Name of the project:
Commissioning unit (Party A):
Testing unit (Party B):
Inspection Permit No.
General information of the project (to be filled in by Party A)
1. Nature of the project:
2. Location of the project:
3. Total amount of the contract for the project:
1.
4, other circumstances:
I. Rights and obligations of the two sides
(a) Party A's rights and obligations:
1, Party A in the project need to carry out the relevant quality testing, according to the requirements of Party B to fill out and submit the testing power of attorney.
2, Party A shall provide the technical parameters of the test project and test preparations.
3, such as Party A needs to the scene for sampling or inspection operations, should be notified in advance and arrangements, and is responsible for organizing personnel to work with Party B.
4, to send the sample contains any known or potential hazards, such as radioactive, toxic, harmful or explosive presence, should be notified in advance to Party B, otherwise the consequences of Party A is responsible.
5, Party A on the test results if there are objections, please within fifteen days from the date of completion of the "Inspection Report" to Party B in writing, re-inspection of the original "Inspection Report" is attached to the re-inspection and pre-payment of re-inspection fees. If the re-inspection results do not match the content of the objections, Party A's re-inspection costs as usual; otherwise, Party B will refund the content of the objections paid by Party A test and re-inspection fees. Non-repeatable test is not re-inspection;
6, Party A needs to pay the corresponding testing costs to Party B according to the payment method of this agreement.
7, all kinds of testing data on the construction in progress have the right to know, the agreement can be queried in the process of implementation.
8, the right to obtain engineering testing consulting services from Party B.
(B) Party B's rights and obligations:
1, Party B in Party A's contract period to provide specification requirements for quality testing services; in line with the Chinese people *** and the country's relevant industry standards and quality requirements of the technical supervision departments.
2, Party B must be submitted to Party A after receipt of the test commission according to the promised period to provide Party A with the corresponding test report.
3, Party B is only responsible for the sample, the test results only reflect the evaluation of the sample, the use of test results and the resulting direct or indirect losses, and the inspection unit has nothing to do.
4, on the discovery of major quality issues (such as the actual test results less than the design requirements, etc.), timely notification to the Party.
5, do a good job related services, special project testing (or Party B testing capacity outside the project), subcontracting should be notified to Party A before the subcontracting unit, after obtaining the consent of Party A before subcontracting.
6, to provide testing and consulting services, to guide Party A sampling work.
Second, the detection costs and payment
Physical testing fees according to the yuan / square meter (one yuan per square meter), the detection of the building area according to the actual detection of square meters; monthly billing settlement according to the actual detection of the area, the Party paid the corresponding detection costs before the 10th of the following month.
Third, testing standards
1, Party A clear testing standards (can be national standards, industry standards or corporate standards), according to Party A specified standards for testing.
2, Party A did not specify the detection standard, according to the standard of acceptance of the construction of the project.
3, the implementation of various types of standards priority level: national standards & gt; industry standards & gt; enterprise standards.
Fourth, other terms
Detection project for entity detection (including concrete ultrasonic rebound, floor thickness, protective layer of steel reinforcement), other detection projects confirmed by the two sides in separate consultations.
V. Liability for breach of contract
This agreement shall enter into force after signing and sealing, Party A and Party B must *** with the compliance, if there is a dispute, it should be resolved by way of friendly consultation.
Power of attorney (agreement) in duplicate, A and B each party to take one, signed or sealed by the authorized person to take effect.
Party A: Party B:
Legal (proxy): Legal (proxy): Manager: Manager:
Fax: Fax:
Phone: Phone:
Unit Address: Unit Address:
Date of signing of the contract: Monthly
Power of attorney contract Part 2Client: ID Card. No.
Trustee: ID No.
I hereby appoint the trustee as my agent to handle the following matters in respect of the lease of the house located in my possession:
1,
2,
3, the signing of the lease contract of the said house, invoices for rent, registration changes, etc.; the rent of the said house is collected on my behalf, The collection of the rent of the above building, the collection of property management fees, utility bills, etc., and all other affairs of the above building.
