To put it simply, it means you are willing and I am willing, and then we fix the things that everyone agrees on, explain it clearly, and then the matter we agree on is an agreement, which is called a contract in law. . Below I bring you a universal version of the contract sample. To view more contract samples, click "Contract" to view.
Contract Sample Universal Version 1
Seller: (hereinafter referred to as Party A)
Buyer: (hereinafter referred to as Party A) Party B)
According to the "Contract Law of the People's Republic of China" and relevant legal provisions, Party A and Party B, on the basis of equality and voluntariness, and in order to clarify the rights and obligations of both parties, purchase Party A from Party B The signing of this contract for the house requires both parties to abide by and implement it:
Article 1
Party A shall have full rights to dispose of the house sold and ensure that it complies with relevant national regulations. , and there are no property rights disputes or creditor's rights and debt disputes.
Article 2
The location and area of ??the house:
1. The subject house mentioned in this contract refers to Jincheng, Haier Avenue, Zunyi City, Guizhou Province A certain number of houses on a certain floor of a certain unit in a certain building in the garden.
2. The construction area of ??the house is 154.03 square meters, of which the internal construction area is 136.65 square meters, and the shared construction area between the public and public buildings is 17.38 square meters.
3. The land use rights corresponding to the house under this contract will be transferred together with the house.
Article 3
Pricing method and price: The total transaction price of the house is: RMB 381,994 yuan (in capital letters: three hundred and eighty thousand one thousand nine hundred ninety four yuan) .
Article 4
Payment method and term: Party B shall pay Party A a down payment of 300,000 yuan within 2 months from the date of signing this agreement, and the remaining house payment will be 81,994 yuan. It should be paid in full before handling the transfer registration.
Article 5
Agreement on house delivery and property rights registration:
1. Party A shall submit the items of this contract within 30 days from the date of signing this contract. All the houses below will be delivered to Party B.
2. Since the property developer has not completed the application for the property ownership certificate of the house, Party A has not obtained the real estate ownership certificate (referring to the "House Ownership Certificate" or "Land Use Rights Certificate" of the house). After obtaining the real estate ownership certificate, Party A shall promptly assist Party B in registering and transferring the ownership of the house to Party B's name.
Article 6
Tax sharing agreement:
1. The taxes, property rights registration fees, and transaction procedures required by Party A to apply for the real estate ownership certificate All fees and taxes shall be borne by Party A.
2. All taxes and fees incurred by Party A in transferring real estate to Party B’s name, including transaction taxes, property rights registration fees, transaction fees, etc. shall be borne by Party B.
Article 7 Liability for breach of contract:
1. If Party B fails to pay according to the time stipulated in this contract, from the day after the expiration of the payment period stipulated in this contract to the actual full amount As of the date of payment of the payable, Party B shall pay Party A a penalty of three ten thousandths of the overdue payable on a daily basis.
2. If Party A fails to deliver the house within the time limit stipulated in this contract, from the day after the expiry of the delivery time limit stipulated in this contract to the date of actual delivery, Party A will have to pay Party B on a daily basis. Pay a penalty of three ten thousandths of the house price.
Article 8
Dispute resolution: Any dispute arising during the performance of this contract shall be resolved through negotiation by both parties; if the negotiation fails, the parties shall file a lawsuit in accordance with the law to the people's court at the place where the contract was signed. .
Article 9
Special agreement: After the transfer registration of the house, if compensation for house expropriation or demolition occurs, the house and the corresponding land will be owned by Party B.
Article 10
Conditions for exemption:
1. Party A and Party B are not responsible for each other’s liability for any losses caused by the inability to continue performance of this contract or due to force majeure. Liability for loss compensation;
2. Force majeure refers to “objective circumstances that are unforeseen, unavoidable and insurmountable”.
Article 11
Statement and commitment terms:
1. Party A promises: Party A has complete right to dispose of the house under this contract
p>
2. Party B promises: It is truly willing to purchase the house under this contract.
Article 12
This contract is signed in Dafang County, Guizhou Province. The contract is made in two copies. Party A and Party B each hold one copy. It has the same legal effect and takes effect upon signature by both parties. .
