Manual labor contract

Employer (Party A): _______________

Employee (Party B): _______________

According to the Labor Law of the People's Republic of China*** and the State of China, the Labor Contract Law of the People's Republic of China*** and the State of China, and the relevant provisions of the GJ and the province, Party A and Party B enter into this contract in accordance with the principles of lawfulness, fairness, equality and voluntariness, consensus, and honesty and credit.

First, the term of the labor contract

1, this contract from _______ year _______ month _______ day to _______ year _______ month _______ day, the expiration of the term of this contract terminated by itself, agreed upon by both parties, you can sign another labor contract.

2, the probationary period from _______ _______ month _______ day to _______ _______ month _______ day.

2. Work content and workplace

Work content: responsible for ______ departmental portering work.

Position: porter.

Work location: ____________________________________________________.

Third, labor compensation

1, Party B wages for piecework wage system, Party A according to the specific handling items piecework wage unit price and calculation as the basis for calculating labor compensation (loading and unloading fees per ton _______ yuan).

2, Party B according to Party A's piece-rate wage system, the monthly labor quota and piece-rate unit price of labor remuneration is not less than _______ yuan.

3. Party A shall pay Party B's wages for the previous month before _______ each month, and in case of statutory vacations or rest days, the payment shall be advanced to the nearest working day.

4, wages must be paid in money, not in kind and securities instead of money.

Fourth, the termination of the contract

1, by the consensus of the A and B, this contract can be canceled. Which is proposed by the Party to terminate this contract, should be paid in accordance with the provisions of the economic compensation.

2, one of the following circumstances, Party A may terminate this contract:

(1) Party B in the probationary period is proved to be incompatible with the conditions of employment.

(2) Party B seriously violates Party A's rules and regulations.

(3) Party B's serious dereliction of duty, malpractice, causing significant damage to Party A.

(3) Party B's serious breach of duty.

(4) Party B establishes labor relations with other employers at the same time, which seriously affects the completion of Party A's work tasks, or Party B refuses to rectify the situation upon Party A's proposal.

(5) Party B, by means of fraud, coercion, or taking advantage of people's danger, to make Party A in violation of the true meaning of the circumstances of the conclusion or change of the labor contract, resulting in the invalidity of the contract or change the agreement.

(6) Party B is investigated for criminal liability.

3, Party B to terminate this contract, should be in advance ______ days in writing to notify Party A; in the probationary period, in advance ______ days to notify Party A.

Fifth, social insurance

A and B negotiation agreed by Party A for Party B for social insurance, and according to the provisions of the full payment of social insurance costs. After the termination of the labor contract between the two sides, should be transferred in accordance with the relevant provisions of the social insurance procedures. Party B injured at work, its treatment in accordance with the relevant provisions of the GJ and the local people's government.

Six, other special agreements

1, Party B in Party A during the employment of personal negligence caused Party A suffered economic losses, should bear a certain amount of liability for compensation, compensation for Party A direct economic losses of ______%.

2, Party B should strictly abide by labor discipline, Party A's rules and regulations, and do their own work. If Party B violates labor discipline and Party A's rules and regulations, Party A may deal with it according to the relevant rules and regulations until the termination of the labor contract.

3, during the employment in Party A, without Party A's permission, Party B shall not engage in part-time all the business related to Party B's duties, if there is a violation, once found, Party A has the right to terminate the labor contract, and do not pay any economic compensation.

4, Party B must obey Party A's work arrangements and mobilization.

5. Party A and Party B will negotiate the renewal of the contract one month before the expiration of the contract. If the contract is not renewed by both parties but the relevant work or business engaged by Party B has not yet been completed, the contract shall be extended to the date of completion of the relevant work or business.

VII. Dispute Resolution

The parties to the performance of this contract, such as disputes, can be resolved through consultation; unwilling to negotiate or consultation fails, you can apply for arbitration to the ______ Labor Dispute Arbitration Committee.

Eight, other

1, the two sides of the unexplained matters and disputes, the two sides in a friendly and reciprocal attitude of negotiation to supplement the settlement.

2, the contract in one _____, since both parties signed the date of entry into force, both sides of the implementation of _____, have the same legal effect.

