Power equipment installation contract
With the growing popularity of the concept of law, more and more scenes and occasions need to use the contract, signing the contract can be more effective constraints on the breach of contract. I believe that many friends are very distressed about the proposed contract, the following is a model contract for the installation of electrical equipment I organized for you, I hope to help you.
Electric power equipment installation contract 1
Party A:
Party B:
Party A due to the production (work) needs, approved by the labor department, the labor market introduction, agreed to recruit Party B as temporary workers, according to the relevant provisions of the relevant state and the relevant policies, the two sides agreed to voluntarily enter into this contract, and *** with the compliance with the following terms:
First, the contract period
from _________ _________ month _________ day to _________ _________ month _________ day. Of which the probationary period shall be for a period of _____ months from the _____ date of _____ to the _____ date of _____.
At the end of the contract period, this contract will be terminated by itself. If Party A needs to continue to retain, with the consent of Party B, the two sides can renew the contract and go through the hiring procedures.
Second, the production (work) tasks
Party A according to the production (work) needs, arrangements for Party B in the _________ position, to undertake _________ temporary production (work) tasks. If Party B agrees, it must obey. In the contract period Party A due to adjust the production (work) tasks, need to change Party B's position and tasks, subject to Party B's consent. If Party B does not agree, you can resign, the two sides for the termination of the contract procedures.
Three, labor time and labor compensation
(a) Labor time: Party A implements a weekly _________ day, a daily _________ hour work system. Strict control of overtime work, production (work) need overtime work, should control the daily overtime work does not exceed _________ hours, overtime work does not exceed _________ hours per month, overtime work should be notified to Party B in advance, agreed by Party B and Party A, according to the provisions of the overtime work fee.
(b) labor compensation: according to the relevant provisions of the state and the actual situation of the unit, according to Party B's position and undertake the task, Party A and Party B agreed to set the daily _________ yuan, monthly _________ yuan. Overtime pay, according to the standard not less than the state regulations. Bonus, according to the efficiency of the unit and labor contribution, regularly issued. If the piece-rate wage system is implemented, the monthly wages shall be settled according to the piece-rate unit price. The specific method is stipulated in the agreement column of the two parties to this contract. If you are engaged in night shift, you should be paid _________ for the night meal.
(3) During the contract period, if there is a stoppage of work and waiting for materials, Party A shall pay Party B the basic cost of living _________ yuan per day.
Fourth, labor protection, insurance and welfare treatment
(a) temporary workers recruited from the town, the implementation of social pension insurance system. The insurance payment method is the same as the unit labor contract workers. Payment of pension insurance premiums shall be borne by Party A _________ and Party B _________ per month. The amount of Party B's contribution shall be paid by Party A first and then deducted from his/her monthly salary. If Party B meets the recruitment conditions and the unit has the target, it can be recruited as a labor contract worker, and the pension insurance paid can be transferred together with it, and the years of contribution can be calculated together.
(b) Party B's treatment of work-related deaths and work-related injuries during the medical period is the same as the contract workers, work-related injuries and medical treatment is completed, the Labor Appraisal Committee to determine the degree of disability.
(C) Party B's illness or non-work-related injury, the maximum medical period shall not exceed _________ months. The treatment during the medical period shall be the same as that of contract workers. During the period of injury and sick leave, Party A shall issue living allowance at its discretion. Party B works in Party A for more than half a year, the medical period has not yet healed by the termination of the labor contract, by the enterprise to issue a one-time medical subsidy _________ yuan, Party B died, Party A shall issue funeral subsidy _________ yuan, a one-time issue of relief for dependent immediate family members _________ yuan.
(d) Party B works in Party A for more than one year, re-signing the contract, Party A shall arrange for Party B to visit relatives in accordance with state regulations, and the vacation for each year of service shall be _________ days. In case of marriage, bereavement, pregnancy, childbirth and breastfeeding of female workers, Party A shall arrange the vacation according to the regulations. The above leave is paid leave, beyond the specified date, approved by the treatment of personal leave.
(e) According to the needs of the work position, and with reference to the relevant state regulations, Party A issued Party B labor protection supplies. Engaged in lifting, welding, furnace and other special types of work, need to hold the relevant departments issued by the "professional post operation certificate" before going to work.
V. Labor discipline
(a) on time to and from work, shall not be late and leave early.
(b) Strictly abide by the operating procedures to ensure production.
