This article is my compilation of wire and cable supply contract, I hope it can help you.
Wire and cable supply contract aContract No.: xxx
Seller: xxx cable company limited
Signing place: xxx development zone site site
Buyer: xxx company limited Signing time: 201x x month x day x yuan whole. If the quantity and model change during the supply process, the unit price of the goods will be reduced by the same proportion of the total price after concessions.
The second quality standards: the cable must comply with national standards, wire diameter and length shall not have negative tolerance, need to provide products factory certificates and 3c certification.
The third seller is responsible for the quality of the conditions and duration: the warranty period of 18 months after the completion of installation and acceptance.
Article IV packaging standards, packaging supply and recycling: packaging must ensure that the goods arrive at the scene intact. Cable tray by the seller in a timely manner recovery, if there is loss of the buyer is not responsible.
Article V random necessities, accessories, tools and the number of supply: None.
Article 6 reasonable loss standard and calculation method: None.
Article VII of the subject matter of the ownership of the buyer from the time of acceptance after the transfer, but the buyer has not fulfilled the obligation to pay the price, the subject matter belongs to the seller.
Article VIII delivery (pick-up) mode, location: according to the buyer's requirements in batches to the site. Delivery time is 10 days after the contract is signed.
Article IX mode of transportation and arrival station (port) and the burden of costs: car transport, the costs borne by the seller.
Article X inspection standards, methods, locations and deadlines: according to the national standards for cables, the current industry standards and the seller provided by the buyer to confirm the acceptance of the sample.
Article 11 installation and commissioning of complete sets of equipment: none.
Article XII settlement, time and place: after the contract is signed, the goods are delivered to the site, after acceptance of the goods paid to 60% of the price of the goods; installation is completed, debugging is qualified, verification of complete documents paid to 90% of the price of the goods; the remaining 10% as a quality deposit, paid within 14 days after the expiration of the warranty period (without interest).
Article XIII guarantee (can also be a separate guarantee contract): None.
Article 14 of the conditions for the termination of this contract: the seller's quality of supply, time is not in accordance with the contract, the buyer has the right to terminate the contract.
Article 15 liability for breach of contract: the seller did not supply according to the contract, the buyer in the right to the seller for the contract price of 1% ~ 5% of the fine. The buyer fails to pay according to the contract, the seller has the right to stop the supply.
Article XVI of the contract dispute resolution: the contract in the performance of the dispute, the parties to coordinate the settlement; can also be mediated by the local administration for industry and commerce; coordination or mediation does not work, according to the following (a) way to resolve:
(a) submitted to the Nanjing Arbitration Commission Arbitration;
(b) according to law, to the People's Court.
Article 17 This contract shall enter into force on the date it is signed by both parties.
Article 18 Other Agreements:
Purchase Contract
1. The cables will be tested according to the relevant national standards after entering the site, and the testing costs will be borne by the seller.
2, the supply quantity is a temporary quantity, the specific amount of the buyer's requirements in the construction process shall prevail, the final settlement in accordance with the actual. The seller's bidding price has included the transportation costs incurred.
3, the unit price of goods is fixed unit price, not adjusted for any reason.
4. The cables provided by the seller are brand new and unused. Cables are not allowed to have joints. The cables should hold the production license issued by the national categorized management department, and have the relevant governmental network entry license of Nanjing City, Jiangning District and so on.
5, the seller shall be responsible for guiding the cable installation, laying, testing and other technical services.
6, multi-core cable requires color separation, its color separation according to national standards (yellow, green, red, blue, black) two-color.
7, the closed end of the cable should be tight.
8, the seller produces the goods to each number of buildings as a unit, can not be the same type of specifications of the cable into one.
9. After the goods are delivered to the site, the seller is responsible for unloading the goods to the place designated by the buyer free of charge.
10, bidding documents, bidding documents, written clarification of the bidding documents as an annex to the contract, is an integral part of the contract.
