Earthwork is a construction process that includes excavation, transportation and filling of earth, so how to write a contract for earthwork? General attention to what? If you do not know, the following is my earthwork contracting contract for you to organize the sample, thank you for your appreciation.
Earthwork Contract 1
Party A:
Party B:
According to the laws and regulations of the state and the "Regulations on Contracting for Construction and Installation Works" principle, Party A according to the needs of the construction of the earth will be excavated and transported to the designated bit of the project is contracted to the construction of Party B, by the negotiation between Party A and Party B signed this Agreement. By the A and B signed this contract, *** with the same compliance.
Article 1: Contracting project, content and duration:
Excavation and earth transportation according to the scope and requirements provided by Party A, including the content: (1) Excavation projects include. (2) Including in the excavation and transportation process of scattering soil, etc., by the relevant units of the fine costs Party B at their own expense. (3)The obstacles in the excavation process are cleaned up by party B.
Article 2: Contracting method: one-time lump sum (including mechanical entry and exit fees).
Article 3: Duration: from the beginning of the excavation to the end of the month of January. Party B must try to complete part of the earth outward transportation according to the determined construction period, or each delayed one day fine of 1000 yuan, by the qinjiang township government for supervision and evaluation.
Article IV: Settlement and payment:
31, the contract unit price: according to the actual excavation and transportation of earth to the designated bit yuan / m settlement (including machinery into the field fee), earth measurement according to the construction machinery to fill the compaction of the A and B parties on-site measurements, calculations to confirm (fill the height of compaction and the height of the existing ground higher than 3.14 meters).
2, Party B according to the actual completion of the earth contracting workload by the construction workers issued by the task list, signed by the management review, the project manager for approval after the approval of the engineering company audit can take effect, the signatures are not full settlement is invalid.
3, settlement: Party B to pay the total cost of the project to the Party A before 10% of the project performance bond to enter the field to start, 30% of the total amount of work completed to return 10% of the project performance bond to complete 60% of the total amount of 40% of the project, the project is completed within one month from the date of acceptance of the completion of the work to pay the 90% of the total amount of work, the balance of the project acceptance of the date of payment within six months.
Article V: Project Quality:
Party B must strictly in accordance with the current building construction acceptance norms promulgated by the state and design requirements for construction. And do a good job of self-inspection, mutual inspection, handover inspection, to ensure the quality of the project, if Party B is not in accordance with the construction program and technical instructions for the construction work caused by quality accidents, or due to improper operation, violation of operating procedures and affect the quality of the project and all the economic losses are self-consuming. Where Party B contracted the project, maintenance and warranty costs, and no longer pay separately.
Article 6: Safety Management:
1, Party B in the construction to establish and improve the production safety responsibility system and safety management organizations and assurance system, the contractor is the first person responsible for Party B's production safety, the production safety is responsible for the overall.
2, Party B in the construction period, to be combined with the actual preparation of the project special safety construction program, to clarify the responsibility of production safety management, to take safety measures, and designate a full-time safety management personnel, the list of safety officers reported to the Party. Contracted safety production and civilized construction of regular supervision, inspection and coordination, and timely elimination of hidden accidents.
3, Party B in the construction must comply with national safety laws, regulations and industry safety technical specifications, standards, sound "production safety system", in the construction in strict accordance with the "safety and technical operating procedures" and safety and technical measures, special safety construction program to operate, and to do a good job of the workers entry safety education and division of safety and technical briefings and team safety activities. The implementation of various protective measures, in the case of conflict between safety and production, the first to meet the needs of safe production.
4, adhere to the policy of safety first, prevention first, do a good job of controlling the sources of danger, and according to the provisions of the equipment and the correct use of safety supplies. The personal protective equipment is purchased by Party B itself.
5, in the construction process of non-Party A reasons for all personal, mechanical, traffic accidents occur by Party B bear all the responsibility and economic losses.