Article 13
For matters not covered in this contract, Party A and Party B may stipulate separately, and the supplementary agreement shall have the same legal effect as this contract when signed and sealed by both parties.
Seller (Party A):
Buyer (Party B):
Signing time: June 9, 20__
Contract sample universal version 2
Party A (employer)_____________________________
Party B (employee, staff))_______________
(Party A) employment_ _______ (Party B) is the business manager of _______. Both parties enter into this agreement and establish a labor relationship on the basis of equality, voluntariness and consensus through consultation, and agree to abide by and perform it.
1. Contract Period
1. Party A and Party B agree to start from _______ month _______ of ___________ year to _______ month ______ of ___________ year As of _ date, __________________ is hired as our company; the contract period is _________ years.
(2) Both parties agree that the first ____ months of the validity period of this agreement shall be the trial period.
2. Work content
1. Responsible for the promotion of the company's products and the implementation of the company's regional marketing plan.
2. Responsible for contacting and liaising with the company's sales and related business, and at the same time filing relevant customer information with the person in charge.
3. Collect, master and provide feedback on competitors’ marketing plans, product prices, market trends and other information to provide reference for the company’s business decisions.
4. Track and provide after-sales service, handle customer issues promptly and properly, collect and feedback customers’ opinions, suggestions and expectations on product sales, etc., to help the company improve its business strategy and service levels.
5. Obey Party A’s arrangements and complete the tasks assigned by Party A on time and with high quality and quantity.
3. Salary system
During the promotion period, the base salary and commission method are implemented, and during the non-promotion period, only the commission method is used.
1. Salary during the promotion period: basic salary____, and the salary standard after passing the probation period is: basic salary____________________.
2. Compensation during the non-promotion period: After completing the tasks during the promotion period, the non-promotion period is the date when the order is accepted. If the customer places an order and settles the payment, there will be a commission, which is calculated according to point 1.
3. Summarize the performance of each salesperson every quarter, and give certain rewards to businesses with good performance.
4. Party A will pay Party B’s salary regularly in cash every month; Party A’s salary payment day is the 15th of every month.
4. Working hours and travel expenses
1. Working hours:
1) 10-hour working day (including noon) (8:30-18 :30), Party B can also reasonably arrange working hours according to work needs, and Party A can ask Party B to return to the company to arrange work at any time if necessary. In principle, you must return to the company every week to attend the weekly meeting. If you are unable to attend due to special circumstances, you must ask for leave from the person in charge of the company one day in advance.
2) There are three days of rest per month, and any excess of three days will be deducted from the daily basic salary. Personal leave must be requested from the person in charge of the company one day in advance, otherwise it will be treated as absenteeism. If you do not need to travel during the non-promotion period, you will work normally in the company from 9:00 to 18:00, and be responsible for daily contact with customers and other work.
2. Travel expenses: The company is responsible for the promotion expenses of each salesperson, the fares are reported according to actual sales (the place visited and the results of the business trip must be indicated), and the meal expenses are 15 yuan/meal.
5. Agreement between the parties
1. Party B shall abide by the company rules and regulations formulated by Party A and obey Party A’s management and work arrangements. Party A has the right to supervise, inspect, assess, reward and punish Party B's implementation.
2. Party A is obliged to create corresponding conditions and support for Party B to carry out business work. Party B shall not engage in any activities in the name of the company that are not related to its own business. The company will not be responsible for any consequences arising therefrom. Any responsibility is entirely my own.
3. Before signing this contract, B must provide a copy of his ID card and family register and submit them to the company for archiving.
6. Change, rescission, termination and renewal of the labor contract
1. Party A requires changes due to changes in the objective circumstances on which the contract was signed, or Party B requires If you want to change the terms of this contract, you must notify the other party in writing seven days in advance. The relevant content of this contract can be changed after both parties reach an agreement. To change the labor contract, both parties should sign an "Additional Agreement".
2. Party A has the right to terminate the contract if it is verified that it has seriously neglected its duties, engaged in malpractice for personal gain or leaked business secrets, causing significant damage to the interests of the company.