Party A: __________________ Party B: __________________

______ year ______ month ______ day ______ year ______ month ______ day

Construction unit (Party A):

Prefabrication yard (Party B):

Supervision unit:

By the A and B **** the same consultation, Party A decided to entrust the prefabrication to the Party B, in order to clarify the powers, obligations and economic responsibilities, and hereby enters into the The following terms of the agreement, the two sides *** with compliance.

1. Summary of the project:

Project name: contract including transportation, installation: unit price per piece (yuan);*** (piece), the total price of ￥ (yuan) capital RMB yuan (cash payment).

2. Contract duration:

The project style requirements in the day before completion, Party B shall not be delayed without reason, if due to Party A's lack of funds, the lower part of the project was not completed on time or Party A did not do a good job in the bridge construction site of the three passes and one leveling (through the water, through the electricity, through the transportation site) and other reasons, resulting in Party B can not be lifted on schedule, Party A compensation for the occupancy of the site of Party B stacked beams.

3. Party B's responsibility:

(1) Party B, as Party A's construction team, contractors, machines, should be strictly in accordance with the drawings provided by Party A and the technical standards, construction specifications for the construction of prefabrication, to accept the supervision of Party A's construction workers and supervisory units, to ensure the quality of the project, the quality of the project grade is qualified.

(2) Party B shall reasonably and effectively organize the construction in accordance with Party A's on-site construction deployment and progress plan requirements to ensure that the implementation of Party A's production plan shall not be delayed.

(3) The materials purchased by Party B that constitute the body of the project shall comply with the relevant provisions of Party A's material procurement, meet the requirements of Party A's qualified suppliers, and can only be used after passing the inspection by Party A and the Supervision, otherwise, Party A will regard the project using the materials as unqualified, and Party B must rework the work without any compensation and bear all the damages and liabilities caused by it.

(4) Party B shall ensure that its own qualifications and experience are suitable for this project and provide legal qualification certificates and other supporting documents; Party B has the responsibility and obligation to review the technical requirements, quality standards and work instructions provided by Party A, and has the right to reject the wrong requirements, standards and instructions issued by Party A. Otherwise, no matter what the reason for . Defects in the quality of the work or failure to achieve the quality level agreed in the preceding paragraph, Party B shall bear the corresponding responsibilities and costs.

(5) Party B shall rework or repair the works which do not reach the quality level agreed in the above paragraph and the defective works without any compensation, and bear all the expenses incurred as a result. If the quality level agreed in this contract is still not reached after reworking or repairing, Party B shall compensate according to the actual loss of the project; Party A has the right to reworking or repairing the unqualified and defective works on its own or entrusted to others, and the reworking or repairing cost shall be borne by Party B.
(5) Party B shall rework or repair the unqualified and defective works without compensation, and bear all the costs incurred.

(6) The reworking of the quality of the work, resulting in the construction period exceeding the agreement of this contract, in accordance with the terms of this contract for breach of contract.

(7) Party B shall strictly carry out self-inspection of concealed works. After passing the self-inspection, it shall report to Party A's inspection engineer for inspection. Party A inspection engineer shall, within 24 hours, re-inspect the concealed works and bring it to the supervisor for inspection. After passing the inspection and signing, Party B can carry out the concealed. If the inspection is unqualified, Party B shall complete the repair and re-report the inspection within a limited period of time. Without inspection, Party B unauthorized concealment, Party A has the right to request re-inspection, resulting in increased costs and delays in the construction period by Party B is responsible for.

(8) 35 days after the completion of the project, Party B must also provide prefabricated beams (plates) qualified test documents and construction diary. Take responsibility for the safety of prefabricated transportation and installation.

4. Engineering changes:

In the construction process, such as engineering changes, Party A must notify Party B in advance in writing, increase or decrease in the unit price of the amount of work has been agreed upon price. Qualified materials have been imported party A requires changes and the original imported materials can not be returned, party A must compensate party B for the loss of the budget price of the material.

