Forest greening as the main component of the city's green infrastructure, is to enhance the city's taste, improve the city function, improve the ecological environment of the urban habitat is an important content. What is the contract for the landscaping project? The following is my contract for you to organize the greening project contract model , thank you for your appreciation.
Contracting greening project contract model 1
Party A:
Party B:
First, the project overview
1, project name: Yinggen River comprehensive treatment of greening project (a standard)
2, project location: Qiongzhong County, Yinggen Town
3, the project content Greening: planting and maintenance.
4, the cost of the project (lump sum excluding tax): subject to the number of sites, with a unit price quotation.
5, engineering changes, according to the relevant quota standards in Hainan Province.
Second, the construction period and requirements
1, the construction period:
2, acceptance criteria: GJJ/T82-99 "urban greening project construction and acceptance specifications", other in line with the relevant professional acceptance standards.
3, the project maintenance for 3 months, to ensure survival rate of 100%.
Third, the payment method
1, after the contract is signed, according to the amount of work completed 60% of the progress payment.
2, after the maintenance period, pay the balance within one week.
Fourth, the project changes
In the greening construction process, A and B in the spirit of respect for the principle of truth, the two sides coordinated by the agreement, can be adjusted to part of the seedlings.
V. Completion and acceptance
1, Party B in the planting is completed, should be self-checked, acceptance, notify Party A. If Party A does not organize acceptance within 7 days, it will be considered as the first inspection.
2, after the initial inspection, full of 3 months for delivery and acceptance, all seedlings are required to appear growth potential.
Sixth, the responsibility of both parties
1, Party A's responsibility
1) Party A to provide timely access to construction sites and planting of seedlings point.
2) Party A provides water and electricity for construction free of charge.
3) Party A should actively cooperate with the acceptance of the seedling program and incoming materials, and the principle of the same day confirmation to ensure that the construction period.
4) Party A with Party B's external coordination (eg: the coordination of relevant government departments; the procurement of seedlings, transportation links need to apply for approvals and other relevant procedures for the application).
2, Party B's responsibility
1) In accordance with Party A's requirements for the name, number, specifications for the construction, and to ensure that the planting of all live.
2) In the guarantee period, if the seedlings planted by Party B die, Party B will replant them, and all the required cost will be borne by Party B.
3) Party B must plant the seedlings according to the design requirements, such as unauthorized planting and the loss caused by Party B is responsible for their own.
4) Planting must meet the technical requirements of greening construction.
5) Party B shall comply with Party A's relevant provisions on the site of civilized construction management, all personnel shall be uniform clothing, wearing helmets, to keep the site clean and orderly.
VII. Force majeure factors
1, in the construction period by strong typhoons, rainstorms caused by delays in the number of days are not counted in the construction period.
2, in the construction period due to force majeure factors caused by the death of seedlings, the loss caused by Party B is not responsible.
3, the defaulting party has the right to the defaulting party according to the joint proposed compensation.
Eight, other
1, Party A refers to the representative stationed at the scene _________, Party B stationed at the scene of the representative of _________, both representatives of the scene to sign the documents and information are valid documents.
2. The total cost of the project will be settled by the finalized volume of work.
3, this contract by the representatives of the two sides signed and stamped after the entry into force; this project warranty period expires, the balance of payment, this contract expires.
4, the two sides in line with the principle of friendly cooperation to sign a separate supplementary contract, and this contract has the same legal effect.
5, this contract in one form, two copies each.
Party A: Party B:
Representative: Representative:
Date of signing: January
Contracting greening project contract model 2
Party A:
Party B:
In order to ensure that the smooth progress of the project, by the two sides of the negotiation agreed to the following terms for the two sides to refer to the implementation. Both parties refer to the implementation.
Article 1 Project Overview
1, Project Name:
2, Project Location:
3, Project Content:
4, Contracting Mode:
5, Greening Area:
6, Greening Standard:
7, Greening Varieties:
8, Project Cost: Capital:<
Article II Project Period
All the project start date, the project is scheduled to start on April 1, 20_, all the project completion date: April 18, 20_, the completion of the contract period of the total number of calendar days 18 days.
Article III Project delay and project rewards and penalties
1, Party B shall start the work in time and on schedule, such as in the case of the construction site can not start the case should be three days in advance written notice to Party A and agreed by Party A, Party A does not agree to extend or Party B did not send an extension notice within the specified period, the duration of the work will not be postponed.
2, the construction of various reasons for stopping the work, should be 24 hours in advance written application to the Party, the Party will decide whether to stop the work depending on the situation.
3. In case of force majeure, such as natural disasters and other reasons, the construction period will be postponed accordingly.
4. If the work is delayed or stopped due to Party B, Party B shall bear the corresponding loss.
Article IV Party A work
1, to ensure that the construction surface, the site to do three and one leveling.
2, to ensure that Party B construction and maintenance of water, electricity.