3. Party A has the right to terminate the contract if Party B is not qualified for the job and has not brought any performance to the company for two consecutive months.
4. If Party A fails to pay labor remuneration or provide labor conditions as stipulated in this agreement, Party B has the right to terminate the contract.
Unless otherwise provided in this contract, either party must notify the other party 30 days in advance to terminate or terminate this contract. If the notice time is insufficient, the number of days preceding the termination or termination of the contract shall be equal to the difference. Party B's average daily work shall be used as the standard, and compensation shall be paid to the other party.
7. This contract is made in two copies. Each party holds one copy. It is legally binding and takes effect from the date of signing by both parties.
Party A (seal): ______________
Party B (signature and seal): ______________
___________year_______month_______day
____________year_______month_______day
Contract sample universal version 3
Client (Party A): ____________________
Undertaken by the Party (Party B): _______________
Project: ____________________________
After friendly negotiation and consultation between Party A and Party B, Party A decided to entrust Party B to decorate the front room. In order to ensure the smooth progress of the project, this contract is signed in accordance with the relevant national laws and regulations for mutual compliance.
Article 1. Project Overview
1. Project address: ____________________
2. Construction area ____________________ square meters
3 ,Construction content: ____________________
1). Remove the middle partition wall without affecting the original fire protection and the load-bearing columns and beams of the main structure.
2) Decorate the entire hall with suspended ceilings, wall skirts, floor tiles, wooden floors and decorative lines. Do not damage the original suspended ceiling.
3). Add _____ private rooms and decorate the hall.
4) Party B shall reasonably plan and decorate the kitchen according to Party A’s requirements.
5). The billboard and bar on the opposite facade need to be decorated according to A’s wishes.
6). Build a vegetable sink, fish pond, awning, etc. behind the kitchen.
7). Improve all water and electricity facilities in the store.
4. Project start date: _________year_______month_______day
5. Project completion date:_______year_______month_______day
p>
Total number of days for the project: ______ days
Article 2. Project price
The project price (amount in capital letters)_____________ yuan.
Article 3. Quality Requirements
Party B’s construction must be carried out in strict accordance with Party A’s requirements.
Article 4. Payment method
Full payment will be made after Party A has passed the inspection and acceptance upon completion of the project.
Article 5. Liability for breach of contract
1. Party B must complete the project within the time limit, otherwise Party A has the right to refuse to pay for the project and hold Party B accountable.
2. If Party B’s construction fails to meet quality requirements, Party A has the right to order Party B to take full responsibility.
Article 6. Changes to the Contract
After the contract is signed and takes effect by both parties, both parties must strictly abide by it. If either party needs to change the content of the contract, a new supplementary agreement must be signed after consensus reached by both parties.
Article 7. The contract takes effect
1. This contract shall be sealed by both parties and shall take effect after signature.
2. This contract is made in _______ copies, with Party A and Party B each holding _______ copies.
Party A (signature/seal): ____________________ Party B (signature/seal): ____________________
_______________year_________month_________day_______year_ _________month_____________
Contract Sample Universal Version 4
Party A: (hereinafter referred to as Party A)_____________ ID Number: __________________
Party B: (hereinafter referred to as Party B)_____________ ID number: __________________
In order to complete the project, Party A originally contracted the approximately square meters of the project to Party B. Both parties acted on the basis of equality, mutual benefit, consensus through consultation, and followed equality, This agreement is entered into based on the principles of voluntariness, fairness, good faith and the specific circumstances of this project.
1. Project name: ____________________________
2. Project address: ____________________________
3. Construction area: ____________ about m2
5 , Contracting method: labor and materials
6. Project cost: including taxes and fees __________yuan/m2
7. Contract duration: total number of days, to Calculated from the date of Party A’s notice of commencement of construction. Postponed due to force majeure.
8. Project nature: ____________________________.
9. The final settlement amount of both parties is based on the actual acceptance amount of Party A and Party B.
10. Party B is responsible for the pressure test work and costs of materials required for the project price, and Party A’s coordination and cooperation with the test data will be handed over to Party A for unified management.