The seller buyer identification (notarized) opinion:
The seller (chapter): buyer (chapter):
Residence: Residence:
Legal representative: ? Legal representative:
Entrusted agent: ? Delegated agent:
Tel: Tel:
Fax: Fax:
Bank of account: Bank of account: Identification (public) certification authority (chapter)
Account number: Account number: ? Manager:
Zip code: Zip code: Month of the year
Signing time: Signing time:
Wire and cable supply contract twoSupplier: (hereinafter referred to as Party A)
Demand: (hereinafter referred to as Party B)
Party B due to the need for the construction of the project, the purchase of power cables from the Party A, in order to clarify the rights and obligations of the two sides, by the two sides of the equal Friendly consultation, the following terms.
1. Party B's engineering construction of all the cables required from Party A to buy. Without the written consent of Party A, Party B shall not purchase cables from other channels, otherwise, Party B shall pay Party A a liquidated damages of RMB 50,000 yuan, while Party A has the right to terminate the contract unilaterally.
2. Party B according to the progress of the project needs, in stages and batches to Party A to purchase the required cable, Party B each time you need goods, should be three days in advance to notify Party A of the required cable specifications, models, quantities, production of origin, confirmed by the Party A, Party A should be within 3 days of the cable delivered to the site of the Party B. If the price of the overdue price of the cable, Party B shall pay a penalty of RMB 50,000 yuan, while Party A has the right to terminate the contract unilaterally. If Party A overdue futures price of three thousandths of the payment of liquidated damages.
3. Cable prices are determined once, not with the market price changes. Price, specifications are as follows:
180m square meters of high-voltage cable 450 meters, the unit price of 90 yuan / meter.
240m ㎡ low voltage cable 6000 meters, unit price of 60 yuan / meter.
50m ㎡ low voltage cable 8000 meters, unit price 17 yuan / meter.
4. Acceptance of cable reception: Party B should be tested upon receipt of the goods, qualified before use, if there is a quality problem should be notified in writing within 7 days from the date of receipt of the goods to Party A, and the relevant test report, otherwise the quality of the cable is considered to be fully qualified. After both parties confirm that the quality of the cable is indeed unqualified, Party A shall ship back the unqualified cable and bear the freight cost incurred in shipping back, but Party A shall not bear any other responsibility, while Party A shall exchange the qualified cable within 10 days.
5. Payment: The cable payment under this contract shall be paid in the following way: Party B pays Party A 500,000 RMB after signing the contract, Party A sends the cable to Party B according to the plan declared by Party B, and after exceeding 800,000 RMB, Party B pays the excess to Party A.
6.
6. Both parties shall strictly abide by this contract, if there are disputes between the two sides should be resolved through negotiation first, and if the negotiation fails, submit to the People's Court of the location of Party A for a ruling.
7. This contract shall enter into force after both parties sign and seal it.
8. This contract in duplicate. A and B each sign a copy.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ ____ month ____ day _________ year ____ month ____ Day
Wire and cable supply contract III__________ (demand side) (hereinafter referred to as Party A)
__________ (supply side) (hereinafter referred to as Party B)
After consultation and agreement, in accordance with the provisions of the Chinese People's *** and the country's economic law, the contract is entered into as follows:
Article 1 Party A orders from Party B the total value of RMB ___ yuan. Its product name, specifications, quality (technical indicators), unit price, total price, etc. as listed in the table
Article II Product packaging specifications and costs _______
Article III Acceptance method ______
Material name specifications quality standards unit of measurement unit of measurement unit price (yuan) total (yuan)
Article IV Payment and settlement of payments and expenses, etc. ______
Article V Delivery Regulations
1. Delivery method: ______
2. Delivery place: ______
3. Delivery date: ______
4. Transportation fee: _______
Article VI Economic Responsibility
(a) Party B shall be responsible for the Economic responsibility
1. When the product color, variety, specification and quality are not in accordance with the provisions of this contract, Party A agrees to utilize the product at the price according to the quality. Can not be utilized, Party B shall be responsible for warranty, warranty return, warranty replacement. Due to the above reasons for the delay in delivery time, each day late, Party B shall be calculated according to the late delivery of part of the total value of the purchase price of three ten thousandths of the late delivery of liquidated damages to be repaid to the Party.