3, Party A should provide Party B with information on underground hidden works.
Article 5: Party B's work
1. Party B must organize the construction according to Party A's confirmation of the progress of the project, and accept Party A's supervision and inspection of the progress of the project.
2. After the completion of the project, Party B shall bear the quality warranty responsibility for the project according to the warranty period agreed in this contract.
3, Party B shall comply with the relevant provisions of the management of construction safety, safety construction, construction, such as Party B's responsibility for accidents caused by inadequate safety measures and related costs, by Party B.
Article 6: The construction of the project shall be carried out in accordance with the provisions of the contract.
Article VI Quality Acceptance
1, seedling planting should strictly comply with the operating specifications to ensure that the survival rate of seedlings is not less than 100%.
2, civil engineering and soil replacement works should be constructed according to the drawings.
3, planting is completed with Party B in Party B in one month to complete the acceptance.
Article VII Payment
Party A paid in full after acceptance.
Article VIII Disputes
Disputes arising from the fulfillment of this contract shall be resolved through consultation.
This contract in two copies. A, B each party to sign a copy, the two sides stamped into effect.
Article IX maintenance
A, B and coordination.
Party A: Signature:
Party B: Signature:
Month and year:
Sample Contract for Contracting Greening Works 3
Party A:
Party B (name of subcontracting unit):
In accordance with the "People's Republic of China*** and the State Construction Law", "People's Republic of China*** and the State Contract Law" and their respective laws. *** and State Contract Law" and other relevant laws and administrative regulations, following the principle of equality, voluntariness, fairness and honesty and credit, according to the Xiongxian County Sewage Water Treatment Plant Civil Engineering Construction General Contract signed by Party A and the construction unit, the two sides on the construction of the construction project labor construction to negotiate and reach agreement, and hereby enter into this contract.
1. Project Overview
① Project Name:
Xiong County sewage water treatment plant plant greening project
② Project Location: East of Yagucheng Village, X County
③ Project Contents: plant greening project
2. Contracting Scope:
3. 46 days of project duration
① Start Date: 20 _ May 15, 20 _
② completion date: July 1, 20 _
4. quality of the project
① Party B in accordance with the project construction drawings, construction instructions and the corresponding construction specifications for construction, in line with the quality standards of the general contract, and to receive representatives of the Party, the construction unit, the supervision and inspection of the supervisory unit.
② Party B must be prepared in accordance with the overall construction organization design and set the quality control points for construction control.
③ Quality level:
5, safety: Party A and Party B must sign a construction safety agreement, and strictly enforced.
6, the contracting method: package construction
7, the responsibility of both parties
Party A's responsibility:
Project Manager's name: Position:
① before the start of the construction of water, power supply interface;
② before the start of the construction of the construction drawings and related technical information;
③ before the start of the construction of the turnkey project to do a good job of the organizational design, and submit to Party B the construction organization Design, and submit to Party B;
④ Responsible for the approval of the progress plan and construction program;
⑤ Provide Party B with materials and equipment before the commencement of work or in stages.
⑥ Responsible for supervising the construction quality and progress of Party B.
⑦ Responsible for design changes and on-site visa procedures and cost matters.
⑧ for the project with the owner of the budget (settlement).
⑨ Disbursement of project payment to Party B as agreed in the subcontract.
⑩ other responsibilities: to provide accommodation for Party B's construction personnel.
Party B's responsibility:
Name of the person in charge of the project: Xu Yongjin Position: Project Manager ① Obedience to Party A's unified management, command and scheduling, and accept the inspection and supervision of Party A's business departments;
② Carefully organize the construction, to ensure that the construction of the subcontracted works progress, quality objectives;
③ Do a good job of the construction site safety, security, Fire work, the specific implementation of the two sides signed the "Construction Safety Agreement"; Party B to arrange for the defense personnel to defend the construction site machinery and construction materials, if lost or damaged, Party B shall be responsible.
④ Do a good job of environmental protection at the construction site, effective control of chemical hazards, dust, solid waste, wastewater, noise, etc. at the construction site, and do a good job of civilized construction;
⑤ Quality accidents occurring in the course of construction should be remedied in a timely manner, and promptly reported to Party A. Party B shall also bear the responsibility for any loss or damage caused by Party B, and take the responsibility for any loss or damage. And bear the cost losses caused by Party B;
⑥ Party B construction personnel must be licensed in accordance with the provisions of the work, and reported to Party A for review and approval;
⑦ Party B in the process of construction must maintain the reputation of Party A, and there shall be no damage to Party A's language and behavior;
⑧ construction Party B shall strictly abide by the Party's regulations relating to safety, environmental protection, quality management, etc., and accept the provisions of the Party's safety, environmental protection, quality management, and so on. In the construction, Party B shall strictly abide by Party A's regulations on safety, environmental protection, quality management, etc., and accept Party A's supervision;
⑨ Party B's construction personnel must be uniformly dressed in accordance with Party A's requirements, the cost of which Party B is responsible for; Party B's construction personnel's own protective equipment, labor insurance products by Party B.