5. Party A's responsibility:

Party A should provide the project design drawings and related technical documents and other information, must be in the contract signed within three days after the prepayment of 50% of the total amount of the project to the party to buy the main materials, and then according to the progress of the prefabrication of payment in installments, the prefabrication of all the project is completed, Party A must pay the 98% of the total project, the last (piece, span) beam shipped out of the party prefabrication yard before Before the last (piece, span) beam is shipped out of the prefabrication yard of Party B, Party A must pay all the works except for RMB 3,000 as deposit for qualified experimental documents and construction diary. All taxes and fees of this contract shall be borne by Party A.

6. Matters not covered can be resolved through separate negotiations or supplemental agreements, compensation agreement payments and this agreement with the same legal effect.

7. This agreement will be effective from the date of signing, and will be naturally terminated after all the beams have been lifted and all the payments have been settled.

8. This contract is in duplicate, and each party holds one copy.

Party A (official seal): _________ Party B (official seal): _________

Legal representative (signature): _________ Legal representative (signature): _________

_________ year ____ month ____ day _________ year ____ month ____ Day

3. Manual labor contract model simple

Contract number: ________________

Party A: ____________________

Party B: ____________________

According to the guidelines of the Contract Law of the People's Republic of China*** and the State of China, the Construction Law of the People's Republic of China*** and the State of China, as well as other relevant laws and administrative regulations, Party A will contract some of the works and processes in the _______________ project to Party B. In order to clarify the rights and obligations of both parties, on the basis of fairness and reasonableness, after consultation between the two sides, the following terms are agreed upon, and we hope that *** with the compliance.

Article I, contract documents

As an annex to this agreement, the following documents and this agreement *** with the contract documents, and this agreement has the same effect:

1. The project construction technical specifications, technical instructions, work instructions, drawings;

2. The project quality inspection, acceptance standards;

3. The project construction safety standards;

4. The project construction organization design;

5. The project construction schedule (including nodal plan);

7. The documents of the owner, supervision and Party A;

8. Supplementary agreement between Party A and Party B, minutes of meeting,.

Article 2, Contracting unit price

See (Annex) for details, no price adjustment.

Article 3, the relevant agreements

1. Party B is responsible for Party A, recognizes and strictly in accordance with Party A and the owner of the signing of the relevant quality, safety, technology, environmental protection, civilization and other standards of construction, in the construction schedule issued by Party A (including node plan) to complete the construction.

2. Measurement and Payment

2.1 After Party B completes the contracted project, Party A will make measurement and payment based on the number of qualified works completed by Party B and the unit price of the bill of quantities (Annex 1).

2.2 Party B shall organize construction according to Party A's construction plan. If the construction plan is not completed due to Party B, Party A shall have the right to claim compensation from Party B for the delay incurred as a result (compensation = ____? Amount of work? Number of days of delay) which is limited to ____% of the total price of the task. At the same time, Party A has the right to terminate this contract.

2.3 There is no advance payment for this project, Party B should have the ability to advance funds before settlement and payment.

3. Project material supply

3.1 The main materials required by Party B is responsible for, need to be inspected by Party A can be used.

3.2 Due to road blockage, natural disasters and other irresistible external forces caused by the material can not arrive in time to affect the construction, Party B shall not claim to Party A.

4.1 The material shall be supplied by Party B in accordance with the following conditions.

4. Measurement, testing, inspection and other technical work

4.1 Party A will carry out written technical instructions and measurements at any time according to the needs.

4.2 Party A is responsible for engineering test inspection work, Party B should be under the supervision of Party A with Party A laboratory inspection.

5. Party B shall not subcontract. Otherwise, Party A has the right to terminate the contract. Party B shall bear the loss caused by this and pay Party A the liquidated damages of _____% of the total price of this contract.

6. Concealed works can only be carried out after acceptance by Party A and Supervisor.

7. The unit price contracted by Party A to Party B covers the full cost of construction. Party B, as an economic entity, shall fulfill all the social obligations stipulated by GJ (labor, medical care, work-related injuries and other kinds of insurance, all kinds of taxes and fees, etc.)