11. Specific requirements during construction
1. Quality requirements: The quality of this project shall be based on the specific requirements of the country and the construction party, Party A, and the construction party shall accept it as the standard. The signature and seal of the supervision company and relevant functional departments shall prevail.
2. Safety Responsibility: During the construction process, Party B shall strictly carry out construction in accordance with the relevant national standards and safety technical operations, so as to achieve civilized construction, clean site, and complete and appropriate safety measures. Party B shall be solely responsible for all safety accidents that occur during the construction process and within the scope of its contract.
3. Estimation and payment method: The estimate is based on the actual work volume received by Party A and Party B on site. After the agreement is signed, Party B will advance the funds to enter the site and pay the project payment within 7 days after the completion of the construction foundation and acceptance. ______ ten thousand yuan. After the project is completed and accepted, Party A shall pay Party B _______ of the total project price within 10 days, and the remaining _______ project price shall be paid within the year after deducting the warranty deposit in accordance with national regulations.
4. Construction period requirements: Due to the tight construction period and heavy tasks of this project, Party B must strictly carry out the construction in accordance with Party A's construction progress requirements and shall not use any excuse to stop work or delay the construction period. If the above situation occurs, it will be a breach of contract. , Party B shall pay Party A the total cost of liquidated damages _______, and Party A has the right to terminate the agreement, and Party B shall be responsible for all losses.
12. When signing this agreement, Party B pays Party A a performance deposit of _______ million yuan. This deposit will be returned to Party B when Party A allocates project funds for the first time.
13. Liability for breach of contract: If one party breaches the contract, the breaching party shall compensate the other party for all losses caused.
14. Any unfinished matters shall be resolved through negotiation between Party A and Party B. This agreement is made in ______ copies, with Party A and Party B each holding ______ copies. The agreement shall be signed by both parties and shall become effective within the validity period. It will naturally expire after the project is completed and all project payments are settled.
Party A (signature/seal): ____________________ Party B (signature/seal): ____________________
_______________year_________month_________day_______year_ _________month________
Contract Sample Universal Version 5
Contractor (hereinafter referred to as Party A): _______ Contractor (hereinafter referred to as Party B): _______
Contact number: ____________________ Contact number: _______________
ID number: _______________ ID number: ____________________
In accordance with the "Contract Law of the People's Republic of China" and other relevant In accordance with the provisions of laws and regulations, combined with the characteristics of family room decoration and decoration in this city, Party A and Party B, on the basis of equality, voluntariness and consensus through consultation, will discuss matters related to Party B's contracting of Party A's family room decoration and decoration project (hereinafter referred to as the project). , reached the following agreement:
Article 1: Project Overview
1. Project location: _______________
2. Project decoration area: _________
3. Project house type: _______________
4. Project content and methods (see quotation and drawings);
5. Project contracting shall adopt the following _________ method ：
(1) Party B will contract the work and cover all the materials (see Attachment 3)
(2) Party B will contract the work and cover some materials, and Party A will provide the remaining materials (see Attachment 3) 2, 3)
6. The project period is _________ days (calculated based on actual working days);
The start date is _________year________month________day;
Completion date is _________year________month_________day.
7. Project payment and quotation
(1) Project payment: The project cost of this contract is (RMB) _________.
Amount in capital letters: ____________________________________.
(2) The quotation shall be based on the "Beijing Home Decoration Project Reference Price" and shall be agreed upon by both parties in accordance with the operating rules of the market economy and based on the principle of high quality and low price, and shall be included as an attachment to this contract.
(3) The quotation should be prepared in conjunction with the material quality standards and manufacturing and installation process support as the basis for determining the project price.
Article 2: Project Supervision
If this project is subject to project supervision, Party A shall sign a separate "Project Supervision Contract" with a project supervision company approved by the construction administrative department. and notify Party B of the name, unit, contact information of the supervision engineer and the responsibilities of the supervision engineer.
Article 3: Construction drawings and indoor environmental pollution control pre-evaluation calculation sheet
1. Construction drawings shall be provided in the following _____________ method:
(1) If Party A designs by itself, it must provide construction drawings and indoor environmental pollution control pre-evaluation calculation sheets in triplicate, with Party A holding one copy and Party B holding two copies.