⑩ in accordance with the requirements of Party A to set up a full-time safety officer is responsible for the party's construction personnel safety education, good safety protection, accept the Party's safety management personnel inspection and supervision.
(11) other responsibilities: responsible for the party's construction personnel canteen and meals.
(12) accept Party A's monthly assessment scores on safety, quality, progress, civilized construction, and rectification in accordance with Party A's requirements, for each deduction of 1 point, a fine of 100 yuan; after the completion of the project, the overall evaluation of the satisfaction of Party A will be all or part of the fine as a reward to the subcontractor.
8, the supply of materials and construction machinery
9, project completion
① project with the completion of acceptance conditions, Party B according to the relevant provisions of the national project completion acceptance, to Party A for acceptance.
② Party A received the completion of the acceptance of the application within 3 days of the preliminary acceptance, and give recognition or proposed modifications. Party B should be modified as required, and bear the cost of modification caused by their own reasons;
③ Party A preliminary acceptance, Party A in the turnkey project acceptance of the completion of the project will be handed over to the construction unit for acceptance. If the general contracting project cannot pass the completion acceptance due to Party B's subcontracting construction, Party B shall actively repair and bear the cost of modification.
10, project settlement
① Project cost: one hundred and forty thousand five hundred and fifty-two thousand two hundred and eighty-four dollars
② Settlement: the first project payment allocation of 50,000 yuan, the second allocation of 40,000 yuan, and the third allocation of 55,528,000 yuan.
③ Payment method: Party A or the construction party directly allocated to Party B's account.
④ Water and electricity for construction are measured by hanging meter and deducted from the settlement price according to the actual expenses incurred.
⑤ All the above prices include taxes.
Party B will provide invoices according to Party A's requirements, and the tax will be borne by Party B accordingly.
11, engineering quality warranty
① scope and content of engineering quality warranty: all the contents of the construction scope of Party B
② quality warranty amount: 5% of the project cost
③ engineering quality warranty period: based on the warranty period in the contract signed by the party and the owner to implement.
12, liability for breach of contract
① construction, Party B construction progress, quality, etc. can not meet the requirements of Party A or the owner, Party A has the right to terminate the contract and replace the team, the resulting loss borne by Party B.
② Party B can not be completed according to the agreed schedule or the key nodes required by Party A, each day of delay, should be paid to the Party A 10,000 yuan of liquidated damages; liquidated damages still can not make up for the loss of Party A, Party B should be made up according to the actual loss.
③ Party B shall bear the cost of dismantling and re-construction if the quality of the project fails to meet the quality standard agreed in the contract due to Party B, and the construction period shall not be postponed, and shall compensate for the loss caused to Party A.
③ Party B shall be responsible for the cost of dismantling and re-construction.
④ Party B's failure to do a good job because of Party B's construction site safety, security, fire, environmental protection and other losses incurred by Party B. Party A shall not be liable to Party B for unauthorized work. Party A shall have the right to penalize Party B for any violation of rules and regulations, for any violation of rules and regulations, for any loss of quality or safety accident caused by Party B's unauthorized operation or command, and for any disobedience to Party A's management, and the penalty may be deducted from the progress payment of the current month's project or the settlement payment of the project.
⑤ Party A causes quality, safety problems and delays in the construction period, Party A shall be responsible for the economic losses.
13, disputes
Disputes occurring in the course of the fulfillment of this contract shall be resolved through consultation between the two parties; if the consultation fails, both parties may sue to the People's Court of Xiong County.
14, other
① five copies of this contract, Party A, two copies, two copies of Party B, the construction side of a
② Party A and the construction unit of the general contract signed by the general contract is one of the conditions for the implementation of this contract, the contract is not exhaustive the two sides to negotiate or refer to the relevant terms and conditions of the general contract;
③ GF - 1999-0201 "Construction Engineering Construction", "Construction Engineering Construction", "Construction Engineering Construction" and "Construction Engineering Construction". 1999-0201 "construction contract" (model text) in the general terms of this contract is one of the conditions for the implementation of this contract, the contract does not provide for the implementation of the general terms;
④ this contract from the date of signature and seal of the two sides came into effect, in the completion of all the works, for the handover acceptance of the warranty period for the full payment of the project after the expiration of the clear.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ ____ month ____ day _________ year ____ month ____ Day
Contracting Greening Contract Model 3 Related articles :
★ Greening Contract Model 5
★ Greening Contract 3
★ Simple Greening Contract 5
★ Simple version of the greening contract model 3
★ Greening contract model 3 latest 2020
★ The latest version of the gardening contract model 3
★ 5 practical gardening contract model contract
★ Practical version of the greening contract model 3
★ 5 about the greening contract model
★ The gardening contract model 3 the latest 2020