(3) love unit property, not to damage public property without reason.
(D) work work (production) time shall not do personal business, shall not do things unrelated to production work.
(e) Listen to the command, obey the mobilization.
(F) quality and quantity to complete the task, no speculation.
(VII) something in time to ask for instructions, do not take the initiative.
Six, the labor contract changes, termination, termination and resignation
(a) Party A due to the change of production, adjust the production project or due to changes in the situation, with the consent of Party B, you can change the relevant content of the contract.
(b) The contract period is terminated upon expiration of the implementation, and the termination of the contract procedures. If the production (work) needs, Party A continue to recruit Party B, you need to agree with Party B, and approved by the labor department, the two sides to re-sign the contract.
(3) In one of the following cases, the labor contract can be terminated:
(1) Both parties agree.
(2) In accordance with the provisions of Article 6, paragraph 5 and Article 6, paragraph 6 of this contract.
(3) Party B's training (proficiency) period expires, does not meet the conditions of employment or Party B is not willing to contribute.
(4) Party B non-work-related injuries, the end of treatment is still unable to return to work.
(4) In any of the following cases, this contract will be canceled:
(1) Party A declares bankruptcy, or is on the verge of bankruptcy in the legal rectification period.
(2) Party B is removed from the expulsion, correctional labor or sentenced to imprisonment.
(E) Party B in the contract period of one of the following circumstances, Party A can be dismissed:
(1) a serious violation of labor discipline, affecting production and work order.
(2) violation of operating procedures, damage to equipment, tools, waste of raw materials, energy, resulting in economic losses.
(3) Poor service attitude, harming the interests of consumers.
(4) embezzlement, theft, gambling, malpractice and other offenses that do not yet constitute criminal liability.
(5) unreasonable, fighting, seriously affecting the social order or other serious mistakes.
(6) Party A has one of the following circumstances, Party B can resign:
(1) confirmed by the relevant state departments, the labor safety and health conditions are poor, no effective labor protection measures, serious damage to the health of workers.
(2) Party A does not pay wages according to the contract or does not pay wages for two consecutive months.
(3) Personality is insulted by the person in charge of the Party.
(4) Party A does not fulfill the labor contract, or violates the national labor laws and policies and infringes on the legitimate rights and interests of workers.
(5) Being recruited into the army with the approval of the state.
(7) Party A shall not terminate the contract if Party B has one of the following circumstances:
(1) The contract term is not yet expired and does not conform to one of the circumstances in item 3 of Article 6.
(2) suffering from occupational diseases and work-related injuries within the period of treatment failed to cure, belonging to all or most of the loss of labor capacity.
(3) Female workers during pregnancy, maternity leave, or breastfeeding.
(8) Party A or Party B requests to terminate the labor contract, except for the cases listed in Article 6 (4), the other party must be notified half a month in advance. And handle the relevant formalities.
VII, breach of contract
Party A violates the relevant provisions of the contract or without good reason within the contract period of the dismissal of Party B, according to the actual loss of Party B to be compensated for the specific amount of negotiation between the two sides.
Party B violates the terms of the contract to cause economic losses to Party A, Party A can be based on the actual loss of Party B to be compensated. Specific amount to be negotiated by both parties. Party B without the consent of Party A to leave the unit privately, compensation for Party A _________ yuan, or Party A will not go through the procedures for leaving the unit.
Eight, the two sides think need to agree on other matters
(a) Party B to provide housing, rent, water, electricity by Party B's own responsibility. Rent charged by the standard of commercial housing, Party A shall give Party B housing subsidies for _________ per month. If Party B solves the housing by itself, Party A shall give Party B housing subsidy of _________ yuan per month.
(b) Party A's own cafeteria, according to the cost of meals charged, do not run a cafeteria, outside the meal, the required management fee paid by Party A. Party A to Party B meal subsidies per month _________.
(c) Party A shall give Party B all kinds of subsidies***_________ yuan per month according to the state regulations.
(D) For piece-rate wage system, the monthly wage settlement: _________.
(e) Party B, whether in service or after leaving the company, must strictly abide by the company's commercial secrets, if any violation, Party A has the right to require Party B to bear all the economic losses and legal liabilities.
Either party violates the labor contract, causing economic loss to the other party, the other party has the right to pursue the breach of contract _________ and compensation _________ according to the responsibility and consequences caused.