6, during the construction period due to illegal operation, illegal command, violation of labor discipline and improper use of safety equipment caused by injury, disability and death according to the relevant provisions of the immediate report to the competent authorities of the enterprise, Party A is obliged to assist in rescue and actively cooperate with the government and relevant departments to do a good job in the investigation of the accident. Required medical expenses, living expenses, subsidies and pensions and other economic costs and losses are borne by the party responsible for the accident, causing major accidents constitute a crime in accordance with the relevant laws and regulations to pursue legal responsibility.
Article 7: the rights and obligations of Party A:
(a), the right:
1, according to the Ministry of norms and standards, the progress of Party B's construction projects, quality, safety, civilized construction, on-site management, supervision and inspection. If Party B mismanagement, resulting in delayed contracted projects, poor quality or Party B risky operations against the rules of command, Party A shall oblige Party B to rectify the situation, if Party B does not comply with the supervision and direction of Party A management personnel, Party A has the right to pursue the Party B's responsibility, Party B shall bear all the economic losses caused by this.
2, according to the relevant state laws, regulations and business regulations, Party B in the construction of violations of discipline, Party A has the right to be punished or terminate the contract.
3, in the contract period, Party A if found that Party B workers have stolen construction facilities and materials, according to take a fine of 100 doubled the heavy penalty processing, fines deducted from the settlement of Party B, constituting a criminal transfer to the public security organs to investigate criminal responsibility.
(B) obligations:
1, for Party B to provide and create construction conditions.
2, to assist Party B to solve specific problems arising in the construction in a timely manner.
Article 8: Party B's duties, rights and obligations:
(a), duties:
1, fully responsible for the contract within the scope of the sub-contracted construction projects in the whole process of technology, quality, safety, civilized construction management.
2, the establishment of a sound production safety responsibility system and safety management organization, the contractor is solely responsible for the contracting team's production safety management.
3, the development of safety management system, precautionary measures and emergency measures, adhere to the people-oriented, safety training and education of employees and special operations licensed to work.
4, equipped with full-time production safety supervision and inspection personnel, responsible for the contracting team's safety production and civilized construction management and supervision and inspection.
5, the frequency of safety accidents is controlled within 2 ‰, to put an end to serious injuries and fatal accidents.
(ii) rights:
1, the right to refuse to unauthorized command, forced risky operations.
2. The right to raise the behavior that endangers life safety and personal health.
(C) Obligations:
1, before the contract is signed Party B should take the initiative to business license, business qualifications and valid documents to Party A approved, the copy will be left to Party A for storage and inspection.
2, in strict accordance with safety regulations, standardized construction, in the subcontracting construction process, care for safety facilities shall not be arbitrarily dismantled to move safety protection facilities and safety signs. May not use child labor, the disabled, special operations can not be used more than 50 years old workers.
3, the full implementation of the content of the contract, subject to the leadership of the Party, listen to the Party's command, and seriously implement the Party's construction site management system and unified arrangements to achieve safe production, civilized construction, quality and quantity of the completion of sub-contracts in the completion of the construction tasks of the contract.
Article 9: Other:
1, this contract in quadruplicate, Party A three, Party B one.
2, this contract is not exhaustive, the two sides in a timely manner to sign a supplemental contract, supplemental contract and this contract is equally valid.
Party A:
Party B:
Representative:
Month and year:
Earthwork Contract 2
Offeror:
Contractor:
According to the provisions of the "Chinese People's Republic of China*** and the State of the contract law" and relevant laws and regulations, etc.
First, the project overview
(a) Project name: Nanchong City, Jialing District, the total true mountain Guanyin Temple expansion of earth and stone works.
(b) Project Location: Nanchong City, Jialing District, General Zhenshan Guanyin Temple
(c) Project Content: earth excavation and transportation backfill.
(D) the amount of work: the total volume of excavation about 40,000 cubic meters.
Second, the duration
Start date: the construction period from January to January
Party B has fully considered the construction period of the environmental impact, road conditions, vehicle transportation, management, construction inspection, policy changes, and the possibility of mass obstruction of the construction of the construction and other factors that can affect the progress of the project. Except for natural disasters and other force majeure factors, the construction period will not be adjusted for other factors. After the contract came into effect, Party B actively organize machinery into the field, within three days to start.