Authorization period: from January to January
Account of the beneficiary:
Bank:
Account name:
Account:
All the documents signed by the trustee within the scope of his authority are recognized by me, and I express my true intention, and all the legal responsibility arising from this will be borne by the trustee.
This authorization, as an annex to the lease contract, is signed at the same time as the lease contract, and the lease contract has the same legal effect, effective from the date of signature.
A copy of this authorization is the same as the original and has the same legal effect.
Client: Trustee:
Date: Date:
Power of attorney contract Part 3This power of attorney declares that: (name) is the legal representative of (unit), is authorized to delegate the unit of (position) (name) in the name of the Company and its unit of workers to sign a labor contract, training agreement, commercial technology confidentiality agreement, car reform contract and other related labor contracts and agreements and handle the relevant procedures. Contracts and agreements and related formalities. I recognize all the above documents signed by the trustee in the labor activities during the period of employment and handle all the affairs related to it.
I hereby authorize
Legal Representative: (Signature and Seal)
Monthly
Trustee: (Signature and Seal)
Monthly
Authorization Letter for Legal Person
Attorney:
Address:
Legal Representative:
Trustee:
Address:Principal person in charge:
Gender: Position: Telephone:
This power of attorney declares that: the trustee may, in the name of the Company, sign labor contracts, training agreements, confidentiality agreements, car reform contracts and other related labor contracts and agreements with the workers of his/her unit and go through the relevant formalities, and that the documents signed by the trustee in the labor activities as mentioned above and deal with all matters related to them The Company recognizes the above documents signed by the trustee in the labor employment activities and the handling of all matters related to them.
Hereby entrusted
Entrusted party (signature and seal)
Monthly
Entrusted party (signature and seal)
Monthly
Power of attorney contract Part 4Party A: (hereinafter referred to as Party A)
Party B: Zhengzhou Dongsheng Household Services Co. In order to ensure the smooth progress of the daily cleaning work, both parties in the spirit of *** with the collaboration, the principle of mutual benefit, after full consultation to develop this contract.
First, entrusted to manage the scope:
(1) 1-7 building 14 units of the stairs, elevators, staircase glass, corridors, basements, handrails, rooftops, and appurtenances of the wipe, inspection and cleaning.
(2) external environment: hard surface, flower beds, green belts, water systems, underground parking lots and appendages of the wipe, inspection and cleaning.
(3) public **** area, the external environment, the periphery of the store cleaning.
Second, entrusted with the management of standards:
The ground is clean, no obvious debris, no stagnant water, the bathroom has no odor, sanitary ware has no obvious stains. (See the attached table: cleaning standards)
Third, staffing: people.
Four, entrusted to manage the funds:
1, A to B to provide management funds yuan / month.
2, the payment method: a month before the day of payment of the previous month's cleaning fee.
5, entrusted to manage the period:
Since the year from the date to the end of the month.
Sixth, the two sides of the power, responsibility, obligation:
1, Party A:
(1) for Party B to provide Party B must be the material storage room;
(2) to ensure that the Party B cleaning operations required by the water and electricity supply.
(3) Payment to Party B according to the contract.
(4) Supervise, inspect and advise Party B's work.
2, Party B:
(1) accept Party A entrusted, in accordance with the contract organization and arrangement of cleaning work.
(2) Party B should be modest (from:) accept Party A's supervision and inspection.
(3) Party B should strengthen the staff's ideological education, strict adherence to work discipline.
Seven, the contract changes, supplements and termination:
1, the consensus of the two sides, can be modified, changes and supplements to the terms of this contract, to the written contract shall prevail.
2, the expiration of the contract itself, such as the renewal of the contract, the same conditions, Party B has priority.
VIII. This contract shall enter into force on the date of signing.
Nine, this contract in duplicate, with the same legal effect.
X. A and B have a dispute over this contract, the mediation fails. The company has the right to file a lawsuit.
Party A: (seal) Party B: (seal)
Signature: Signature:
Year Month Month Day
Power of Attorney Contract Part 5Signing Time:
Plant site leveling contract
Contractor:
Legal Representative: Contact:
Address.
