1.2022 Purchase and Sales Contract Format Model
Party A: __________________
Party B: __________________
I. Product Name, Trademark, Model, Quantity and Amount.
Second, the quality requirements of technical standards: Party B shall produce in accordance with the technical drawings provided by Party A, the quality of which meets the industry standards, quality problems occurring by Party B is responsible for the free replacement, and to ensure that the replacement of new products in place within one working day.
Third, the delivery time and location: see the table above, Party B delivery to the designated location of Party A, the party to bear the freight.
Fourth, the payment settlement method and period: Party A in the receipt of goods and acceptance of the goods, the payment of goods accumulated _________ above, Party B issued _________% VAT invoice, Party A pay off the purchase price.
V. Quality issues and deadlines: If there is a quality problem, Party A since the receipt of Party B's products _________ working days to Party B, the quality of the device, Party B unconditional refund, replacement.
VI. Liability for breach of contract:
1. Party A fails to make payment on time, for each day of delay, bear the late payment part of the total amount of _________% of the liquidated damages to compensate Party B.
2. Party B fails to deliver the goods on time, and for each day of delay, Party B shall bear the liquidated damages of _________% of the total amount of the delayed delivery.
VII, the way to resolve contract disputes:
In the fulfillment of this contract, such as disputes, the two sides should be resolved through friendly consultation, the consultation fails to apply to the Arbitration Commission for arbitration or directly to the People's Court in the location of the Party A lawsuit.
VIII, this contract in duplicate, A and B each party to sign one, the two sides sealed the date of signing effective, fax and the original contract has the same legal effect.
Party A: _________
Party B: _________
Date: _________ year _____ month ___
2.2022 Sample Form of Purchase and Sale Contract
________ Limited (hereinafter referred to as Party A) in order to unify and improve the store and product image of ___________________________ (hereinafter referred to as Party B). To create a better sales environment for Party B, through consultation between the two sides, in the spirit of voluntary, equal, reciprocal, mutually beneficial principle, reached the following agreement:
1, since the date of signing the agreement, Party A is responsible for providing Party B with the overall design and decoration of the store. Decoration content includes:
The design, production and installation of door billboards;
The design, production and installation of product image wall;
The design, production and installation of product displays;
The development of the main store colors, painting;
The design, production and installation of the store roof flag;
Party A free of charge to provide you with a set of samples, the installation of uniforms. Provide party B free of charge, a set of samples, installation of four sets of uniforms and a variety of certificates and product descriptions.
2, since the date of signing the agreement, Party B is required to pay Party A a decoration deposit of RMB _____________.
3, Party B in the agreement within one year from the date of signing shall not operate other brands or products in conflict with Party A, or will be deducted from Party B's decoration deposit.
4, A, B and the two sides of the full year of cooperation, Party B can well maintain the image of Party A's products, and no breach of contract, Party A will return Party B's renovation deposit (return to the floor to cash).
5, this agreement in three copies, Party A 2 copies, Party B 1 copy.
6, this agreement is modified by the two sides to solve the problem.
7, this agreement is effective from the date of the seal of both parties to _______ the _______ month _______ termination.
Party A: __________________
Party B: __________________
Office address: ______________ Office address: ______________
Bank of account: ______________ Account Bank: ______________
Account Number: __________________ Account Number: __________________
Zip Code: __________________ Zip Code: __________________
Phone: __________________ Phone: __________________
Fax: __________________ Fax: __________________
_______ Year ______ Month _____
3.2022 Sample Form of Purchase and Sale Contract
Seller: (hereinafter referred to as Party A)
Buyer: (hereinafter referred to as Party B)
The buyer and seller on the seller for the provision of the distribution box related matters, by consensus reached the following terms and conditions, the signing of the contract, for the purpose of *** with the letter and spirit.
I. Equipment name, model, quantity and amount
1, the total amount of the contract:
RMB (upper case): 30,000,000,000,700,100,800 yuan positive lower case: 34718 yuan
2, equipment and its price
Second, the time and place of delivery
1, the place of receipt:
2, the period of time:
2, the goods:
3, the seller and the buyer have agreed on the following terms and conditions to sign this contract for the purpose of *** with the letter.
Third, the quality requirements
The seller should ensure that the above products are produced in accordance with national specifications, in line with the relevant technical standards and norms issued by the state and the production region, the seller shall send the corresponding product specifications with the equipment, inspection reports and certificates of conformity and other information. Specific models to the seller's offer list shall prevail.
Fourth, the handover and acceptance of equipment
The buyer should be based on the waybill, accompanied by a single, product certification and contract acceptance.
V. Payment and term
After the contract is signed, the buyer pays a deposit of 10,000 yuan, and pays the balance after the product is accepted.
Six, quality assurance
The seller guarantees that the quality of the goods supplied meets the relevant national requirements.
