First, the family renovation contract sample
Customer (Party A):
Organizer (Party B):
Engineering project:? Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, in accordance with relevant national laws and regulations, this contract (including its annexes and all supplementary contracts) is hereby signed for * * * to abide by.
Article 1: Project Overview
1.？ Project address: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _? ;
2.？ Project: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ square meters;
3.？ Construction content:? ;
4.？ Method of entrustment: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
5.？ Project commencement date: _ _ _ _ _ _ year? _ _ _ _ _ month? _ _ _ _ _ _ days? ;
6.？ Project Completion Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Day? ;
7.？ Total days of the project: _ _ _ _ _ _ _? God? ;
Article 2: Project Price
Total project price (amount in words)? Yuan, (digital amount)? Yuan.
Article 3: Quality Requirements
1.？ The varieties, specifications and names of the main materials used in the project shall be approved by both parties.
2.？ Regarding the acceptance standard of this project, both parties agree to refer to the local municipal standard DB3 1/T30- 1999 Acceptance Standard for Residential Decoration.
3.？ During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.
4.？ Quality Supervision Department: Home Decoration Professional Committee of City Interior Decoration Industry Association.
5.？ Where the materials and equipment are purchased by Party A, the product quality shall be borne by Party A; Party B shall be responsible for the quality of the project.
6.？ If Party A hires a project supervisor by itself, it shall notify Party B before the project starts, so as to facilitate the work connection.
Article 4: Supply of Materials
1.？ Party B shall clearly mark the price of all materials used in this contract in strict accordance with the relevant national price regulations, and shall not use them for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at twice the price of the misappropriated materials.
2.？ If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..
3.？ The materials and equipment that Party B is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. After the materials are accepted by Party A, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.
Article 5:? Payment type/method
1. After signing the contract, Party A shall pay 20% of the contract price as the advance payment; Party A shall pay 20% of the contract price for the second time when the construction period is over half. The remaining 60% will be settled by Party A after the project is completed and accepted.
Article 6:? construction period
1. If the completion is delayed due to Party B's reasons, Party B shall pay Party A 1% of the working expenses as liquidated damages every day until the working expenses are deducted. If the completion is delayed due to Party A's reasons, Party B shall be paid 1% of the labor cost in the decoration project price for each day of delay.
2. If the unqualified materials and equipment selected by Party A affect the project quality and time limit for a project, Party A shall bear the cost of rework, and Party B shall bear the cost of rework for quality accidents caused by Party B's construction, and the time limit for a project remains unchanged.
3. During the construction, the shutdown caused by engineering quality problems and disagreement between the two parties shall not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration to coordinate the handling, resolve the dispute as soon as possible and continue the construction.
4. If it is necessary to rework due to Party A's reasons, or if the construction period is delayed due to Party A's change of construction contents, it is necessary to apply for a visa, and Party A shall bear all the construction costs. If rework is caused by Party B, Party B shall bear the responsibility, and the construction period will remain unchanged.
5. During the construction process, Party A shall be responsible for the quality problems and time delay caused by notifying the construction personnel to change the construction content without Party B's consent.
Article 7:? acceptance of works
1.？ For project quality acceptance, except for concealed projects, Party B shall organize Party A to conduct completion acceptance after the project is completed. Both parties shall handle the project settlement and handover procedures.
2.？ After Party B notifies Party A of process acceptance and completion acceptance, Party A shall be present for acceptance within three days. Failing to do so within the time limit, Party A shall be deemed to have voluntarily waived its rights and passed the acceptance. If there is any problem, Party A shall be responsible for it. Party A's own occupancy is deemed as qualified.
3.？ If Party A fails to come for acceptance within the time specified by Party B, it shall notify Party B in time and set another date. However, Party A shall acknowledge the completion date of the process or project, and bear Party B's storage fee and related expenses.
Article 8: Other matters
1.？ The first party
The house plan and water, electricity and gas circuit diagram approved by the property management department must be provided, otherwise Party A shall provide the house plan and water, electricity and gas circuit diagram and make on-site disclosure to Party B. ..
2.？ party B
Homework (name)? As the on-site representative of Party B, be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction tasks on time with good quality and quantity.
Be responsible for the safety, fire prevention, certificates and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible. In case of any safety accident due to construction, Party B shall be responsible for it.
Strictly fulfill the contract and implement the credit period. If the completion is delayed, such as divestiture, deceleration or excuse to induce Party A to advance capital, it will be considered as a breach of contract after investigation. Undertake the warranty responsibility within the scope of decoration construction, and the warranty period is 36 months from the date when the project is completed and accepted by Party A. ..
Article 9: Liability for breach of contract
After the contract comes into effect, during the performance of the contract, the party that terminates the contract without authorization shall pay the other party 5% of the total contract amount as liquidated damages. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.
Article 10: dispute settlement
1. In case of any dispute during the performance of this contract, both parties shall settle it through negotiation without affecting the project progress. Or complain to the Home Improvement Committee of the Interior Decoration Industry Association of the city with this contract and the advance payment receipt, and ask for a solution.