2. If Party B does not deliver the products according to the quantity stipulated in this contract, Party A should make up for the underpayment if needed. Party A can return the goods if not needed. Party B shall bear the loss caused by the return. If Party A needs and Party B can not deliver, then Party B should pay Party A can not deliver part of the total value of the goods 5 % of the penalty.
3. Product packaging does not comply with the provisions of this contract, Party B shall be responsible for repair or repackaging, and bear the cost of repair or repackaging. If Party A requires not to repair or repackaging, Party B should be inconsistent with the provisions of the contract packaging value of 2% of the penalties to be paid to Party A.
4. Product delivery time does not match the contract, every day of delay, Party B shall pay Party A to delay the delivery of part of the total value of the payment of three ten thousandths of the penalty.
(B) Party A should be responsible for the economic
1. Party A, such as change in the middle of the product color, variety, specifications, quality or packaging specifications, should be repaid to change the part of the purchase price (or value of the packaging) of the total value of the X % penalty.
2. Party A, such as the return of goods, should be negotiated with Party B in advance, Party B agreed to return the goods, should be reimbursed by Party A part of the goods returned by Party B X % of the total value of the penalty. Party B does not agree to return the goods, Party A is still in accordance with the provisions of the contract.
3. Party A did not deliver the technical information, raw materials or packaging to Party B according to the specified time and requirements, in addition to Party B will have to postpone the delivery date, every day of postponement, Party A shall pay Party B to postpone the delivery of the total value of the product of three ten thousandths of the penalty. If Party A is always unable to submit the above information should be submitted, it should be treated as a midway return.
4. The materials are self-pickup by Party A, such as Party A did not pick up the goods according to the specified date, for each day of delay, Party B should be reimbursed to the delayed pick up part of the total amount of the goods of three ten thousandths of the penalty.
5. If Party A fails to pay Party B according to the specified date, for each day of delay, it should pay Party B three ten-thousandths of the total amount of delayed payment, as a penalty for delay.
6. If Party B delivers or transports the products on behalf of Party A, if Party A refuses to take over the goods, Party A shall bear the losses and transportation costs and penalties caused by this.
Article 7 The price of the products, if adjusted, must be negotiated by both parties and reported to the price department for approval before the change. Before the approval of the price department, the original price should still be implemented according to the contract. If Party B's delivery is affected by the price problem, Party B shall pay Party A three ten-thousandths of the total value of the delayed part as penalty for each day of delayed delivery.
Article 8 A, B, any party to request all or part of the cancellation of the contract, you must provide adequate reasons, after consultation between the two sides, and reported to the higher authorities for the record. The party that proposes to cancel the contract shall pay the other party X% of the total amount of compensation for the canceled part of the contract.
Article 9 If Party B has to change the product varieties, colors, specifications, quality and packaging due to significant changes in production materials, production equipment, production process or market, it should consult with Party A __ days in advance.
Article 10 All the terms of this contract, A, B, either party shall not change or modify without authorization. If one party alone changes or modifies this contract, the other party shall have the right to refuse to produce or receive the goods, and demand the party who alone changes or modifies the contract to compensate for all losses.
Article 11 A, B, either party due to force majeure, can not perform the contract, should promptly notify the other party can not perform or must be postponed, part of the reasons for the performance of the contract. After obtaining the certification of the competent authorities of the other party, this contract may not be performed or postponed or partially performed, and exempted from liability for breach of contract.
Article 12 In the event of disputes or disputes in the implementation of this contract, A and B shall consult to solve the problem, and in case of failure to solve the problem, any one of the parties may apply for mediation and arbitration to the state contract management organization. If a party is not satisfied with the arbitration, it can sue to the People's Court within 15 days after receiving the arbitration.
Article 13 This contract shall come into effect on the date of signing by both parties, and shall be canceled after Party B sends all the orders to Party A for acceptance and settlement of the payment according to the provisions of this contract.
Article 14 During the implementation of this contract, if there are any unfinished matters, may be negotiated by Party A and Party B, another bylaw attached to this contract, all the bylaws in the law and this contract have the same effect.
Article 15 This contract **** ___ copies in one form, by A, B, each of the original, ___ copies, and reported to the competent authorities of both parties each one.
