accordance with the accident reporting procedures and requirements, in addition to reporting to the unit's higher departments, but also must be timely to the Zhonghe Coal Company report.
14, other outstanding matters to be resolved by the A and B parties.
(C), safety production management responsibility penalties
1, Party B won the bid, in the signing of the contract and safety agreement must pay 20 ~ ___ 0 million yuan as a safety and quality deposit, the safety effect, project quality as an important basis for acceptance of the project, due to the management responsibility of outsourcing units caused by accidents, quality failure or violation of the relevant provisions of this agreement, in accordance with the provisions of the fines given. The fine is deducted from its safety and quality deposit.
2. Party B will subcontract or subcontract the contracted contract or subcontract or subcontract to a third party in any disguised form, and will be ordered to make corrections within a certain period of time and be fined 50,000 yuan.
3, Party B did not carry out, assess and sign the safety technology measures for construction personnel, ordered to make corrections within a period of time, and imposed a fine of __00 yuan.
4. If Party A checks that Party B arranges untrained employees to work in the well, it will give a fine of 5000 RMB/person.
5. Party B shall, according to the requirements of the Special Provisions, have a managerial and technical personnel to lead the shift at the construction site in each shift, and empty shifts are strictly prohibited. Found empty shift a fine of 500 yuan.
6, because of Party B management is not in place or because of illegal operation caused by Party B personnel casualties, the responsibility borne by Party B.
The occurrence of minor accidents, party B 20,000 yuan fine;
The occurrence of serious injuries and accidents above the second level of non-personal injury or death, party B to the project part of the person in charge of the management of the person in charge of the direct person in charge of the dismissal and termination of the labor contract sanctions, and at the same time give party B a fine of 100,000 yuan / person;
1 death of one person in the responsibility of accidents, party B to give the project manager, in charge of the person in charge of the dismissal and demotion Disposition; at the same time give party B a fine of one million yuan / person.
For a death of 2 people or cumulative death of 2 people responsible for the accident, Party A to give Party B to terminate the construction contract;
7, Party B is responsible for the safety management of other personnel into its operating area, causing casualties to other people, the responsibility borne by Party B, the penalty with Article 5.
8, due to Party A's management is not in place or due to illegal operation caused by Party B personnel casualties, the responsibility shall be borne by Party A, in accordance with the implementation of the document Zong coal security ___ 1.
9, Party B management personnel and Party A management personnel have the responsibility and obligation to **** with the implementation of all kinds of rewards and penalties stipulated in the document of the Zhongshan Coal Safety ___1.
(D), this agreement in two copies, Party A and Party B each one, effective from the date of signing.
Party A (official seal) Party B (official seal)
Party A legal representative: Party B legal representative:
Year month day month day
Building Construction Contract Agreement 4
Demand (Party A):
The supply side (Party B):
According to the "Chinese people's ***Contract Law of the People's Republic of China and the relevant provisions of the State, combined with the specific circumstances of the project, after full consultation between the two sides, signed this contract
I. Project
1, Project Name:
2, Delivery and Installation of the project location:
Second, the total cost of the project
1, the total cost of this street lamp project, including taxes, in yuan:
2, the entire street lamp project must be
Third, payment
1, the date of signing the contract within _3_ days Party A to arrange for 30% of the total amount of the project as a production advance.
2, the goods to the construction site within _3_ days of Party A to pay 85% of the total project cost;
3, the project is fully completed, through Party A and the relevant departments after acceptance, and then pay 95% of the total project cost.
4, set aside 5% of the quality guarantee deposit, one year after the expiration of the project within five days to pay off the warranty.
Fourth, supply and installation:
1, the street light project installation and construction date totals the completion of street light installation and construction projects within one working day.
2, this street light project must be strictly in accordance with the relevant national construction and installation specifications for construction.
3, in the installation process, because of force majeure factors, Party A's responsibility, change of design or other reasons caused by the installation of changes, schedule delays, A and B can be negotiated.
Fifth, the security responsibility
Party B must be strictly in accordance with the construction safety standards to do a good job of construction quality, safety management, where construction quality, safety accidents during construction, are by Party B to bear the legal responsibility, Party A does not bear any legal responsibility.
Six, maintenance
The street lamp project warranty period for _ one _ year, since the completion of the project and through the Party and the relevant departments acceptance date. Warranty period, such as street lamps found fault, Party B must be notified by Party A within 24 hours from the date of maintenance, if not due to Party A man-made damage, Party B exempted from all charges;
VII, breach of contract
A and B mutually agreed to resolve the issue.
VIII, this contract in two copies, Party A and Party B, each with a copy of the contract since the seal of Party A and Party B signed on the same day in effect.
Contractor (official seal): Contractor (official seal):
Residence: Residence:
Legal representative: Legal representative:
Entrusted legal representative: Entrusted legal representative:
Tel: Tel:
Fax: Fax:
Date: Date:
Building Construction Contract Agreement
This contract is the first of its kind. strong> Building Construction Contract Agreement 5
Party A:
Party B:
According to the Contract Law of the People's Republic of China*** and the State of China and other relevant laws and regulations, Party A and Party B, in the spirit of the principle of equality and voluntariness, fairness and good faith, on the ___ Industrial Park street light construction and installation matters agreed to enter into this contract.
I. Project Overview
Project Name: ___ Industrial Park plant street light installation
Project Location: ___ Industrial Park
Project Content: plant street light installation construction
Source of Funds: Self-financing
II. Scope of works
The contents required in the street lamp layout plan of the factory area.
III. Construction period
Start date: ________, ____, ____
Completion date: ________, ____, ____
IV. Quality Standard
One-time acceptance in accordance with the national quality acceptance standards for construction projects and Party A's requirements.
V. Contract Payment and Payment
The contract price is lump sum price: 86900.00 yuan, capital: ___ yuan whole.
Payment: after acceptance, deduct the warranty deposit one-time settlement, the warranty deposit is 5% of the total contract price, that is: 4345 yuan, uppercase: ____ yuan.
VI. Warranty period
After acceptance, Party B's warranty time is ________ years.
VII. Liability for breach of contract
Due to Party B's reasons, the quality of the project is not up to the requirements of one-time acceptance, Party B is responsible for rectifying and improving until qualified, resulting in delays in the construction period, in accordance with the daily penalty of 3,000.00 yuan to be paid to Party A.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
________ year ____ month ____ day ________ year ____ month ____ day < /p>
Building Construction Contract Agreement 2021 Related Articles :
★ 2021 Building Construction Contract Agreement 5 Articles
★ 2021 Building Construction Contract Template
★ Engineering Construction Contract 2021 Latest Model 5 Articles
★ 2021 Simple Construction Contracting Contract model 3
★ 2021 construction contract agreement latest format five
★ 2021 construction contract agreement excellent model
★ 2021 construction contract agreement content
★ 2021 personnel construction contract latest model
★ 2021 construction contract agreement excellent model
★ 2021 Construction Agreement Contract Form Template