2. If the parties are unwilling to settle the dispute through negotiation or mediation, or negotiation or mediation fails, they may apply to the Arbitration Commission for arbitration or bring a lawsuit to the people's court according to this contract.
Article 11: Modification and Termination of the Contract
1.？ After this contract is signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing, and pay a penalty of 65,438+00% of the total contract price, and go through the termination procedures.
2.？ In the process of construction, either party shall propose to terminate the contract in writing to the other party. After both parties agree to go through liquidation procedures and conclude a termination agreement, the contract shall be deemed to be terminated.
Article 12: Contract comes into effect
1.？ This contract and its annexes shall come into effect after being sealed and signed by both parties.
2.？ The supplementary contract has the same legal effect as this contract.
3.？ This contract (including annexes and supplementary contracts) is made in duplicate, with each party holding one copy.
Party A (Owner):? Party b:? (signature)
Date of signature: xx, XX, XX.
Second, the housing renovation contract
Customer (Party A):
Organizer (Party B):
Through friendly negotiation between Party A and Party B, Party A decides to entrust Party B to decorate the living room. In order to ensure the smooth progress of the project, this contract is hereby signed in accordance with relevant national laws and regulations for * * * * to abide by.
Article 1: Project Overview
1.？ Project address: _? __。
2.？ Room specification: room type? , the total construction area? Square meters.
3.？ Construction Contents: See Annex (1) List of Home Decoration Construction Contents and Construction Drawings for details.
4.？ Entrusting method: turnkey project of contracting and materials.
5. Commencement date: 201/April 15, and completion date: 20 1 1? June 14, total project days: 60 days.
Article 2: Project Price
Project price (amount in words)? For details, please refer to Annex (II) Budget Table of Home Decoration Engineering Materials.
Article 3: Quality Requirements
1.？ The varieties, specifications and names of the main materials used in the project shall be approved by both parties.
2.？ The acceptance standard of this project shall be implemented with reference to the relevant provisions of the state.
3.？ During the construction, if Party A has special construction projects or special quality requirements, both parties shall confirm and sign a supplementary contract for the increased costs.
4.？ Where the materials and equipment are purchased by Party A, the product quality shall be borne by Party A; Party B shall be responsible for the quality of the project.
5.？ If Party A hires a project supervisor by itself, it shall notify Party B before the project starts, so as to facilitate the work connection.
Article 4: Supply of Materials
1.？ Party B shall clearly mark all materials used in this contract in strict accordance with the relevant national price regulations. The materials provided by Party A shall be used in the decoration project specified in this contract, and shall not be used for other purposes without Party A's consent ... If Party B uses them for other purposes, Party B shall compensate Party A at double the price of the misappropriated materials.
2.？ If the materials and equipment provided by Party B do not meet the quality requirements or have different specifications, they shall not be used. If it has been used, all losses caused to the project shall be borne by Party B. ..
3.？ The materials and equipment that Party A is responsible for purchasing and supplying shall be qualified products that meet the design requirements, and shall be supplied to the site on time. Delayed arrival, postponed construction period and delayed punishment. According to the total amount of materials provided by Party A? 10? % shall be paid to Party B as management fee. After the materials are accepted by Party B, Party B shall be responsible for keeping them, and Party B shall be responsible for compensating the losses caused by improper keeping.
Article 5: Method of Payment
1.？ Once the contract is signed, Party A shall deal with it immediately? 100? % of the cost of engineering materials and construction? 50? %; When the progress of the construction period is halfway (2011May 25th), Party A will pay the second project payment? 40? %。 Surplus? 10? At the end of%, after the project is completed and accepted, Party A will be entertained for settlement. (Note: Construction costs include labor costs).
Party A's failure to pay on time is a breach of contract, and Party B has the right to stop the construction. If the project price is not settled after acceptance, it shall not be delivered for use.
Article 6: Construction Period
1.？ If the completion is delayed due to Party B's reasons, what is the daily cost? 1? % shall be paid to Party A as liquidated damages until the work expenses are deducted. If the construction period is delayed due to Party A's reasons, each day of delay shall be calculated as the labor cost in the decoration project price? 1? % shall be paid to Party B as lost time.
2.？ If the unqualified materials and equipment selected by Party A affect the project quality and construction period, Party A shall bear the rework expenses, and Party B shall bear the rework expenses for quality accidents caused by Party B's construction, and the construction period will remain unchanged.
3.？ In the process of construction, the shutdown caused by engineering quality problems and disagreement between the two parties shall not be punished as delayed work or delayed construction period. Both parties should take the initiative to ask the relevant departments for mediation or arbitration, coordinate the settlement of disputes as soon as possible, and continue the construction.
Article 7: Other matters
1.？ Party A's responsibilities
1? ) Party B must provide the house floor plan and water, electricity and gas circuit diagram approved by the property management department, or Party A shall provide the house floor plan and water, electricity and gas circuit diagram and make disclosure to Party B on site. ..
2? ) The second renovation project, in which all or part of the house is vacated, will affect the removal of obstacles in the construction. Necessary protective measures shall be taken for furniture and furnishings that can only be partially vacated in the house, and all formalities shall be handled with Party B, and the expenses shall be borne by Party B..