IX. This contract shall come into effect upon signature by both parties, in _________ copies, with A and B each holding _________ copies.
Party A (seal):
Date of signing: ________
Party B (signature):
Date of signing: ________
Power Equipment Installation Contract 2Party A: ________
Party B: _________
I. Name of the project: _________
II. Location of the project: _________
III. Form of the contract: package work and materials
IV: _________
V. Project Cost
The budget price of the contract for this project is _________. Both sides from the date of formal signing of the agreement, Party A shall pay Party B a one-time payment of _________ yuan for the advance payment of the project according to the total cost of the project, and then pay the advance payment of _________ yuan for the project when proceeding with the commencement of the work. To be completed after the acceptance of the project according to the final account of the settlement of the project, the amount of more refund less compensation.
Six, the responsibility of both parties
1, before the construction, Party A is responsible for together with Party B, the design unit of the engineering construction drawings and engineering estimates for review, after review of the engineering construction drawings and engineering design estimates, as the only basis for the future construction and the preparation of the construction budget.
2, in the project before the commencement of work, Party A shall organize the relevant personnel, Party B to prepare the project construction drawings budget for review, after the review of the project construction drawings budget as the only basis for the completion of the project settlement.
3, Party B must be strictly in accordance with the construction drawings to ensure the quality of construction, Party A must facilitate the construction site, and a person responsible for the construction quality supervision and acceptance of hidden works.
4, Party B should review the design drawings of the design unit, the design problems occurring in the construction process should be Party B is responsible for.
5, construction equipment and materials from Party B's material warehouse to the site of the transportation costs have been included in the final account.
7, both sides - agreed to sign the contract of engineering commissioning Party A soil construction after acceptance _________ months to complete the project, such as the project delay, caused by stoppage of nesting and rework and other losses, by Party B is responsible for.
eight, safety and quality measures fee, 250kya and below for five hundred yuan, 315kva and above for one thousand yuan, 1000kva and above for _________ (capital) yuan. Transformer oleochemical test fee per _________ (upper case) yuan. Equipment transportation picking insurance fee according to industry regulations to the equipment cost of ` 1.5%, the design fee according to the provisions of the survey and design costs, transformer acceptance fee of 2 yuan / kva (compiled into the final account).
Nine, equipment and materials supply method, in order to project progress, the equipment and materials required for the project by Party A entrusted to Party B supply, engineering equipment and materials need to have a certificate of conformity (compiled into the final account).
X. five days before the completion of the project, Party B notified Party A acceptance, Party A received notice of the timely organization of the relevant personnel to participate in the acceptance without undue delay.
XI, the handling of disputes
1, this contract is subject to the jurisdiction of the People's Republic of China **** and the laws of the State and interpreted in accordance with them.
2, the contract in the course of performance of the dispute, by the parties to the negotiation to resolve, but also by the relevant departments of mediation; consultation or mediation fails, according to the following _________ way to resolve:
(1) submitted to _________ Arbitration Commission arbitration;
(2) according to the law to the people's court.
XII, this agreement in four copies, Party A executes one, Party B executes three, each with the same effect.
xiii, this agreement is effective from both sides of the signature day, after the completion of the settlement, and at the same time invalid.
Party A (signature): _________
Party B (signature): _________
_________
_____ ___ month ___
Where the agreement is signed:
Electrical Equipment Installation Contract 3Party A (contractor): _________
Party B (Contractor): _________
According to the "Chinese People's *** and National Code", "Chinese People's *** and State Construction Law" and "Regulations on Contracting of Construction and Installation Works" and the relevant provisions of the electric power construction and installation works, Party B is entrusted by Party A to undertake the whole process of contracting and construction of the power distribution project, in order to specify the rights, obligations and liabilities of the two parties, agreed by both sides to sign This contract.
I. Project name: ____
II. Project location: ____
III. Project unit: ____
IV: ____
V. Total Contract Price: ____
VI. Contracting Method:
VII. Payment and Settlement
VIII. Duration: It is agreed that the duration of the project shall be from the commencement of the work on XX/XX/20XX to the completion and acceptance of the work on ____ XX/XX/XXXX.
Nine, construction preparation
1. Party A:
(1) power distribution room civil construction is completed and accepted, ____ xx xx day before having to enter the field conditions of power supply and roads, etc., to meet the conditions of the construction of Party B into the field.