Contractor:
Legal representative: Contact: Qualification level: E-mail:
Address:
In accordance with the "Contract Law of the People's Republic of China" and the relevant laws and regulations, and in accordance with the principles of equality, voluntariness, fairness and good faith, the two sides on the project of the project earthwork construction engineering project matters agreed to enter into the present contract.
1, project overview
Project name: Project address: Project contract scope: 2, contract price
2.1 site leveling works unit price (including tax) for each square meter RMB yuan (capitals: Jiao whole), the amount of site leveling works for the square meter, the contract price is: yuan (capitals: yuan whole).
(1) This contract is a fixed lump-sum price and will not be adjusted under any circumstances.
(2) The contract unit price includes all costs incurred during the construction process. Including but not limited to the following: ± 30cm earth leveling, machinery in and out of the fee, inside and outside the field and along the road cleaning costs, road cleaning costs, civilized construction costs, peripheral coordination, the contractor's reasonable management fees, profits, taxes and other costs.3, payment
Payment is to be made upon the completion of the project acceptance and acceptance of the bill of lading one-time payment. The contractor shall provide the contractor in line with the contract and meet the financial requirements of Party A real, valid and legal invoices, otherwise the contractor has the right to delay payment and does not assume responsibility for breach of contract.
4, the contract duration
4.1 Project duration: start date: January, the completion date: January the total number of calendar days of the work period: days. (Or: the date of commencement of the work is subject to the date stated in the notice of commencement issued by the Contractor, and the total number of calendar days of the work period is: 10 days).
4.2 The above construction period refers to the absolute calendar period from the date of commencement of construction, including winter and rainy seasons and adverse weather (e.g., high winds, sand, dust, hail, sustained high temperatures, etc.), governmental political meetings or other events (e.g., college entrance exams, sports games, and major holidays), which is the unchanged period.
4.3 If there is any change in the work period, the written confirmation document formed by the Contractor and the Contractor shall prevail; the Contractor shall not delay the work period for any reason; the Contractor's acceptance of the Contractor's progress plan shall not alleviate or exempt the Contractor from the obligations and responsibilities in the contract.
5, the quality of the project
5.1 The contractor must be in accordance with the national provisions of the quality inspection standards, construction acceptance norms and construction drawings to organize the construction. If there are rationalization proposals should seek the consent of the contractor, and change procedures before changing the construction.
5.2 The quality of the project meets the acceptance standards of the Party. 6. General Rights and Obligations of Both Parties 6.1 Rights and Obligations of the Contractor
(1) Provide the Contractor with information related to the project, and provide the Contractor with the construction site with construction conditions and designate the Contractor's specific location for entering the site.
(2) Timely fulfillment of the obligations of completion and acceptance and settlement agreed in the contract. (3) Pay the contract price to the contractor as agreed in the contract. 6.2 Contractor's Rights and Obligations
(1) Before signing the contract, the Contractor has conducted a careful and comprehensive survey and inspection of the construction site and its surroundings, and has obtained sufficient clarifications and answers from the Contractor in respect of any queries that may exist. The Contractor shall be responsible for any understanding, inference or interpretation made by him in respect of the said information.
(2) Slope trimming must be able to meet the requirements of the Contractor and the relevant national construction specifications to ensure the stability of the foundation slopes.
(3) The contractor is responsible for handling all related matters in the process of excavation and soil transportation (including but not limited to measuring and placing lines, organizing excavation works, manual soil removal, transfer, organization and management of machines and equipments, maintenance of transportation roads, removal of garbage from excavated ground, and inspections by sanitation departments, etc.);
(4) The contractor is required to transport the transported earth to the designated area of the contractor in strict accordance with the instructions of the contractor. (4) The Contractor shall transport the soil to the area designated by the Contractor in strict accordance with the Contractor's instructions, and if it fails to do so in accordance with the Contractor's instructions, the Contractor shall not measure and pay for the soil transported; and the Contractor shall not dump or sell the soil in the middle.
(5) The contractor shall clean up the site and the transportation road in time. The earth transported to the site shall be covered in accordance with the requirements of the local government.
