Project balance payment agreement 1
Ordering party:
Contractor:
According to the "People's Revolution of the People's Republic of China and the State Council" In accordance with the provisions of the Contract Law and relevant laws and regulations, in line with the principles of good faith, mutual benefit, and after full consultation and consensus by both parties, this contract is entered into.
The first custom-made product for processing contract
1.1 Product name: Galvanized surface treatment of scaffolding
1.2 Specifications: Subject to actual delivery
1.3 Quantity: subject to actual delivery
Article 2 Contract Price
2.1 Total contract price or pricing method: Yuan per ton.
2.2 Payment method: Quarterly settlement, payment at the end of each quarter
Article 3 Quality requirements and technical standards for processed finished products:
3.1 Quality requirements: In accordance with national standards National standards
3.2 Technical standards: (technical standards such as hardness, strength, toughness, corrosion resistance, oxidation resistance and other physical and chemical parameters)
Methods, specifications, and quantities of raw materials , Quality
4.1 The main raw materials of scaffolding are provided by the custom-made party.
4.5 The contractor shall complete the inspection within 1 day after receiving the raw materials provided by the ordering party. If the raw materials do not meet the galvanizing requirements, the contractor shall notify the ordering party within 3 days after receipt.
Article 5 Special Commitment
5.1 The ordering party will not hand over the galvanizing process of scaffolding products to a third party during the contract period. The contractor will ensure that the ordering party’s products output volume, we will no longer undertake surface treatment business from other third parties.
5.2 If either party violates the above agreement, the other party has the right to terminate the contract.
Article 6 Acceptance Criteria and Methods
6.1 Acceptance Standards:, National Standards
6.2 Acceptance Methods: All Acceptance
6.3 Customized The time for the employer to accept the ordered crops completed by the contractor: within 3 days after receipt
6.4 The location for the ordering party to accept the ordered crops completed by the contractor: within the production site of the ordering party
6.5 Before acceptance, the contractor shall submit necessary technical data and relevant quality certificates to the ordering party.
6.6 For customized products whose quality defects are difficult to detect during short-term inspection, if quality defects are discovered within one year after use, the customizing party has the right to claim compensation for losses.
6.7 If there is a dispute between the two parties regarding the quality of the ordered crops during inspection, the inspection certificate provided by the quality supervision and inspection agency shall prevail.
Article 7 Time and place for delivery (submission) of ordered crops
7.1 Both parties agree that the contractor will pick up the goods to be processed and deliver the ordered crops.
7.1.1 Time for self-proposed crops: Within 3 days after the ordering party’s notification
7.1.2 Location of self-proposed crops: Within the ordering party’s unit
7.2 Both parties agree that the contractor will deliver the ordered crops
7.2.1 The time for delivering the ordered crops: within 3 days after notifying the ordering party
7.2.2 Delivery of the ordered crops Location of crops: Within the ordering party's unit
7.3 If either party requires early or delayed delivery (delivery) of ordered crops, it must reach an agreement with the other party in advance, and the agreement reached has the same legal effect as this contract.
7.4 Calculation of the date of delivery (submission) of ordered crops: If the contractor prepares its own transportation means to deliver the ordered crops, the date of stamp received by the ordering party shall prevail; if the transportation department is entrusted with transportation, the date of shipment of the ordered crops shall prevail. The date of stamp issued by the shipping department shall prevail; for self-ordered crops, the pick-up date notified by the contractor shall prevail. However, when the contractor sends a notice to pick up the ordered crops, it must leave necessary transit time for the ordering party.
Article 8 Packaging requirements and cost burden:
8.1 Packaging requirements: (The packaging method, material of the packaging items, packaging size, etc. should be specified in detail)
8.2 Cost burden: Packaging costs shall be borne by the contractor
Article 9 Transportation method and cost burden
9.1 Transportation method of customized products: car
9.2 The transportation costs shall be borne by the contractor.
Article 12 The contractor’s liability for breach of contract:
12.1 If the ordered product is not delivered according to the quality agreed in the contract, if the ordering party agrees to accept it, the price shall be determined based on the quality; otherwise Those who agree to accept it shall be responsible for redoing it. After rework, if the quality standards stipulated in the contract are still not met, the ordering party shall have the right to reject the goods, and the contractor shall compensate for any losses caused thereby.