Third, the quality of the project
1, the quality of the project should reach the level of the national quality inspection and evaluation standards.
2, Party B according to the drawings and information provided by Party A to carry out construction, to ensure the quality of the project, project acceptance, should be measured according to the square amount of acceptance (GPS grid data settlement shall prevail).
Fourth, the project price and settlement
(a) Comprehensive unit price:
1, comprehensive unit price: 8.8 yuan / cubic meter, this project adopts the volume of excavation work as the basis for measurement of the comprehensive unit price lump sum, including earth and stone excavation, slag removal and transportation, loading fees, site formation, sanitation, and other related costs, the two sides shall not be subject to unauthorized changes in the contract price. (If there are other geographic geology that contains solid rock or lapis lazuli and other factors change, A and B negotiation to solve.)
2, this comprehensive unit price for the Party designated places to pour soil. (Such as beyond the designated scope of transportation, increase the cost of the project by the A and B negotiation to solve.)
3, this price includes the cost of price changes and policy price adjustment factors, according to the requirements of the contract period and the relevant work instructions and the cost of rush work.
(b) project settlement is handled in the following manner:
1, the amount of work under this contract is a tentative amount, to be determined by the actual construction of the amount of A and B *** with the determination of the remittance of the signatures and seals as the basis for the final settlement. If the drawings and instructions provided by the Party and the actual inconsistency, according to the actual visa or the actual amount of settlement.
2, Party B construction site before providing a list of site management personnel and construction organization plan to Party A, Party A agreed to construction.
3, Party B should be in accordance with the design drawings and specifications and Party A in accordance with the contract issued by the instructions of the construction, at any time to accept Party A's inspection and examination, the quality of the project does not meet the agreed standards should be unconditionally re-construction, the cost of which will be borne by the Party B itself.
(C) Settlement of the project price
The end of the project and accepted by Party A, Party A within three working days to pay Party B all the settlement of the project.
(d) The method of payment of the project price: bank transfer payment or cash.
V. Project Contracting Methods
(a) This project is a general construction contract. Party B shall not subcontract the contracted works to other construction units for construction. After the commencement of the project, if Party B is found to have failed to implement the contractual commitments, Party A has the right to terminate the contract, and Party B shall bear all the consequences arising therefrom.
(b) Party B shall, according to the contract, abandon the soil in the designated abandonment point, non-consent by Party A, the earth and stone shall not be transported out for any reason, otherwise, every time you find, Party B to Party A to pay 10 times the number of transported fines and not less than 5000 yuan.
VI. Responsibilities of both parties
(a) Party A's responsibility
1, to provide Party B with the construction site backfill range and elevation signs.
2, Party A sent representatives at the site for technical, quality supervision, inspection, for construction visas, acceptance procedures, etc., to solve the problems that should be solved by Party A;
3, due to Party A caused by Party B's construction machinery, transportation vehicles, work or stoppage, Party A shall be responsible for the mechanical stoppage of the bench fee and the corresponding actual losses. (Party A shall be responsible for the obstruction of work by farmers and relevant law enforcement departments due to the disadvantageous problems arising from the coordination.)
4, engineering changes: Party A shall notify Party B in writing 7 days in advance, and sign a supplementary contract or another construction visa. Otherwise, the economic losses caused by Party A and the corresponding delay in the construction period.
5, the completion of the project and after receiving a written application from Party B, Party A shall organize a special person within 3 days for acceptance, shall not be excused for any reason.
6, Party A has the right to request Party B to dismiss any member of Party B whose ability or behavior has been unable to perform the work related to this project.
7. Other work to be done by Party A as agreed by both parties.
(B) Party B's responsibility
1, to provide the necessary information and documents to enter the construction site, to prove its ability to undertake the project qualification of the relevant materials. And provide Party A with the project progress plan and the corresponding statistical reports and engineering accident reports.
2, obey the Party unified scheduling management, the implementation of the Party issued technical quality instructions, according to the Party approved design drawings, construction programs and the requirements of the contract to organize the construction, to ensure that the contract duration and quality requirements to complete the project undertaken.