Seven, the warranty period:
1, the warranty period of years. Warranty period from the date of acceptance of the contract products delivered for use. Warranty period the seller of the products supplied free of charge replacement and warranty.
2, the warranty does not cover:
Damage to the equipment caused by loads beyond the requirements and due to temporary changes in the program at the site will be the responsibility of the buyer.
3, after-sales service: the seller arrives at the site within one hour after receiving the buyer's notice, restores the supply and distribution system in the shortest possible time, and maintains it for life. Beyond the quality warranty scope and period of damage, the seller will charge the material and labor costs at the factory price.
Eight, confidentiality terms
The buyer of the technology provided by the seller, technical information, prices and related solutions to bear the responsibility of confidentiality.
IX. Liability for breach of contract
1, the two sides signed, without the written consent of the other party does not fulfill all the obligations of the contract, the party in breach of the contract shall pay the other party equivalent to 10% of the total amount of the contract liquidated damages.
2, such as the seller of goods supplied by the quality of the buyer's works occurring quality problems, the seller shall assume the responsibility for breach of contract, and compensate for all the losses incurred by the buyer.
3, other breach of contract provisions in accordance with the Contract Law.
X. Force majeure
1, any party due to force majeure so that the performance of contractual obligations are impeded, the parties must be force majeure occurs within three days after the occurrence of the force majeure, the occurrence of force majeure and its status of the other party notified in writing. At the same time must be accompanied by a government department or authority to prove.
2. If one or both of the parties cannot perform or cannot fully perform their contractual obligations due to force majeure, after obtaining the certificate mentioned in the previous paragraph, it is permitted to postpone the performance of the contract, partially perform or not perform the contract, and partially or fully exempted from the responsibility of breaching the contract according to the actual situation.
XI. Arbitration or Litigation
All disputes arising from the fulfillment of this contract shall be resolved through consultation between the two parties. Failure to negotiate, may be litigated to the People's Court of the buyer's location.
XII, other
1, the change or termination of this contract shall take the form of a written, stamped by both parties and signed by an authorized representative shall be valid.
2, the contract in duplicate, the buyer and seller each sign a copy of the two units since the two sides signed and sealed to take effect.
3, if there is a design change, the buyer in the drawings marked out the change instructions and stamped
Party A (official seal): _________
Party B (official seal): _________
________ year ____ month ____ day
4.2022 Sample Form of Purchase and Sale Contract
Seller: __
Buyer: __
Place of Signing: __
Time of Signing: ___Year ___Month ___
I. Product Name, Specification, Model, Packaging, etc.
Name: ___
Material: ___ <
Type:___
Specification:___
Unit Price:___
Purchase Quantity:___
Total Amount:___
Second, the above price is tax inclusive, the seller issues VAT ordinary invoice to the buyer, and the above price is inclusive of freight.
Third, the delivery method is express delivery by the seller to the buyer's address or the buyer's designated address. The buyer's address is:
Fourth, the payment
The buyer will be a one-time WeChat transfer to the seller, the seller receives the payment that is arranged to ship the goods, the seller buyer to receive all the goods within three days.
The name of the seller's WeChat is: ___; micro-signal: ___
V. Seller
The goods delivered by the seller, for the regular manufacturers.
VI. Liability for breach of contract
1, the quality is not qualified, the seller shall refund the buyer all the purchase price, and bear the liquidated damages equivalent to double the total amount of the contract;
2, the seller is late in the delivery of the goods, each late day to bear the liquidated damages of 10% of the total amount of the contract, more than 7 days late, the buyer may notify the seller to terminate the contract and require the seller to bear the responsibility for breach of contract, or Continue to fulfill the contract and require it to assume responsibility for breach of contract;
3, liquidated damages are not enough to make up for the buyer's losses, but also to compensate the buyer for the corresponding losses.
VII. Disputes arising out of this contract shall be resolved through consultation between the two parties, and if the consultation fails, the contract may be resolved through litigation in the People's Court of the place where the plaintiff is located by either party.
VIII, this contract in duplicate, each party to take a copy of the two sides since the date of signature or seal.
Seller:___
Buyer:___
___Year___Month___
5.2022 Sample Purchase and Sale Contract Form
Demand: ___(hereinafter referred to as Party A)
Supplier: ___(hereinafter referred to as Party B)
< p> According to the Chinese people's *** and the State Contract Law, supply and demand parties through friendly consultation and abide by the principle of voluntariness to enter into this contract, supply and demand parties must *** with strict compliance.First, the lamps and lanterns products agreed list is shown in the table below (in addition to the special agreement of this contract, the price agreed in this contract is the price of the product, and this price for the price of tax)
Second, the product's packaging, transportation, insurance:
a) the product's packaging in accordance with the national standard packaging of similar products, i.e., cardboard packaging;
b) the product is transported by steam, and the cost of transportation and insurance in transit. Transportation costs and insurance in transit are borne by the supplier; Product acceptance criteria, confirmation and installation after receipt.
a) The supplier's products in accordance with the relevant provisions of the state of the industry to organize the production of quality and quantity;
b) After the arrival of the goods at the scene, the demand side in accordance with national regulations to organize acceptance, confirm the number and quality; in the number of goods and quality acceptance of the goods, the designated consignee must be in the delivery of goods to the designated location to sign the recognition.