Party A (official seal): _________ Party B (official seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ _________ ____ ____ _________ ____ Day
wire and cable supply contract IVParty A (supplier):
Party B (purchaser):
The subject matter of the name, specifications, quantity, price and delivery (pick-up) time:
First, the quality and acceptance standards: delivery and acceptance of the requirements of product standards. Implementation of national standards
Second, the quality assurance period: within one year of the product manufacturing quality of three packages. Delivery within half a year to raise objections.
Third, the supply and recovery of packaging: Party A free of packaging fees, after the use of cable packaging disk by Party B to keep it well, and notify Party A to take back.
Fourth, the delivery method, location: construction site
Fifth, the payment method: prepaid deposit of 50,000 yuan, a one-time payment at the time of pickup
Sixth, the conditions for the termination of the contract: no
Seventh, the special agreement: the two sides to negotiate the settlement of the outstanding issues.
VIII, the conclusion of this contract, both parties should present the business license or identity card, power of attorney, and the contract on the designated handler. This contract in duplicate, since the two sides signed and sealed to take effect.
Party A (official seal): _________ Party B (official seal): _________
Legal representative (signature): _________ Legal representative (signature): _________
_________ year ____ month ____ day _________ year ____ month ____ Day
Wire and cable supply contract fiveParty A (demand):
Party B (supply):
Based on the "Chinese People's *** and the State Contract Law", "Chinese People's *** and the State Construction Law" and other relevant laws, in order to clarify the rights and obligations of Party A, Party B, follow the principle of voluntariness, equality, fairness and honesty and trustworthiness, A and B, after friendly consultation. Sign this contract, *** with the trust and strict performance of the following contract terms:
I. Subject matter and price of the contract
1.1 The quantity of this contract, except for special agreement, are provisional, the settlement is based on the actual signing of the qualified quantity, Party B shall not sue Party A or claim against Party A on the basis of the discrepancy between the contracted quantity and the actual amount of the signing of the contract. If the actual amount exceeds the total amount of this contract, the two sides will sign a separate supplementary contract.
1.2 The price of this contract includes: packaging, transportation, loading and unloading, packaging and transportation (including loading and unloading) loss, assembly, acceptance, wages, wage subsidies for the supplier's personnel, medical insurance, pension insurance, unemployment insurance, work-related injuries, accidents, third-party liability and other kinds of insurance premiums, repair, maintenance, inspection and testing costs, replacement of unqualified products, financial fees, risk lump sum, taxes, as well as state and local government regulations to pay the taxes. and all kinds of fees that should be paid by the state and local governments.
1.3 The price of this contract is fixed unit price. Party B will not adjust it for any reason regardless of the rise or fall of the market price.
Second, the quality requirements of the subject matter
2.1 The quality must be in line with the national standards for wires and cables:
2.1.1 The standards for wires, twisted pairs, and sheathed wires: GB/T5023.1- 5- 2008 (BV-450/750V), GB/T5023.6-2006 GB/T5023.7-2008 (BV -450/750V), JB8734-1998, IEC227
2.1.2 Cable standards: GB/T5013-2008, JB8735-1998 (YC0.6/1KV)
GB/T12706-2008, IEC502-1994 (YJV0.6/1KV)
GB/T9330-2008, IEC227 (KVV450/750V)
2.1.3 Flame retardant and fire-resistant standards: GB/T12666-2008, GB/T19666-2005, IEC331
2.1.4 Low-smoke halogen-free cable standards: GB/T18380-2008, GB/T19216-2008, GB/T17651-98
GB/T17650-98, IEC6052
2.2 Product quantity standards: "Measures for Supervision and Administration of the Measurement of Quantitatively Packaged Commodities" and "Measurement and Inspection Rules for Quantitatively Packaged Commodities" issued by the General Administration of Quality Supervision, Inspection and Quarantine of the State in 2005.
2.3 Quality guarantee period: 2 years for each project since the completion and acceptance of the project or a longer period proposed by the demand side, if the quality guarantee period is greater than 2 years, the specific period shall be agreed by the two sides separately.
3. Delivery time, place and manner
3.1 Party B shall deliver the subject matter within the time specified by Party A. The delivery shall be made within the time specified by Party A. The delivery shall be made within the time specified by Party A.