8. According to the Labor Law, Party B shall pay employees' labor remuneration on time and in full (not less than the minimum wage standard announced by the local government). Party A has the right to supervise, if necessary, Party A has the right to pay on behalf of (directly to the wages paid to the hands of Party B's employees)

9. Party A contracted to Party B's unit price includes Party B's workers' compensation insurance and third-party liability insurance. Therefore, Party B's workplace accident costs and associated costs are fully borne by Party B.

10. Changes in Party B's on-site construction manager and technical manager need to be agreed by Party A, and Party A needs to fulfill the leave formalities for leaving the site.

11. Party B completed the workload (calculated according to the number of entities) by the Party commissioned the representative to sign the validity. Project payment by Party A technology, safety and quality, materials, contracts, finance and other departments responsible for signing, Party A captain approved payment.

12. Party A has the right to make an assessment of Party B's performance ability, if Party B is incapable of performance (especially quality, schedule, safety), Party A has the right to terminate the contract, and has the right to claim damages from Party B according to the total amount of the contract subject matter _____%.

13. After the signing of this contract, Party B's personnel and equipment must enter the construction site according to the time. Otherwise, Party A has the right to terminate the contract or make corresponding penalties for Party B's breach of contract (the penalty standard shall be determined by Party A according to the degree of Party B's breach of contract, and the penalty limit shall be ____% of the total price of Party B's tasks)

14. Party B is responsible for the safety of this project, equipped with the necessary safety protection facilities, and in accordance with the GJ relevant laws, administrative regulations and operating procedures of work safety, and submit to the Party A's safety supervision and Management, no matter what the reason, caused by personal injury, mechanical accidents, Party B bears full responsibility, Party A does not bear any responsibility.

15. Party B must do on-site civilized construction and environmental protection, including the control of dust, reduce noise and other related operations, and equipped with a variety of signs to meet the construction of the project, signage.

16. Party B shall take measures to actively cooperate with Party A's owner or supervisory engineer's regular or unscheduled inspections and evaluations. If Party B, due to Party B's reasons, causes Party A to be penalized in the owner's or supervisory engineer's inspections and evaluations or affects Party A's evaluation results, Party A shall impose a fine of ____ times to Party B or penalize Party B according to the evaluation results. Party A has the right to terminate Party B's contract if Party B's reasons cause events that seriously affect Party A's credibility.

Article 4, Dispute Resolution

If a dispute arises in the fulfillment of the contract, the two parties agree to resolve it in the following manner:

1. Settlement. Both parties shall, on the basis of voluntary and friendly, communicate with each other, understand each other, and solve the problem through negotiation;

2.Mediation. Under the auspices of a third party, through the third party's persuasion, guidance, mediation methods to resolve disputes and reach an agreement;

3. Arbitration. Consultation, mediation fails, by the ________ Municipal Arbitration Commission arbitration.

Article V, the bylaws

1. This contract needs to be negotiated between the two sides to sign a supplementary agreement, the supplementary agreement and this contract have the same legal effect.

2. This contract shall enter into force after both parties have signed and sealed it, and shall expire naturally after the completion of the project, the settlement of the final payment of the project, and the expiration of the warranty period.

3. The original of this contract ____, both parties ____; copy ____, both parties ____.

Party A: __________________ Party B: __________________

Representative: ________________ Representative: ________________

Phone: __________________ Phone: __________________

Date: _____ Date: _____ Date: _____ Date: _____ Date: ____

Attachment 1: Bill of Quantities (Omitted)

4. Sample of Labor Contract for Manual Labor Simple

Party A: __________________ (hereinafter referred to as Party A)

Party B: __________________ (hereinafter referred to as Party B)

According to the relevant spirit of the "Chinese People's **** and the State Contract Law" and the "Regulations on Contracting for Construction Works", through the negotiation between Party A and Party B, Party A agrees to the __________________ project's labor contract to Party B. In order to clarify the rights and obligations of both parties, the following terms of agreement are signed for both parties*** to comply with.

I. Name and Location of the Project

The project is the __________ School Teaching Laboratory Building Project in the city of __________ _____.