3, safety construction
① Party B shall strictly implement safety regulations, the necessary safety education and safety technology to the personnel on site, to comply with the Party formulated rules and regulations on production safety.
② Party B should do a good job in the work area of the safety protection, to the site operation of the staff to provide adequate helmets, rubber shoes, safety belts, safety shoes and other safety and labor protection products, personal safety protection work of the operating personnel.
③ Responsible for the safety protection in the construction area, develop appropriate construction safety measures, bear the economic losses and responsibilities caused by their own safety protection measures are not effective. Party B must strictly in accordance with the construction safety regulations for construction, according to the provisions of the establishment of warning signs; Party B's own personnel safety by its own responsibility, Party B to pedestrians, passing vehicles and the surrounding masses caused by personal injury and death, property damage caused by Party B is responsible for dealing with all and bear the corresponding responsibilities and costs. Party B caused by the third party personal injury by Party B itself.
4, for the construction site underground pipelines, adjacent buildings, public **** public, landscaping facilities, Party B should take effective measures to protect, such as damage caused by Party B should be repaired in a timely manner, compensation. If Party B does not timely repair, compensation, Party A will be in accordance with the requirements of the other party to repair or compensation, the full amount of its costs deducted from the Party B works;
5, the completed project is not delivered to Party A before, Party B is responsible for the protection of finished products, the loss of Party B is responsible for the repairs at their own expense; Party B for their own machinery and equipment, materials and supplies, etc. should be to strengthen the management of the loss of or damage to the Party B is responsible for.
6.
6, civilized construction, to ensure that the construction site is clean and tidy. During the construction period must obey the municipal management, bear the losses and fines caused by violation of the relevant provisions.
7, all construction personnel must strictly abide by the relevant provisions of the construction site, and develop appropriate internal management measures, due to violation of the provisions of all the consequences occurring Party B is responsible.
8, Party B must work closely with the project management personnel, coordinated, such as Party B did not submit a timely application for material supply plan or due to improper stacking of materials occurred in the loss, loss, secondary handling and other costs borne by the Party.
9, involving the transportation of materials, labor and other local mass relations by the Party is responsible for coordination, and bear all the costs incurred.
VII, liability for breach of contract
(a) Party A default
Party A suspended the contract without cause does not fulfill the obligations of the contract or do not fulfill the obligations of the contract in accordance with the contract in other cases, Party A bear the responsibility for breach of contract, compensation for the breach of contract to the Party B caused by the economic losses, according to the amount of the total amount of 20% of the amount of compensation to the Party B, the delay in the period of delayed accordingly postponed.
(B) Party B default
1, due to Party B's reasons for the quality of the project does not meet the quality standards agreed in this contract, Party A has the right to require Party B to re-construct, such as Party B in the Party's specified period of re-construction is still unable to meet the quality standards agreed in the contract, Party A has the right to unilaterally terminate the contract, then the project has been completed is not to be settled, and the other Party B should be paid to the Party A of the total price of 20% of the project. Liquidated damages.
2, Party B does not fulfill the obligations of the contract or do not fulfill the obligations of the contract in other cases, Party B bear the responsibility for breach of contract, compensation for the economic losses caused by its default to Party A, and pay to Party A 5% of the total price of the project liquidated damages. After Party A reminds, Party B still does not fulfill the contractual obligations or not according to the contract to perform their obligations, then Party A has the right to unilaterally terminate the contract, the completed project will not be settled, and Party B shall pay Party A 5% of the total price of the project liquidated damages.
3, one party default, the other party requires the defaulting party to continue to perform the contract, the defaulting party to assume the responsibility for the above default, should still continue to perform the contract;
4, termination of the project: Party B due to non-force majeure factors for more than 5 consecutive days of stoppage of work, deemed to be the termination of the project, the Party A according to the actual acceptance of the project price calculation of qualified works, deducted from the price of the qualified works 5% as a penalty, and terminate the contract. Any loss caused by this to Party A shall be borne by Party B.