3.2 Party A and Party B agreed to the following two ways of delivery of the first as the delivery of this contract:
(1) Party B will be the subject matter of Party A to the designated location;
(2) Party A to the designated location of Party B to pick up the subject matter of Party B is responsible for loading.
3.3 Party B shall provide the corresponding test reports, factory certificates of conformity and other quality documents of the batch of goods with each shipment, and ensure that the subject matter is produced by the agreed brands and manufacturers in this contract.
3.4 A and B each agreed to the following contact person for the contract related visas, signing formalities for the confirmation of the person, beyond the following agreed person, is considered invalid:
Party A on-site contact person: Tel:
Party B on-site contact person: Tel:
Fourth, the subject matter of the transfer of risk
4.1 Regardless of the place of delivery of the goods as well as the transport Regardless of the place of delivery of the goods and the responsibility of transportation, after the goods are transported to Party A's construction site and unloaded to Party A's designated place, the risk responsibility of the subject matter will be transferred to Party A.
5.
V. Acceptance of the Subject Matter
5.1 When the Subject Matter is delivered, it shall be accepted on site by the material acceptance personnel designated by Party A and the quantity shall be signed.
5.2 Acceptance in accordance with the quality requirements of the subject matter of the contract as stipulated in Clause 2 of the Contract, Party A shall have the right to refuse to accept the wires and cables if the quantity and quality of the wires and cables fail to meet the requirements.
5.3 If the parties disagree on the quality of wire and cable, it should be inspected by the inspection organization with inspection qualification. If the inspection quality is unqualified, Party B shall bear the inspection costs and bear all the losses caused by this to Party A (including the loss of time), such as the inspection quality is qualified, Party A shall bear the inspection costs.
5.4 If Party B fails to provide the documents mentioned in Clause 3.3 of this contract, Party A has the right to refuse to accept the goods, and Party B shall bear the losses caused.
6. Settlement Method and Period
6.1 Settlement shall be made in the following manner.
6.1.1 Mode 1: one-time settlement
After the goods are qualified and handed over to Party A for use, Party B will apply for settlement with Party A and Party B with the valid documents signed by Party A and Party B (including the confirmed delivery list), and full tax-paid invoice of the applied settlement price.
6.1.2 Mode 2: purchase goods in batches and settle in installments
Settlement shall be made on a monthly basis, and the day of each month shall be the month-end date for settling the payment for the goods received from the previous month to the day of the current month. Before the end of each month, Party B will apply to Party A for settlement and payment with the valid documents confirmed by Party A and Party B, the agreed settlement price and settlement amount, and the full tax-paid invoices of the delivered and unsettled goods within the settlement timeframe.
6.2 Payment ratio and period (the progress and proportion of payment in principle with the progress and proportion of the lump sum contract of the contractor to pay the Party A, but the proportion of payment before the completion of the settlement between the contractor and the Party A does not exceed the total amount of the contract
70%; the form of payment consists of bank transfers and promissory notes, of which the proportion of the payment of the promissory notes in principle, for the contract amount of 40% -50%). 50%).
VII. Liability for breach of contract
7.1 A and B, either party does not fulfill the contractual obligations or the performance of contractual obligations do not meet the agreement, causing losses to the other party, the defaulting party shall compensate for the losses caused by the breach of contract, including direct losses and indirect losses.
7.2 Party B shall not assign the rights under the Contract to a third party in whole or in part without Party A's written consent. If Party B violates this agreement, it shall be regarded as Party B's breach of contract, and Party B shall bear all the losses thus caused to Party A and 10% of the total contract price.
7.3 Party B must provide the goods agreed in the contract in accordance with national standards to meet the construction requirements of Party A. If Party B is found to be in breach of contract in the process of supplying the goods, Party B shall bear all the losses caused to Party A and the liquidated damages of 5% of the total contract price.