2.？ Party B's responsibilities
1? ) Assign a staff member as the on-site representative of Party B to be responsible for the performance of the contract, organize the construction according to the requirements of the contract, and complete the construction task on time with good quality and quantity.
2? ) Be responsible for the safety, fire prevention, related certificates and civilized construction of the construction site, so as to prevent accidents such as pipeline blockage, water leakage, power failure and damage to articles caused by construction from affecting others. If it happens, it must be repaired or compensated as soon as possible.
Article 8: Liability for breach of contract
After the contract comes into effect, during the performance of the contract, the party who cancels the contract without authorization shall pay the total contract price? 5? % as liquidated damages to the other party. If the actual loss caused to the other party by the unauthorized termination of the contract exceeds the liquidated damages, it shall be compensated.
Article 9: Settlement of disputes
In case of any dispute during the performance of this contract, both parties shall settle it through consultation without affecting the project progress. If the parties are unwilling to settle the dispute through consultation, or if consultation fails, they may bring a lawsuit to the people's court in accordance with the contract.
Article 10: Modification and Termination of the Contract
1.？ After this contract is signed by both parties, both parties must strictly abide by it. If either party needs to change the contents of the contract, it shall sign a supplementary agreement after both parties reach an agreement through consultation. If it is necessary to terminate the contract, the party who proposes to terminate the contract shall do so in writing and on the basis of the total contract price? 10? % to pay liquidated damages, and go through the formalities to terminate the contract.
2.？ In the process of construction, either party shall propose to terminate the contract in writing to the other party. After both parties agree to go through liquidation procedures and conclude a termination agreement, the contract shall be deemed to be terminated.
Article 11: Entry into force of the contract
1.？ This contract shall come into effect after being sealed and signed by both parties.
2? This contract is made in duplicate, one for each party.
Party A (Owner):? Party B:
Signature:? Signature of entrusted agent:
Signing date:? Date of signing:
III. Facade Decoration Contract
Party A:
Party B:
Article 1: Through friendly negotiation between Party A and Party B, based on the principles of trust, cooperation, coordination and economy, Party A agrees to entrust Party B to decorate the facade and ensure the smooth completion of all projects.
Article 2: Project Overview:
1. Project name: facade decoration
2. Project site
3. Contracting method: auxiliary materials contracting.
Article 3: Design Standards and Quality Requirements:
1. The facade decoration design is provided by Party A, and Party B puts forward good suggestions.
2. Woodworking part: the base is firm and firm without pulling, and the vertical and horizontal deviation should be less than 0.5cm ..
3. Paint part: no obvious air holes, nail holes and other phenomena, smooth and comfortable feel, no brush leakage.
4. Water and electricity part: laying electric conduit according to the situation of the same site, and the wiring and piping should be horizontal and vertical.
5. Tiles must have straight seams without dent or damage.
6. The style is not the quality. Party B will carry out the construction according to the drawings and will not undertake rework. Party A will be responsible for the cost of rework.
7. During the renovation of the facade, Party B is responsible for the protection of the finished products in Party A's facade. If there is any damage, Party B shall compensate according to the price.
Article 4: Warranty Period:
1. Height of waterproof wall 1m for main wall and 0.5m for other areas. The warranty period is 2 years.
2. The floor tiles must be stitched straight without hollowing and damage, and the warranty period is 2 years.
Both parties agree that Party B shall take full responsibility for the above problems during the warranty period, and be responsible for the reply (within the warranty period, it will be postponed for 2 years after Party A's acceptance).
Article 5: Contracted projects
1. According to the project list provided by Party A and Party B, Party A and Party B agree on the expenses? Yuan.
2. Any increase or decrease according to the bill of works must be negotiated by both parties, and all expenses must be settled with any increase or decrease.
Article 6: Construction Period
What is the construction period? , the entry date is from? Year? Month? Solstice? Year? Month? Day stop.
Article 7: Material Brand
According to the main material brand proposed by Party A, Party B must complete it according to Party A's requirements. See the material brand list for details.
Article 8: Method of Payment
The payment method is divided into three times: the two parties sign the contract for the first time, and Party A pays Party B the material fee? Yuan, finally completed, Party A will keep 3% quality deposit after acceptance, and the balance will be paid off.
Name of payee:? Bank of deposit:? Account number:
Article 9: Warranty Scope
Paint and wall paint are guaranteed for half a year, and water and electricity are guaranteed for two years.
Article 10: This contract is made in duplicate, one for each party, and shall come into effect after being signed.
Signature of Party A:? Signature of Party B:
Year? Month? sun
Here, Bunny has to remind everyone that the home improvement market is very prone to engineering disputes, such as subcontracting, affiliated companies, decoration quality, delays in construction period, and disputes over budget and final accounts. In order to prevent such disputes, the owners must sign a family renovation contract to ensure their own interests.
Tubatu Online provides you with "every decoration quotation, 1-4 local decoration companies, 3 sets of decoration design schemes" and the decoration pit avoidance strategy for free! Click this link:/Zhu Ye /zxbj-cszy.php? to8to _ from = SEO _ zhidao _ m _ jiare & amp； Wb, you can get it for free ~