6, Party B must arrange for specific personnel to be stationed at the site responsible for the construction, 3 consecutive days are not at the site or not for the project, a daily fine of 1000 yuan.
Eight, contract disputes
All disputes arising from the fulfillment of this contract, without prejudice to the normal conduct of the project, by Party A and Party B to negotiate a solution. When the two sides fail to negotiate, the two sides agreed to take the following ways to solve the problem step by step.
1, mediation;
2, according to the law to the People's Court of Nanchong City Jialing District.
IX. Other matters
(a) This contract shall enter into force upon signature and seal of both parties, and shall expire on its own after the fulfillment of the obligations of both parties to the contract.
(b) If there are any outstanding issues in this contract, both parties may sign a separate supplementary agreement according to the specific circumstances.
(C) This contract is in four copies, all have the same legal effect, Party A executes two copies, Party B executes two copies.
Party A (seal) Party B (seal)
Legal representative (signature) Legal representative (signature)
Date of signing of the contract: Month of the year
Place of signing of the contract:
Earthwork Contract 3
Party A (Contracting Party):
Party B 1(Contractor):
Party 2(Contractor):
A and B, in the spirit of equality, voluntariness and the principle of honesty and credit, in accordance with the "Contract Law of the People's Republic of China*** and the State of China", the "Regulations on Contracting for Construction and Installation Works" and other laws, regulations and the relevant provisions of the Ningxia Hui Autonomous Region, in order to specify the rights and obligations of the two sides, agreed by consensus between the two sides, to sign the present contract and Strictly fulfill.
Article I. Scope of Contracted Works
(a) Project name: demolition and removal, earth excavation and backfilling works.
(2) Project location: .
(3) Scope and content of the project: demolition and removal of all above-ground attachments and earth excavation, transportation, backfill.
(D) all the contract cost of the project:
1, all the above ground attachments of this project (including the two buildings and all the surrounding bungalows and all the attachments, piles, etc. in other sites), the volume of demolition and removal of about 8,000 square meters, the demolition and removal of the lump-sum contract price of $ 80,000.
2, the project earth excavation unit price per cubic meter 11 yuan, the final party confirmed the actual excavation work volume to calculate the total price.
3. The unit price of earth backfill of this project is RMB 11 yuan per cubic meter, and the total price will be calculated based on the actual backfill quantity confirmed by Party A.
4, the above 1 ~ 3 terms of the project price for a one-time lump-sum price (including the demolition of ground attachments, clearing construction waste, garbage, excavation, backfill, transportation, the cost of piles and urban management, municipal, environmental protection, sanitation, demolition and relocation of permits and other related departments need to go through the formalities of the cost, while the price includes machinery, fuel costs, garbage resettlement fees and other costs), no longer count any costs.
Article II Project Period
Start and completion date: the above three projects start time decided by the director of Party A, Party A sends a list and drawings handed over to Party B, Party B should be strictly in accordance with the requirements of the Party A completed on time.
Article 3 Responsibility of both parties
(a) Party A's responsibility:
(1) Party A ensures that the construction site has the legal right to use.
(2) Organization and validation of the construction design or program, for the intermediate handover project acceptance procedures, responsible for visas, the quality of the progress of the project to supervise the organization of the completion of the acceptance.
(3) Payment of the project according to the contract.
(2) Party B's responsibility:
(1) Party B shall not subcontract the project.
(2) Strictly in accordance with the reviewed construction drawings, construction specifications and operating procedures for the construction, to ensure the quality of the project, to ensure the progress of the project, according to the Party A dispatch order within the specified time to complete. The plane position, bottom dimension, slope gradient, elevation and holding layer of the base pit shall conform to the requirements of the design drawings, and the deviation shall be controlled within the permissible range of the construction specification. Party B must actively assist with the general contractor, mechanical excavation from the design of the base first reserved mm thick soil, this mm thick soil by the construction of the general contractor to send people to cooperate, people digging machine transportation, prohibit over-excavation.