12.2 If the quantity delivered is less than the quantity stipulated in the contract, and the ordering party still needs it, it shall make up the amount, and the supplementary part shall be treated as overdue delivery; if the part delivered is no longer needed, the ordering party shall have the right to If the contract is terminated, the contractor shall compensate for any losses caused thereby.
12.3 If the ordered product is not packaged as agreed in the contract and needs to be repaired or repackaged, the customer shall be responsible for the repair or repackaging and bear the resulting expenses. If the ordered goods are damaged or lost due to packaging that does not comply with the contract, the contractor shall compensate for the losses.
12.4 If the ordered crop is delivered overdue, a penalty of 20% of the total processing price of the ordered crop should be paid to the ordering party.
12.5 If the ordered crops are delivered in advance without the consent of the ordering party, the ordering party has the right to reject them.
12.6 If you are unable to deliver the ordered goods, you shall pay the ordering party a liquidated damages of 20% of the total value of the ordered goods.
12.7 If the raw materials, equipment, packaging and other items provided by the ordering party are damaged or lost due to poor storage, the ordering party shall be compensated for the losses caused thereby.
12.8 Failure to inspect the raw materials provided by the ordering party according to the method and time limit stipulated in the contract, or failing to notify the ordering party of replacement or supplementation according to the time limit stipulated in the contract if the raw materials are found to be non-compliant after inspection. , the contractor shall bear the corresponding losses.
12.9 If the raw materials or repair parts provided by the ordering party are replaced without authorization, the ordering party has the right to reject them, and the contractor shall compensate the ordering party for any losses caused thereby. If the ordering party requires rework or re-repair, it shall be completed according to the ordering party's requirements and shall bear the responsibility for late delivery. If the raw materials or repair parts provided by the ordering party are sold, the ordering party has the right to terminate the contract.
12.10 If the material consumption quota exceeds the material consumption quota stipulated in this contract, the material provided by the ordering party shall be used, and the excess material cost shall be borne.
12.11 In case of violation of 5.1 of this contract, liquidated damages shall be paid based on 20% of the custom-made processing price.
Article 13 Liability for breach of contract by the ordering party:
13.1 If the quantity, specifications, quality or design of the ordered crops are changed midway, the contractor shall be compensated for the losses caused thereby.
13.2 If the contract cannot continue to be performed due to the ordering party’s reasons during the performance of the contract, the ordering party shall pay 20% of the total value of the unfulfilled portion of the price to the contractor as liquidated damages.
13.3 If the contractor fails to provide raw materials to the contractor within the time stipulated in the contract, the contractor has the right to terminate the contract and compensate for the losses caused to the contractor; if the contractor does not request to terminate the contract, the date of delivery of the ordered products It should be postponed.
13.6 If you refuse to accept the ordered crops without reason, you will be compensated for the losses caused to the contractor.
13.7 When changing the delivery location or receiving unit (person) of the ordered goods, you will be responsible for the additional expenses incurred.
13.8 In case of violation of 5.1 of this contract, liquidated damages shall be paid based on 20% of the custom-made processing price.
Article 14 Force Majeure
14.1 If the ordered crops or raw materials are damaged or lost due to force majeure (excluding illegal infringement by a third party) during the performance period stipulated in the contract, the contractor shall The party may be exempted from liability for breach of contract after obtaining legal certificates, but shall take active measures to minimize losses.
14.2 During the period when the ordering party delays acceptance or refuses to accept without reason, the contractor shall not be held liable if the ordered crops or raw materials are damaged or lost due to force majeure.