(2) If Party A entrusts Party B with design, Party B must provide construction drawings and indoor environmental pollution control pre-evaluation calculation sheets in triplicate, with Party A holding one copy and Party B holding two copies.
2. The construction drawings and indoor environmental pollution control pre-evaluation calculation sheets provided by both parties must comply with the requirements of the "Code for Indoor Environmental Pollution Control of Civil Construction Projects".
3. Both parties should sign and confirm the construction drawings and indoor environmental pollution control pre-evaluation calculation sheet.
4. Both parties shall not copy or transfer the construction drawings, design plans and other materials provided by the other party to a third party without authorization, nor shall they be used for projects other than this contract.
Article 4: Party A’s work
1. Three days before the start of construction, conditions must be created for Party B to enter the construction, so as to not affect the construction.
2. Water, power and winter heating during the construction period will be provided free of charge.
3. Responsible for handling the start-up procedures of the property management department and related fees that should be paid by the owner.
4. Comply with the rules and regulations of the property management department.
5. Responsible for coordinating the relationship between Party B’s construction personnel and neighbors.
6. The following behaviors are not allowed:
(1) Modifying the main body and load-bearing structure of the house at will.
(2) Open windows and doors on the exterior wall or expand the size of the original doors and windows, and remove the wall connecting the balcony doors and windows.
(3) Pave more than one centimeter of stone indoors, build walls, and increase floor load.
(4) Destroy the waterproof layer on the kitchen and toilet floors and dismantle and modify heating, heating, gas and other pipeline facilities.
(5) Other acts of forcing Party B to perform illegal construction work.
7. If the content listed in paragraph 6 must be involved, Party A shall apply to the housing management department, and the original design unit or a design unit with corresponding qualification levels will review the safe usability of the modification plan. A written certificate must be issued and approved by the housing management department.
8. If Party A still needs to use part of the room during the construction period, Party A shall be responsible for cooperating with Party B in security and fire-fighting work.
9. Participate in the supervision of project quality and construction progress, and participate in the acceptance of project materials, acceptance of hidden projects, and completion acceptance.
Article 5: Party B’s work
1. Strictly implement construction specifications, quality standards, safe operating procedures, and fire prevention regulations during construction, and complete the projects agreed in this contract safely, with high quality, and on schedule content.
2. Strictly implement the construction site management regulations of the municipal construction administrative department:
(1) Without the approval procedures and reinforcement drawings of the housing management department, the main body of the building and buildings in the project shall not be demolished or modified. For load-bearing structures, the ground load of the building shall not be increased, and the original indoor heating, heating, gas and other pipeline facilities shall not be modified.
(2) No noise-generating decoration such as knocking, chiseling, planing, or drilling is allowed between 12:00 and 14:00, and between 18:00 and 8:00 the next day. Renovation activities.
(3) Party B shall bear the responsibility for repairs and loss compensation if pipes in adjacent residential buildings are blocked, leaked, water outage, power outage, etc. due to decoration construction.
(4) Responsible for the protection of finished project products, equipment and remaining furniture and furnishings in the living room.
(5) Ensure that the upper and lower water pipes in the living room are smooth and the bathroom is clean.
(6) Ensure the cleanliness of the construction site and clean the construction site after completion every day.
3. Provide Party A with access conditions for various standards, specifications, calculations, reference prices and other written information involved in the signing and performance of this contract through notification of website, unified publicity, etc.
4. If Party A is a member of an ethnic minority, Party B shall respect their ethnic customs and habits during the construction process.
Article 6: Project Changes
If any changes to the project contents agreed in the contract are required during the construction period, both parties shall reach an agreement through consultation. Both parties to the contract must sign a written change agreement and adjust the relevant project fees and construction period at the same time. The project change agreement serves as the basis for completion settlement and extension of the construction period.
Article 7: Supply of materials
1. Provide materials in accordance with the supply methods and contents agreed in the "Project Materials and Equipment Detailed List" for home decoration of this contract prepared by Party B.