Second, the contracting method and requirements

The project Party A to take sub-trades, unit price combined into a total price in the form of tax, labor, food and lodging package contracted to Party B. The contracting team is required to have a labor contracting qualification. Requirements for the contracting team with labor contracting qualifications, the main types of work to have a certificate of employment, and the preparation of personnel roster to Party A archives for inspection.

Third, the project contracting unit price and content

After consultation between the two sides, the project by _____ yuan / (m2, m3, t) contracting unit price contracted by Party B, the contracting unit price includes the following: completion of the construction party to provide a full set of construction drawings, briefing notes, changes in the construction of the entire content; site preparation and cleanup; _____ meters within the scope of ground level Transportation; production equipment maintenance, maintenance; material savings; and other teams with other content.

Fourth, project quality and safety

According to the owner's requirements, the quality of the project is required to achieve excellent, so the single contracting must ensure that excellent, such as the quality of the project was assessed as excellent engineering, Party A appropriately rewarded, such as contracting a single assessment of unqualified, reworked and repaired by the B side until qualified, and rework of all the economic losses borne by the B side, and from the B side of the labor settlement. Deducted back.

Party B construction personnel must comply with the arrangements of Party A management personnel, must strictly abide by the "safety regulations", in order to enable workers to enhance the safety awareness, the team and the team responsible for the daily arrangement of the workload, to carry out safety education, emphasize the safety of operation, with a good helmet, installed a good safety belt, do a good job of all the safety protection work, to prevent the occurrence of safety accidents. Any safety accidents caused by Party B are Party B's responsibility, Party A does not bear any economic and legal responsibility.

Fifth, civilized construction and rewards and penalties

Party B into the construction site personnel must comply with the civilized construction manual, in the scope of their own contracted to do the work of the material end of the site clear, strictly put the material savings off, not allowed to sawing, littering, waste of materials, such as found in the responsibility of the separation of the fines given. At the same time, the person in charge of Party B must manage their own team, _____ personnel outside the city, before entering the site, do a good temporary residence permit, is strictly prohibited to have _____ suspected patients into the construction site, strictly abide by the public security management regulations, violators will be fined, Party B personnel must obey the command of the management staff, to comply with all the rules and regulations of the site. Report the ID card and family planning certificate to Party A. No one under the legal age shall come to the construction site to do the work. If all the violators, refer to the relevant provisions of the project department penalties.

Six, the payment method and duration

The project party B team into the field, its upfront costs by party B is responsible for, party A according to the progress of the project lent party B a certain amount of cost of living, the main body of the top of the payment to the labor cost of _____%. The completion of the project is paid to _____% of the labor fee. Pay _____% of the labor fee for the completion of the project settlement. Leave _____% to be paid within _____ months after the expiration of the warranty period. Due to the tight schedule of the project, and the owner's rewards and penalties, in order to ensure that the project is completed according to the deadline for the completion of the completion of the project, so Party B to enter the site must pay the work schedule deposit _____ million. Party B in the construction site must be determined in accordance with the Party A's schedule control points, careful organization, careful construction, to ensure the achievement of the schedule target, such as Party B causes delays in the construction period. In addition to the deduction of the schedule deposit, the penalty will be given according to the contract signed between Party A and the owner.

VII. Powers and Obligations of Both Parties

(A) Party A:

1. Party A has the right to review Party B's qualifications, and to impose penalties on Party B for violating the contents of the contract terms, and the power of economic compensation and dismissal.

2, Party A in accordance with the requirements of the project, arrangements for Party B to implement the project contract content, Party B shall unconditionally comply with the implementation.

3, Party A to provide Party B as convenient as possible construction conditions, and according to the labor contract and the owner of the payment of labor fees.

4, Party B to provide to the construction workers to implement the real name system, the establishment of health status files, the disability and mental retardation of the workers are dismissed, shall not enter the construction.

(B) Party B

1, Party B must be submitted to Party A in line with the contracting qualifications and the right to put forward legitimate requirements of Party A, take the initiative to undertake all the work of the contract to ensure the quality of the project.

2, Party B must be in accordance with Party A's requirements for safe production, Party B shall not violate the safety regulations without authorization, for the violation of safety regulations for personal injury and fatal accidents, Party B must assume full responsibility, Party A is not responsible.