(3) to ensure compliance with site rules and regulations and the provisions of the party related to civilized construction, to comply with the command of the site management personnel and the supervision and management of the relevant departments at higher levels. Construction site cleanliness in line with the relevant provisions of environmental health management, to ensure that the construction road is smooth.
(4) Organize safe and civilized construction, all work-related safety accidents and safety accidents caused by Party B to other units and personnel during the construction shall be the responsibility of Party B itself. Before the commencement of construction, Party B shall do a good job of educating the staff of the unit on safety ideas and safety precautions, and shall not enter the construction site without safety education, and shall make a good record of handing over. When entering the construction site, you must do a good job of safe and civilized construction work. Take the necessary safety measures to eliminate potential accidents.
Party B should comply with the relevant management regulations of engineering construction safety production and the relevant safety management system, and should strengthen the safety education of operators to improve safety awareness. Implementation of safety construction rules, construction
personnel must have the appropriate qualifications, the construction site must have the conditions of safe production, should be in accordance with the requirements of mechanical operation of the construction. Strictly in accordance with the earthwork construction technical operating procedures in the safety precautions and safety standards organization for construction, and at any time to accept the industry safety inspectors in accordance with the law to implement the supervision and inspection. Any uncivilized construction behavior (including barbaric construction, disobedience to Party A's project management requirements, open defecation, etc.) in the construction of the project is regarded as a breach of contract, and a liquidated damages of RMB 2,000 yuan will be delivered to Party A for each occurrence, and Party A shall have the right to recover the damages until the termination of the contract if it results in the delay of the construction period or the economic loss. Liquidated damages and penalties can be deducted from Party B's project payment.
Party B should notify Party A in time if it adjusts personnel. Due to Party B's inadequate safety measures, unauthorized operation caused by mechanical damage or casualty accidents and the related responsibility and costs incurred as a result, Party B shall bear the responsibility, and Party A shall not bear any responsibility.
(4) Provide Party A with the notice of commencement of work in a timely manner, and prepare the construction organization design or program, construction schedule, construction layout plan, engineering statistical reports and engineering accident reports.
(6) Demolition and removal of construction waste and excavation of the earth by Party B transfer and find their own dumping sites (construction site is now piling up the earth, gravel, garbage by the obligation of Party B to transport away, do not calculate the amount of work), due to dumping of garbage, earth costs incurred by Party B, the cost has been included in the unit price of the contract, not calculated separately. If the project needs to use earth, Party B shall pile up the earth to the designated place according to Party A's requirements.
(7) Party B found in the construction process of underground water or buried pipes, cable lines, etc. should promptly notify the person in charge of the site Party A and take appropriate measures. If encountered building foundations and other obstacles can not be dug and transportation should be promptly notified to the person in charge of the site A party.
(8) Party B after digging the earth must be designed, construction (supervision), quality supervision station and Party A check to meet the requirements for qualified; otherwise, they should bear the cost of repair, rework.
(9) Party B found in the construction of cultural relics, monuments, etc. should be immediately reported to the Party.
(11) If a third party (e.g. the demolished person) blocks or hinders the construction during the construction process, Party B will be responsible for handling the matter and bear the cost, and Party A will not bear any cost for this.
Article 4 Project price, pre-settlement and settlement
(a) Party B will hand over the completion settlement documents to Party A for review within days after the acceptance of the completion of the project.
(2) Party A pays the project in full within days after the completion of the settlement.
Article 5 Construction and Design Changes
Party B must insist on construction according to the drawings. If any of the following circumstances cause rework, materials, components backlog, construction force and machinery relocation and other losses to Party A, Party B shall bear:
(a) For the production and use of the needs of the construction unit requires a change in the design, it must obtain the consent of the original design unit to issue a notice of design change, the two sides to handle the visa formalities before the change.
(b) in the construction of the design found to have errors or obvious unreasonable places, Party B shall notify Party A in writing, Party A within days and the original design unit agreed to propose modifications or changes in the design documents, by the two sides of the A and B visas, before allowing the construction.