7.4 When Party B has a dispute with a third party, so that the third party applies to the court to take property preservation measures or mandatory enforcement, resulting in the court's account number or other property of Party A for the seizure, freezing, transfer, seizure, auction, discount, execution and other mandatory measures, Party B must be in the court issued a ruling or notice of assistance in the implementation of the date of the letter of determination or notice of assistance in the implementation of the letter of 20% of the amount of liquidated damages and liabilities to Party A. Party B must pay Party A 20% of the amount determined in the ruling or notice of assistance in execution and bear all the losses. Meanwhile, Party A has the right to unilaterally terminate the contract if the above situation occurs, and Party B will bear all the consequences.
7.5 Force majeure, Party B shall notify Party A in writing or by fax within 3 days from the date of occurrence of force majeure, so that Party A can make adjustments; if Party B fails to supply in time and cause losses to Party A, Party A shall be compensated for the corresponding economic losses, and Party A has the right to terminate the contract.
7.6 When Party B has a dispute with a third party, if Party B causes the third party to apply to the court for property preservation measures or compulsory execution, resulting in the court's seizure, freezing, allocation, seizure, auction, depreciation, execution and other compulsory measures on Party A's account number or other property, Party B must pay Party A 20% of the amount determined in the ruling or notice of assistance in execution to Party A on the date of the court's issuance. Notice of the amount determined in 20% of the liquidated damages and bear all the losses of Party A, at the same time, Party A has the right to unilaterally terminate the contract, and all the consequences shall be borne by Party B itself.
VIII. Disclaimer
8.1 Party B will take the subject matter to Party A designated location for delivery, in the subject matter of transportation, loading and unloading process and transport vehicles in the location designated by Party A occurred in any of Party B's transport vehicles, staff, third-party personal property, security accidents, Party A does not assume any responsibility.
8.2 Take Party A to Party B's designated location to extract the subject matter, Party B shall protect Party A's transportation vehicles, staff safety.
IX. Settlement of Contractual Disputes
9.1 Any disputes arising out of or in connection with this contract shall be resolved through consultation between the two parties. If consultation fails, litigation shall be brought to the People's Court of Party A's domicile.
9.2 During the dispute resolution period, if the dispute does not affect the fulfillment of other terms of this Agreement, such other terms shall continue to be fulfilled.
9.3 Any forbearance or delay in exercising the rights under this Agreement by Party A to Party B shall not affect any of its rights under this Agreement and the laws and regulations, and shall not be regarded as a waiver of such rights or an exemption from such obligations or liabilities.
X. Other Agreements
10.1 Party B shall provide Party A with a copy of business license, tax registration certificate, institutional code certificate, a copy of general taxpayer's certificate, a letter of authorization and other supporting documents before the contract is signed, and stamped with official seal.
10.2 Party B shall issue true and valid invoices according to Party A's requirements, and Party A shall make payment after confirming that the invoices are correct. If Party B is found to have provided false invoices, Party B shall pay liquidated damages and replace valid invoices with no compensation to Party A. In case of refusal or overdue replacement of the invoices, Party A shall have the right to terminate the contract and refuse to pay or delay the payment of the subsequent payments.
10.3 Party B must obey the command and dispatch of Party A's management personnel and vehicles at Party A's site, and comply with Party A's and the contract-related parties' safety management regulations and related systems, or else it shall be liable for breach of contract in accordance with Party A's internal management system, and Party B shall independently bear the damages caused by Party B, and Party A shall have the right to deduct them from the warranty deposit and/or payment for the goods.
10.4 If Party A and Party B have any dispute over the understanding of the terms of the contract, the true meaning of the terms shall be determined in accordance with the words and phrases used in the contract, the relevant terms of the contract, the purpose of the contract, the trading habits and the principle of good faith.
10.5 If there is any update of the national standards mentioned in Article 2.1 of the Contract, the updated national standards shall prevail.
10.6 This Contract shall come into effect upon signature and sealing by both parties, and shall terminate on the day of January.
10.7 This contract is in one copy, Party A executes one copy, Party B executes one copy, with the same legal effect. (The number of copies of the contract held by Party A shall meet the needs of legal compliance, finance, equipment and materials, and other departments of the record management)
Party A (Official Seal): _________ Party B (Official Seal): _________
Legal Representative (Signature): _________ Legal Representative (Signature): _________
_________ ____ ____ ____ _________ ____ ____
I carefully recommend