(1) For materials and equipment that shall be provided by Party A, Party A shall notify Party B before the materials and equipment arrive at the construction site. Both parties will agree to accept the materials, equipment quality, and environmental protection standards and handle the handover procedures.
(2) For materials and equipment that should be provided by Party B, Party B shall notify Party A before the materials and equipment arrive at the construction site. Both parties will agree to accept the materials, equipment quality, and environmental protection standards, and Party A will confirm and file them.
(3) The building decoration materials provided by both parties must comply with the "Limited Standards for Hazardous Substances in Interior Decoration" issued by the State Administration of Quality Supervision, Inspection and Quarantine, and have professional qualifications recognized by the relevant administrative departments. Test qualification report issued by the testing agency.
(4) If one party has objections to the materials provided by the other party and needs to conduct re-inspection, the testing fees shall be paid in advance by it; if the materials are indeed unqualified after testing, the testing fees will ultimately be borne by the other party.
(5) After the materials and equipment provided by Party A have been inspected and accepted by Party B, and the handover procedures have been confirmed and completed, Party B shall be responsible for the storage and quality control of the materials and equipment during construction and use.
Article 8: Delay in construction period
1. If the completion date is delayed due to the following reasons, the construction period shall be postponed upon confirmation by Party A:
(1) Changes in project quantities or design changes;
(2) Force majeure;
(3) Other circumstances in which Party A agrees to postpone the construction period.
2. If the completion date is delayed due to the following reasons, the construction period shall be postponed:
(1) Party A fails to complete the work for which it is responsible as stipulated in the contract, thus affecting the construction period;
(2) Party A’s failure to pay the project price as agreed in the contract affects normal construction;
(3) Other situations where the construction period is delayed due to Party A’s responsibility.
3. If the project cannot be completed on time due to Party B's responsibility, the construction period will not be postponed; if there are problems with the project quality due to Party B's fault, the rework costs will be borne by Party B, and the construction period will not be postponed.
4. To determine the delay in the construction period caused by the "written agreement recognized by both parties" as the basis for determining the responsibilities of both parties.
Article 9: Quality Standards
1. In terms of indoor environmental pollution control during decoration, the standards of the "Code for Control of Indoor Environmental Pollution in Civil Construction Projects" should be strictly followed.
2. The construction quality of this project shall be implemented in accordance with the following _________ standards:
(1) "Beijing Quality Acceptance Standards for Family Room Decoration Projects";
(2) "Beijing Quality Acceptance Standards for Advanced Architectural Decoration Projects".
3. When the two parties have disputes over project quality or indoor air quality during completion acceptance, they should apply for certification by a professional testing agency recognized by the relevant administrative departments; the relevant fees for the certification process shall be paid by the applicant in advance , and will ultimately be borne by the responsible party.
Article 10: Project Acceptance
1. During the construction process, joint acceptance of project quality shall be carried out in the following stages:
(1) Material acceptance;
(2) Concealed project acceptance;
(3) Completion acceptance.
2. After the project is completed, Party B shall notify Party A for acceptance, and Party A shall organize acceptance within three days after receiving the completion acceptance notice. After passing the inspection and acceptance, both parties will go through the handover procedures, settle the balance, and sign the warranty form. Party B shall submit the water and electricity reconstruction drawings of its construction part to Party A.
3. Before both parties carry out completion acceptance, Party B is responsible for protecting the safety of the finished project and the project site.
4. Party A is not allowed to move in if both parties have not completed the acceptance procedures. If Party A moves in without authorization, it will be deemed that the acceptance has been passed, and the resulting losses will be borne by Party A.
5. When there are individual problems in the project quality, indoor air quality and economy during the completion acceptance that do not involve major problems, both parties shall reach an agreement to resolve the remaining issues in the completion acceptance and sign the "Agreement for Solving the Remaining Issues in the Completion Acceptance" (as an attachment to the completion acceptance form) You can also check in first later.
6. From the date of acceptance by both parties, the warranty period for the interior decoration project under normal use conditions is two years, and the warranty period for the kitchen and bathroom anti-leakage projects with waterproofing requirements is five years. Year.