3, Party B has the right to reject Party A does not meet the safety requirements of the instructions, and put forward their own views for Party A's reference.

4. Party B shall not use disabled and mentally challenged workers, and shall not conceal and use them privately. At the same time, Party B shall provide a list of personnel, identity cards.

5, Party B should control their own team, not in the site and outside the illegal and criminal activities. Once caused by the consequences of crime, Party A is not responsible.

6, in order to ensure that the work schedule, Party B must be required by Party A, to ensure that the project enough labor, not passive.

VIII, breach of contract and other

1, the above terms and conditions must be strictly observed by both parties, any party to violate or cause the suspension of the project, the defaulting party must be held responsible.

2, such as Party B cause damage to the company's reputation, site equipment and the project caused some economic losses, Party A has the right to require Party B to compensate for all losses, and deducted from the contracted labor costs.

3, belonging to Party B's own equipment, bring their own tools and appliances, Party B must be their own custody, and shall not be put forward to Party A to make other requirements, and shall not find excuses to affect the quality and progress of the opening process, the resulting loss borne by Party B.

4, the contract in one _____, Party A _____, Party B _____, signed by both parties to take effect, with the same legal benefits.

Party A: __________________ Party B: __________________

Representative: __________________ Representative: __________________

Date: ____ year ____ month ____ date: ____ Year ____ month ____ day

5. Manual labor contract model simple

Party A (employer) name: _______________________________

Party B (worker) name: _________________________________

According to the provisions of the Labor Contract Law of the People's Republic of China*** and the State of China and relevant laws and regulations, Party A and Party B enter into this contract in accordance with the principles of lawfulness, fairness, equality and voluntariness, consensus and honesty.

Article 1 The term type of this contract is (fixed term/unfixed term/term for completion of certain work tasks), from _______ _____ month _____ to __________. Of which, probationary period (with/without), starting from _______ _____ month _____ to _______ _____ day.

Article 2 Party A arranges Party B to engage in the work of ____________________ and the workplace is ____________________. Party B shall conscientiously fulfill the duties of the post and complete the work on time in accordance with the content and requirements of the work arranged by Party A.

Article 3 Party A arranges Party B to implement _____ working hours work system (standard working hours/comprehensive calculation of working hours/unscheduled hours).

Article 4 Party A pays Party B's salary in full and on time in the form of cash or transfer before _____ of each month, and the salary (hourly/piecework) is __________ of which the salary during the probationary period is __________.

Article 5 Party A shall pay social insurance premiums for Party B in accordance with the relevant GJ and local regulations, the specific item is _______________. Party A shall be responsible for withholding and paying the part borne by Party B.

Article 6 Party A shall provide Party B with safety training and labor safety and health conditions in accordance with GJ regulations and necessary labor protection supplies. Arrangements for Party B to engage in occupational hazards of the work, should be regularly for Party B to conduct health checks. Party B in the labor process should strictly abide by the system specifications and operating procedures.

Party B in the event of work-related injuries, Party A shall take timely measures to enable Party B to get treatment, and in accordance with the provisions of the "Regulations on Work-Related Injury Insurance", to pay the appropriate treatment of work-related injuries.

Article 7 Party A and Party B shall perform, change, cancel and terminate this contract in accordance with the relevant provisions of the Labor Contract Law. Party A shall pay economic compensation to Party B in accordance with the relevant provisions of the Labor Contract Law.

Article 8 Party A unlawfully terminate or terminate this contract, Party B requires the continuation of this contract, Party A shall continue to perform; Party B does not require the continuation of this contract or this contract has been unable to continue to perform, Party A shall, in accordance with the law, the economic compensation standard of two times the compensation to be paid to Party B.

Article IX the other matters agreed by the parties: _______________________________________

Article X labor contract outstanding matters, according to the GJ and the relevant local regulations.

Article 11 This contract shall take effect from the date of signature or seal of A and B. This contract is in duplicate, A and B each sign a copy.

Party A (official seal) _________________________ Party B (signature) _________________________

Legal representative (principal person in charge) _______________________________

Date of signature. Date of Signature: _______ _____ _____ _____ _____