Third, the settlement method and period:
The demand side in the contract signed to the supply side of the designated account remittance of the total amount of the contract: one million three hundred and seventy-seven thousand eight hundred and thirty-five thousand yuan for the deposit (i.e., prepayment); in the arrival of all the goods and the quality and quantity of the goods acceptance of the goods, to the supplier or the delivery side of the remaining amount to be paid.
Contract term: 20__ year x month x to 20__ year x month x
Fourth, the warranty period:
lamps warranty two years; metal halide lamps electronic ballasts and electronic transformers warranty two years; light source warranty one year. Above, that is, due to the supplier's reasons in the warranty period of the product quality problems, free of charge by the supplier to provide appropriate services.
V. Liability for breach of contract:
supply and demand sides of any party to violate the terms of the contract, according to the Chinese People's Republic of China *** and the State Contract Law and the following provisions of the breach of contract: the supply side fails to supply as promised, each overdue day, according to the total amount of goods not to the same period of time, the bank interest on the loan to pay liquidated damages to the demand-side, 20 days overdue, the demand-side has the right to unilaterally terminate the contract;
demand-side Failure to pay as agreed, each day late, according to the total amount of unpaid bank loan interest over the same period to pay liquidated damages, over 20 days, the supplier has the right to unilaterally terminate the contract, the demand side must pay off the amount of goods supplied.
VI. Dispute Resolution:
Disputes arising from the implementation of this contract between the supply and demand sides should be resolved through friendly consultation between the two sides, after consultation is still not resolved, the local people's court can be litigated.
VII, the original contract in duplicate, signed and sealed by both parties and the supply side to receive the advance payment will come into effect, for the implementation of a copy, the demand side to implement a copy. The contract text is valid by fax.
Party A (official seal): __
Party B (official seal): __
Party A's legal representative (signature): __
Party B's legal representative (signature): __
20__ x month x day
6.2022 Purchase and Sale Contract Format
6.2022 Purchase and Sale Contract Format
6. strong>
Party A (demander): __
Party B (supplier): __
According to the provisions of the __ and other relevant laws and administrative regulations, the buyer and seller on the basis of equality, voluntariness, openness, honesty and credit on the purchase and sale of building materials to reach an agreement on the following matters:
The first basic conditions of the building materials purchased unit: __ yuan / sets of Total price total RMB (capitals) __ million (write): ￥ __ quality standards:
Delivery time:
Delivery location:
Article acceptance: for building materials, product specifications, quantity, material, etc., and the agreement does not match or other quality problems, the buyer objections to the period of one day after the delivery of the seller, objections to the verification of sellers should be made up unconditionally or change goods.
Article III payment methods and . Time: The two sides agreed to pay the price in the first way. Purchase and sale contract (a) when signing the contract, the buyer pays (deposit/advance payment) 400,000 (the deposit shall not exceed __% of the total price), the goods to the acceptance of the remaining balance of a one-time payment:
Article IV: Liability for breach of contract
(a) the seller's liability for breach of contract:
1, building materials products detected by a professional organization does not meet the national standards or the agreed quality standards, the seller should be Unconditional exchange, return, or compensation for the buyer's losses.
2. If the seller delays the delivery, the seller shall pay the buyer __% of the price of the delayed portion of the liquidated damages per day; if the delivery is delayed for one day, in addition to paying the liquidated damages, the buyer shall have the right to terminate the contract, and the seller shall return all the deposits, prepayments, or prices that have already been collected by the seller, but the buyer shall have the right to ask the seller to return the deposit in double amount without collecting the liquidated damages.
(b) the buyer's liability for breach of contract:
1, the buyer delayed delivery of goods, the buyer shall pay to the seller every day the delayed part of the price of __% of the liquidated damages;
2, the buyer unilaterally terminate the contract without a justifiable reason, the buyer shall compensate for the losses caused by this to the seller, the deposit has been paid without the right to ask for the return.
Article V Dispute Resolution: Disputes under this contract, the two sides shall negotiate or apply to the market organizer, the Consumer Association to mediate the settlement, but also to the administrative organs for industry and commerce to file a complaint; consultation, mediation, complaint settlement fails, should be filed with the People's Court, or in accordance with the arbitration clause or arbitration agreement reached separately to apply for arbitration. Other agreed matters:
Article 6 of the changes or additions to this contract unreasonably reduces or exempts the seller from the responsibility to be borne by the seller, the contract shall still prevail.
Undecided matters of this contract, the two sides can negotiate and sign a supplementary agreement.
Party A (official seal): __
Party B (official seal): __
___Year ___Month ___