2. Party B:
(1) the preparation of the construction design or construction program, the construction of the overall progress plan, materials and equipment, such as field plan;
(2) the organization of the construction management personnel and materials, construction machinery into the field.
X. Project quality requirements
1. Project quality should be consistent with the Ministry of Water and Power, "Provisional Technical Specification for Construction and Acceptance of Electric Power Construction";
2. Project quality should be in line with the project design instructions and construction drawings.
XI, construction and design changes
1. The project design drawings, instructions and related technical information, and design briefings and review minutes, as a valid basis for construction, both sides shall not be modified without authorization.
2. If you want to change the design, it must be agreed by the original design unit and the relevant technical departments, both sides and the original design unit **** with a written visa to confirm before it takes effect.
3. Due to significant changes in design and other reasons for Party B stoppage, rework, nesting and other losses, Party A in the contract price outside the actual loss of Party B to be compensated.
4. Party A and Party B shall confirm the written notice of engineering changes within 5 days, otherwise, the written notice shall be deemed to have been confirmed.
XII, equipment and material supply: All equipment and materials required for the project will be supplied by Party B.
The project shall be completed by the end of the year.
XIII, safety responsibility
1. Party B shall, in the course of the construction of the project, strengthen the on-site safety education and take the necessary safety measures.
2. If Party B causes casualties and property damage during the construction of the project, the requirements, litigation costs, fees and expenses incurred by Party B shall be borne by Party A. Party A shall be responsible for providing assistance in the rescue.
3. If necessary, the two sides can sign a separate safety agreement.
XIV, project acceptance
1. Project acceptance of the completion of the Ministry of Water and Electricity, "Provisional Technical Specification for the Construction and Acceptance of Electric Power Construction," the relevant departments of the State Development of the completion of the acceptance of the provisions of the construction and construction drawings and specifications, construction of technical documents as the basis.
2. Sub-acceptance (including hidden works), Party B shall notify Party A 48 hours in advance to participate in, unless both parties have agreed, sub-acceptance shall begin at the expiration of the notice period.
3. Party A shall carry out the completion acceptance within 7 days after receiving the completion acceptance notice, otherwise, Party B will have the right to organize the completion acceptance, and its acceptance result shall be regarded as Party A has confirmed.
XV, quality warranty
1. Party B shall, in accordance with the relevant provisions of the state of the works delivered to the use of Party A in the quality of the warranty period bear the responsibility for warranty.
XVI, project management
1. This project Party A assigned to the project manager, as the representative at the site;
Party B assigned to the project manager, as the representative at the site.
2. Both sides of the project manager, site representative in the project signed by the memorandum of understanding, the contents of the project and equipment certificates and other documents are part of this contract.
XVII. Liability for breach of contract
1. Party A's liability for breach of contract:
(1) Failure to fulfill the responsibility in accordance with the provisions of Article 9 of this contract, in addition to the completion date can be postponed, should also be compensated for the actual losses caused by Party B.
(2) The project manager will be responsible for the completion of the project.
(2) Without acceptance of the project, Party A uses it in advance or without authorization, and Party A shall be responsible for any quality or other problems that may occur as a result.
(3) Failure to fulfill the obligations of payment and compensation in accordance with the provisions of Article 7 and Article 11 of this Contract shall result in reimbursement of liquidated damages at the rate of one ten-thousandth of one percent per day of the amount of liquidated damages.
2. Party B's liability for breach of contract:
(1) If the quality of the project does not conform to the provisions of this contract due to construction, it is responsible for repairing or reworking without compensation. As a result of repair or rework caused by the late or failed to complete the contract on schedule for one day late by two ten thousandths of the total contract price to pay liquidated damages.
(2) the end of the project can be completed on time according to the schedule specified in the contract, resulting in loss of Party A, in addition to the above provisions of the liquidated damages for late payment, should also be compensated for the actual losses caused by Party A.
We will not be responsible for the delay in the construction of the project, but we will not be able to pay for the delay.
18, the contract dispute resolution
The contract in the course of the performance of the dispute, the two sides to negotiate a solution. Consultation fails, either party may file a lawsuit to the local people's court.
nineteen, this contract by the representatives of the two sides signed, stamped with the official seal of the two sides or the contract special seal shall come into force. Project completion and acceptance, settlement of the contract price terminated.
XX, this contract in four copies, A and B each of the two copies.
Party A: ____
Party B: ____
20xx year xx month xx day
;