Article 11: Method of payment for project payment
1. After the contract is signed and becomes effective, Party A shall pay Party B the project payment according to the agreement in the list:
_____________ shall be paid three days before the start of construction;
_____________ shall be paid when the project progresses more than half.
Payment___________ shall be paid upon completion and acceptance.
2. The project progress is more than half, which means that all the water and electricity pipelines in the project have been laid, the walls and top base layers have been completed in accordance with the process requirements, and the basic production and installation of doors, windows and fine wood white stubble products has been completed. Define the standard for more than half of the project.
3. After the project acceptance is passed, Party A will review the project settlement form submitted by Party B. If there is no objection within two days from the date of submission, Party A will be deemed to have agreed to pay Party B the final payment for the project.
4. After the project payment is fully settled, Party B will issue a formal unified invoice to Party A as the project payment settlement voucher.
Article 12: Liability for breach of contract
1. If one party fails to perform its contractual obligations as agreed and causes losses to the other party, it shall bear liability for compensation; if one party is punished for violating relevant legal provisions , the final responsibility lies with the responsible party.
2. If one party is unable to continue to perform the contract, it shall promptly notify the other party, and the responsible party shall bear the losses caused by the termination of the contract.
3. If Party A fails to pay the second and third project fees within the time limit specified in the contract without justifiable reasons, Party A shall pay Party B a penalty of 2‰ of the delayed part of the project payment for each day of delay.
4. If the construction period is delayed due to Party B's responsibility, Party B shall pay Party A a liquidated damages of 2‰ of the project cost of this contract for each day of delay.
5. If the project quality and indoor air quality are unqualified due to Party B’s responsibility, Party B will carry out rework, repairs, comprehensive management and compensation according to the following agreements:
(1) For unqualified project quality Party B must completely rework and repair the parts. Delay in delivery of the project due to rework shall be deemed as project delay, and liquidated damages shall be paid according to the standards of 12 and 4.
(2) If the indoor air quality is unqualified, Party B must carry out comprehensive management. Delay in project delivery due to governance shall be deemed as project delay, and liquidated damages shall be paid according to the standards of 12 and 4.
(3) If the indoor air quality still does not meet the standard after treatment and it is indeed Party B’s responsibility, Party B shall return the full price of the contracted project to Party A; if Party A is also responsible for the non-compliance, Party B may The return ratio will be reduced accordingly.
Article 13: Dispute Resolution Methods
For disputes arising under this contract, both parties shall negotiate or apply to the market organizer, consumer association, etc. for mediation to be resolved through negotiation or mediation. If the dispute cannot be resolved, the dispute shall be sued in the People's Court of _________ or apply for arbitration in accordance with the arbitration clause or arbitration agreement reached separately.
Article 14: Supplementary Provisions
1. This contract will take effect after it is signed (sealed) by both parties.
2. The project shall not be subcontracted after the signing of this contract.
3. Both parties may make changes or supplements to this contract in writing. However, if the changes or supplements reduce or exempt Party B from the responsibilities stipulated in this contract, this contract shall still prevail.
4. If the performance of the contract is affected or losses are caused due to reasons that are not attributable to both parties, both parties shall negotiate and resolve the matter in accordance with the principle of fairness.
5. If Party B withdraws from the market, the market sponsor shall first bear the liability for compensation; after the sponsor assumes responsibility, it has the right to recover compensation from Party B.
6. This contract will automatically terminate after completion.
Party A (signature)_______________ Party B (signature)_______________
_________year____month____day______year____month____day
p>Articles related to the universal version of the contract sample:
★ Service contract template (5 general articles)
★ House rental contract template
★ Five classic examples of general version of cooperation agreement
★ General version of formal cooperation agreement (5 articles)
★ Share transfer contract agreement template (5 general articles)
★ Five classic samples of general project cooperation agreement
★ Sample of store transfer contract agreement (5 general samples)
★ 5 general samples of commercial project cooperation contract
★ Ten company employee labor contract templates
★ General version of house decoration contract agreement