Article 15 Dispute Resolution
Disputes arising during the performance of this contract shall be resolved through negotiation between the parties. If both parties cannot reach an agreement, choose the first method below to resolve the matter:
(1) Apply to Wuxi Arbitration Commission for arbitration.
(2) File a lawsuit in the People’s Court.
Article 16 The place where this contract is signed is Ma Rui Scaffolding Factory, Qianqiao Town, Wuxi City
Article 17 Other matters
17.1 The processing location agreed by both parties is at .
Article 18
18.1 This contract is made in two copies, with each party holding one copy.
18.2 This contract will take effect from the date it is signed and sealed by both parties. The term of this contract is one year, from _____month_____, 20xx_____ to _____month_____, _____year. The fully authorized representative of Party A is. All documents signed by other staff members of Party A must be signed and approved by the fully authorized representative to be legally effective. Documents without the signature and approval of the fully authorized representative shall not be used as the basis for settlement between the parties.
Article 19 Both parties must negotiate together on matters not covered in the contract.
There is no contract text below.
Ordering Party (Chapter):
Contractor (Chapter):
Legal Representative:
Legal Representative:
Authorized agent:
Authorized agent:
Address:
Address:
Telephone:
p>
Telephone number:
Account opening bank:
Account opening bank:
Account number:
Account number:
_____year_____month_____day
_____year_____month_____day project balance payment agreement 2
Party A: _______________________________________________________
p>Party B:_________________________________________________________
Party A and B shall comply with the Contract Law of the People’s Republic of China, the Road Traffic Safety Law of the People’s Republic of China and other relevant laws, Regulations, following the principles of equality, fairness and integrity, we reached consensus on matters related to the construction of road traffic safety facilities in the Luzhou Liquor Development Zone. The specific contents are as follows:
1. Project Overview
(1) Project name: ________________________________________________________________________________________________________________________.
(2) Project location: __________________________________________________________________________________________________.
(3) Project scope: road marking construction and road signage installation. See the attached drawing for specific construction content.
(4) Contracting method: contracting work and materials.
(5) Please see the construction drawings for additional descriptions of materials and processes.
2. Contract Duration and Extension Conditions
(1) Construction Duration
The total contract duration is calculated from the date of actual entry into the site for construction, which is approximately fifty-three days. days, the completion date is November 25, 20xx.
(2) Conditions for postponement of construction period
1. Party A fails to provide construction drawings as agreed;
2. Design changes or project volume increases;
p>
3. Party B’s suspension of work for more than 24 hours due to water, power, and gas outages;
4. Party B’s suspension of work for more than 24 hours due to other force majeure.
(3) Party B shall submit an extension request to Party A in writing within 1 working day after meeting the conditions for extension of the construction period. Party A shall confirm the request within 1 working day after receiving the report, and no request will be made after the deadline. Confirmation shall be deemed as agreement to extend the construction period.
3. Construction and safety requirements
(1) Construction requirements
1. Party A shall assist Party B in handling relevant construction permit procedures and coordinate relations with all parties.
2. Party B shall strictly comply with relevant national requirements, design the construction plan for Party A free of charge, and submit the planning plan to Party A within seven working days after the contract is signed.
3. After Party B receives the notification that Party A’s construction plan has passed the review, Party B will complete the processing of the main components and transport them to the construction site within seven working days.
4. Party B shall purchase and process in strict accordance with the requirements in the construction drawings, and provide relevant materials with quality assurance certificates.
5. Party B shall strictly carry out civilized construction in accordance with the construction requirements specified in the construction permit certificate. Party B shall be fully responsible for any losses caused by failure to comply with the requirements for rough construction.
(2) Safety Requirements
Party B shall abide by the relevant management regulations on production safety in engineering construction, organize construction in strict accordance with safety standards, take necessary safety protection measures, eliminate hidden dangers of accidents, and accept Supervision and inspection by Party A’s representatives.