(6) The Contractor shall be responsible for the formalities related to environmental protection, fire protection, production safety and construction noise management, etc., and the costs incurred as a result of these formalities have been included in the price of this contract; if the Contractor fails to comply with the above formalities in time according to the provisions of this contract, the administrative fines imposed by the relevant administrative authorities shall be borne by the Contractor, and the Contractor shall bear the compensation responsibility for the losses caused to the Contractor. compensation responsibility.
(7) The Contractor is responsible for the proper protection of underground pipelines and neighboring buildings, structures (including buildings under cultural relics protection), old and valuable trees and roads and other utilities; all the costs that may be incurred as a result of this have already been included in the price of this contract.
(8) The Contractor's construction operations shall not cause any damage to the access to the construction site and the public *** road and the public *** road system and its function; otherwise, the Contractor shall be responsible for repairing it, and if the third party suffers losses or incurs administrative penalties as a result of this, the Contractor shall be responsible for compensating for it or bear the responsibility for the administrative penalties.
(9) The Contractor is obliged to take strict safety measures in accordance with the relevant regulations to ensure the safety of the construction and the safety of the third party; all safety accidents occurring during the construction (including, but not limited to, the Contractor's construction personnel's own damages or causing damages to others) shall be the responsibility of the Contractor.
(10) The contractor is responsible for the maintenance of the perimeter of the base trench until the general contractor enters the site.
(11) Before signing the contract, the contractor has the scope of work of geography, humanities and other environments to understand clearly, in the construction process for the surrounding villagers and other man-made interference, malicious obstruction of construction and other behaviors, the contractor should be resolved on their own, the loss of time will not be postponed.
7, safe construction
7.1 The contractor must comply with the state and industry authorities to promulgate the implementation of the relevant laws and regulations on production safety and regulations, in strict accordance with the safety standards for the organization of construction.
7.2 All kinds of machinery, scaffolding and protective facilities used by the Contractor shall be inspected by specialized personnel, and inspection records shall be made to confirm that they are in compliance with the safety standards, and that the personnel holding their special operation certificates shall be allowed to operate them.
7.3 The Contractor must apply for accidental injury insurance for employees engaged in hazardous operations, and apply for insurance for the lives and properties of its own personnel and construction machinery and equipment in the construction site, and pay the insurance costs.
7.4 When an accident occurs, both the Contractor and the Contractor have the responsibility to try their best to take necessary measures to prevent or reduce the loss.
8. Environmental control
The Contractor shall comply with the laws and regulations on environmental protection promulgated and implemented by the state and industry authorities in the course of construction to avoid environmental pollution, and strengthen the management and control of dust, solid waste, noise, hazardous gas, sewage, etc.
The Contractor shall also comply with the laws and regulations on environmental protection promulgated and implemented by the state and industry authorities to avoid environmental pollution.
9, acceptance
works with acceptance conditions, the contractor should be completed 2 days before the completion of the project, the date of acceptance of the written notice to the contractor, such as the contractor can not participate in the acceptance of the contract on schedule, must be notified in advance of the contractor, and with the contractor agreed to accept the date of the acceptance of the construction period is postponed accordingly. If the project passes the inspection, the Contractor shall hand over the completion data to the Contractor within 5 days from the date of acceptance. If the acceptance is not qualified, the contractor shall unconditionally cooperate with the contractor to rework to qualified.
10, liability
10.1 If the contractor fails to complete the work according to the contractual agreement, for each day late, the contractor shall pay 5000 yuan liquidated damages. If the delay exceeds 5 days, the Contractor has the right to terminate the contract, and the Contractor shall pay 20% of the contract price of the contracted contract as liquidated damages. In addition to this, the contractor shall be responsible for any other losses caused to the contractor due to the delay.
10.2 If the Contractor falsely measures the earth, the Contractor shall pay to the Contractor liquidated damages of two times the amount of false measurement.