(c) in the construction, such as design changes beyond the original design standards or scale and need to increase investment should be in the project before construction, according to the approval procedures for re-approval by both sides of the visa, before construction. Both sides before the visa, Party B shall not force construction without authorization.
(d) in the construction, such as the case of stopping midway, slow construction, A, B and the two sides of the project in progress, should be agreed to do a reasonable part. And put forward maintenance measures to minimize losses.
Article VI project quality, completion and acceptance and warranty
(a) Party B must be in accordance with the construction drawings and the technical requirements, specifications, regulations and organization of construction, the quality of the project to achieve: Party A acceptance.
(b) after the completion of hidden works: must be accepted, make a record, before the next process of construction, general hidden works, by Party B to check and make a good record of their own, major or complex hidden works, Party B days in advance to notify Party A in writing and the design unit **** with the acceptance, and for acceptance procedures.
(C) the completion of the project acceptance, the construction acceptance criteria promulgated by the state quality inspection standards and construction drawings, including instructions as the basis. Party B should be submitted to Party A days in advance of the completion of the report form, Party A received notice of acceptance within days of the organization, acceptance, sign the acceptance certificate and from the date of acceptance of the signature within days of the handover to the Party.
(d) In the project acceptance, such as found that the quality of the project does not comply with the provisions, Party B shall be responsible for free repair or rework, and in the measures and deadlines agreed upon by both parties to complete. After passing the acceptance, it will be handed over again. As a result of the late delivery of the project, Party B shall pay Party A two thousandths of the contract cost of liquidated damages per day.
(e) After the completion of the project, Party B shall draw as-built drawings. Changes in the project is not big, by Party B in the original construction drawings to explain, submit to Party A.
Article 7: Liability for breach of contract and dispute resolution
(a) Party B's responsibility for the completion of the contract is not in accordance with the content and date (calculated on the date of completion and acceptance), for each day of delay, shall pay Party A yuan / day (times) of liquidated damages. Party B shall withdraw all personnel and equipment from Party A's site within one day after the project is accepted by Party A (calculated on the date of completion and acceptance), otherwise, Party A has the right to clear Party B's personnel and equipment out of the site by itself. Party B shall pay Party A RMB/day (times) for each day of late withdrawal from Party A's site.
(b) Party A and Party B shall not default on all kinds of payables, such as delayed payment, should be paid to the other party in accordance with the relevant provisions of the liquidated damages of one ten-thousandth of a day.
(3) contract disputes, the two sides can be resolved through consultation or mediation. If the consultation or mediation fails, it shall be sued to the People's Court of Xingqing District, Yinchuan City.
Article VIII Supplementary Provisions
(a) The number of copies of the contract and the validity period:
(1) The contract is in six copies, A and B each party executes three copies.
(2) This contract shall take effect from the date of signature and seal of both parties; it shall be automatically terminated upon completion and acceptance of all the works and settlement of the final payment
.
(2) Supplementary provisions:
1, such as in the construction process of urban management, environmental protection, cityscape, traffic police and road administration and other management departments incurred costs are coordinated by Party B is responsible for Party A does not bear any costs.
2, such as the ground retained sand by Party B is responsible for the removal, not counted in the total amount of the project, Party A will no longer be paid separately.
3, Party A has organized the completion of the acceptance or process acceptance, can not be exempted from the quality of Party B's responsibility and compensation for Party A or the user's responsibility for loss.
4, in the performance of the contract, Party B fails to fulfill its obligations in accordance with the agreement of this contract, in the written notice of Party A within the specified date is still not fully performed, Party A has the right to terminate this contract.
Party A: Party B:
Legal Representative: Legal Representative:
Entrusted Agent: Entrusted Agent:
Year Month Day Year Month Day
Earthwork Contracting Contract Standard Model Related Articles :
★ Earthwork Contracting Contract Standard Version
< p> ★ Earthwork contract model★ Earthwork contract model
★ Detailed version of the earthwork contract book model
★ Earthwork contract agreement
★ Earthwork contract book model (2)
★ Simple earthwork contract model
★ The standard version of the Earthwork Contract
★ Sample Earthwork Contract Book