IV. Project Quality, Acceptance and Warranty
(1) Quality Standards
Party B shall strictly comply with the "Reinforced Concrete Design Code" GBJI0-87, "Highway "Specifications for the Design of Traffic Signs and Markings" JTGD82-20xx clearly requires construction to ensure project quality.
(2) Project Acceptance
1. Party B shall send the notice of completion acceptance in writing to Party A ten working days in advance. If Party A cannot participate in the acceptance inspection as scheduled, Party B must Respond to Party B in writing within three working days and agree on an acceptance date separately.
2. If Party A receives Party B’s acceptance notice without raising any objection, but fails to organize acceptance upon expiration, the project shall be deemed to be completed and qualified.
3. After the project is completed and accepted, the handover of the project will be completed within three working days from the day after the acceptance is passed.
(3) Project Warranty
The project warranty period is one year from the day after the project is completed and accepted. Party B is responsible for the warranty of the project. During the warranty period, except for project maintenance caused by force majeure factors In addition, all costs involved such as material costs and labor costs will be borne by Party B. After the expiration of the warranty period, Party B will provide lifelong maintenance services.
5. Contract Amount and Cost Settlement
(1) Contract Amount: RMB 2,836,483 Yuan.
(2) Within five working days from the signing of the contract, Party A shall pay Party B 30% of the total contract amount as the first-stage progress payment.
(3) Within seven working days after the installation of the facilities is completed, Party A shall pay Party B 50% of the total contract amount as the second stage progress payment.
(4) Within twenty working days from the day after the project is completed and accepted, Party A shall pay Party B 15% of the total contract amount as the third stage progress payment.
(5) 5% of the total contract amount shall be used as a warranty deposit. The warranty period is one year. If there are no quality problems during the warranty period, Party A will refund the warranty deposit within ten working days after the expiration of the warranty period. The full amount shall be paid to Party B.
6. Liability for breach of contract
(1) Party A’s breach of contract
Due to Party A’s failure to pay the project progress payment on time as agreed in the contract, Party B’s construction period was If there is a delay, Party A shall bear the additional costs of material storage, lost work, etc. due to the delay in the construction period.
(2) Party B’s breach of contract
1. Except for force majeure factors, due to Party B’s reasons, all completed works are not completed and accepted by the date stipulated in this contract. For each day overdue, Party B shall report to Party A shall pay one thousandth of the total contract price as liquidated damages, calculated until the date when all projects are accepted and accepted.
2. If the project fails to be put into use due to quality problems caused by Party B, Party B shall pay Party A a liquidated damages of 10% of the total contract amount and bear all losses caused to Party A.
3. Party B shall bear full responsibility for safety accidents caused by Party B's failure to comply with the requirements of safety production regulations during the construction process and shall compensate Party A for all losses caused by the accident.
7. Dispute Resolution
When Party A and Party B encounter disputes during the project, they should try their best to resolve them through negotiation. If negotiation fails, either party may bring a lawsuit to the court at the place where the contract is performed.
8. Supplementary Provisions
(1) This contract is made in four copies, with Party A and Party B each holding two copies. It will take effect upon signature and seal of both parties.
(2) For matters not covered in this contract, both parties may negotiate a supplementary agreement based on the specific circumstances and relevant provisions, which shall have the same effect as this contract.
(3) Contract attachments
1. Standards, specifications and relevant technical documents;
2. Construction drawings;
3. Written agreements or documents regarding project negotiations and changes between the two parties.
Party A: _______________________________________________________________________________
Address: _______________________________________________________________________________
Representative:
Telephone/Fax: _______________________________________________________________________________
Account opening bank: _______________________________________________________________________________
Account number: ____________________________________________________________________________
Party B: ____________________________________________________________________________________________
Address: ____________________________________________________________________________________________
Representative:
Telephone/Fax: _______________________________________________________________________________
Account opening bank: _______________________________________________________________________________
Account number: _______________________________________________________________________________
Signing date: _____ year _____ month _____ day
p>