10.3 If the Contractor dumps or sells earth during the construction period, or fails to transport the earth to the designated place, the Contractor shall be required to pay liquidated damages of RMB 10,000 Yuan/time to the Contractor in addition to the compensation for the actual loss of the Contractor.
10.4 Over-excavation is strictly prohibited in earthwork construction, and the rework costs and all economic losses suffered by the contractor due to the contractor's violation of the technical requirements of the contractor shall be borne by the contractor.
10.5 The Contractor shall have the right to deduct the liquidated damages and damages arising from the Contractor's violation of this Contract, and the Contractor shall have the right to recover the shortfall from the Contractor.
10.6 If the Contractor fails to settle the project payment in time in accordance with the contract, and the payment cannot be made even after 30 days of delay, the Contractor shall be paid 0.1% of the unpaid amount due for each day of delay thereafter. The liquidated damages shall not exceed 5% of the contract price. If the Contractor is in default due to the Contractor's reasons, the Contractor shall not be required to pay the above liquidated damages.
11, dispute resolution
For the fulfillment of this contract or all disputes related to this contract, the two sides consult to resolve the consultation fails, agreed to the people's court of the place where the contract is signed to resolve.
12, other
This contract is in one copy, the contractor executes four copies, the contractor executes two copies, all have the same legal effect. This contract by both sides after consultation with the inclusion of supplementary provisions and the main text has the same effect. This contract shall enter into force on the date of signature and seal of both parties.
13, Annexes Annex 1 Integrity Agreement
Annex 2 Copy of business license
Annex 3 Power of attorney and ID card copy of the contracting representative Annex 4 Agreement on design changes, engineering visa-related matters (the following is not in the body)
(This page is the signature page)
Contractor: (signature) Contractor: (signature)
Signing Representative:
Signing Representative:
Email:
Signing Time:
Account Bank:
Account:
Supervisory Phone:
Chairman's Office:
Email:
Signing Time:
Bank:
Power of attorney contract Article 6
Principal: xxx
Gender: x
Date of Birth:
ID Card No.:
Residential Address:
Entrusted by: xxx
Gender: x
Date of Birth:
ID Card No.:
Residential Address:
Reason for the Entrustment I am busy at work, I can not personally handle xxxxxx related procedures, hereby entrust ____________ as my legal agent to handle the relevant matters on my behalf, the commissioner in the process of handling the above matters signed the relevant documents, I will be recognized, bear the corresponding legal responsibility.
Delegation period: from the date of signature until the completion of the above matters.
The client has the right of sub-delegation.
Client:
xxxx year x month x day
Power of attorney contract Part 7Labor contract power of attorney
Client: gender: date of birth: ID card No.: address:
Delegated to: Gender: date of birth: ID card No.: address:
Reasons for the entrustment and the matter: I, due to the, I can't personally perform the XXX year XXX work, specially entrusted ____________ for me to perform XXX work, the commissioned person in the performance of the contract period signed by the relevant documents, I will be recognized, bear the corresponding legal responsibility; XX year XX of the salary, are by the commissioned person Receive. The period of entrustment: year month day - year month day.
The commissioner: the commissioner:
Year month
Power of attorney contract Part 8The commissioner:
Legal representative: Position:
Commissioned by: Name:
Work unit: Position:
Hereby commissioned to act as a proxy for the commissioner to sign the contract with the contract on the
Granting the right of agency as follows:
1, on behalf of XXXX wages, are received by the delegate. >
1, on behalf of the negotiation of the agreement, agree on the content of the agreement;
2, as an agent in the signing of the agreement;
The trustee in the exercise of this power of attorney under the entrustment of the matter, the principal of the trustee's behavior to assume full legal responsibility.
This power of attorney is valid until the date of signing the agreement.
Entrusted by the unit:
Legal representative:
Month and year
Signing the power of attorney should pay attention to the following matters:
1, the period of time entrusted to be written to the beginning and end of the time, do not write the beginning and end of the time, it is prone to cause disputes.
2, there are three methods of authorization to delegate: express authorization, implied authorization and retrospective.
3, special power of attorney if between citizens, should be notarized to ensure the authenticity and legality of the act of delegation.