Simple version of personal engineering labor contract 1 employer: _ _ _ _ _ _ (hereinafter referred to as Party A)
Contractor: _ _ _ _ _ _ (hereinafter referred to as Party B)
Based on the principle of equality, mutual benefit and unanimity through consultation, Party A and Party B have reached the following terms and conditions of the contract on the construction labor costs for common compliance.
Article 2 Scope of Contract
Cast-in-place concrete engineering (comprehensive), formwork support (including scaffolding and formwork production and installation), and steel bar production and installation; Manufacture and installation of prefabricated components; Bricklaying; Interior and exterior decoration, scaffolding (including steel pipes and fasteners); Demolition of buildings (including slag removal) and erection of temporary facilities; Piecemeal estimation and all construction engineering machinery and equipment (all works except fire protection installation and waterproof works).
Article 3 Contract Amount
Composition of contract amount = unit price _ _ _ _ _ Yuan/m2 × paid-in quantity.
Except for fire fighting installation and waterproofing works, all labor costs of this project have been included in the project price, and no other projects will be set up. If yes, it shall be determined on the spot according to the actual situation.
This unit price has included a series of expenses such as management fee, tool fee, mechanical equipment fee, transportation fee and insurance fee.
Article 4 Time limit for a project (_ _ _ _ month)
(1) Commencement Date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
(2) Completion date: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 5 Technical Requirements for Construction
(1) Before each project starts, Party A's construction technicians shall make disclosure to Party B, which shall be signed by Party B's representative in writing.
(2) The representative of Party B must guide the workers to carry out the construction according to the technical disclosure and construction specifications. Make a model first, and then start construction after reaching the standard.
(3) The first working procedure must be carried out according to the steps of disclosure, construction, inspection and acceptance, and the next working procedure can only be carried out after the completion and acceptance of this working procedure.
Article 6 Responsibilities and Work of Both Parties
(I) Work of Party A
1. Coordinate the working relationship related to Party B's construction;
2. Send the construction management team to the site to arrange the project progress, project quality and construction steps, guide Party B's construction, and supervise and inspect the quality and safety work.
(II) Work of Party B
1. Strictly implement the requirements of the contract on time limit for a project, quality and safety, allocate corresponding types of work and the number of workers required by Party A, obey the arrangement of the construction personnel, and carry out the construction according to the specifications.
2. Strengthen the management of laborers, educate laborers to abide by laws and regulations, and handle temporary residence permits for migrant workers and other related procedures. Strengthen the awareness of safety, fire prevention and theft prevention.
3. Organize civilized construction of workers, and important types of work such as steel bar workers and welders must hold relevant certificates, strengthen the management of the construction site, and make sure that the materials are clear after work. Civilization construction.
Article 7 Project acceptance
(a) the quality of the project, to meet the requirements of the national engineering quality inspection and evaluation standards, to ensure that the subdivisional work is excellent, and the subdivisional work to ensure that the unit project is qualified.
(2) Take the visas of Party A's construction personnel and supervision engineer as the acceptance basis.
(3) In case of quality problems caused by Party B, Party B shall take full responsibility for rework and bear the loss of materials and labor costs.
(4) Party A shall pay _ _ _ _ _ _ _ _ _ _ _ USD to Party B.
Article 8 Payment of Labor Costs
(1) Calculate the workload according to the time when the project owner pays the project payment, and calculate the workload according to the image progress. If the expected construction period is reached, _ _ _ _ _ _% of the total workload will be paid. If the workload exceeds the planned amount, 80% will be paid. If it fails, _ _ _ _ _ _% of the payment will be paid, and the advance payment must be deducted. If Party A fails to pay wages on time, Party B has the right to ask Party A to pay wages or stop work.
(2) After the project is completed and accepted, calculate the total workload, after deducting the total loan amount (prepaid insurance premium), it will be _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 9 Safety responsibilities
Party B must strictly abide by Party A's rules and regulations and construction safety operation procedures. Party B shall be responsible for the safety accidents caused by Party B's illegal operation, and all expenses incurred have nothing to do with Party A. During the construction period, Party B must buy personal accident insurance for all workers, and the insurance premium shall be borne by Party B. Party B shall submit the list of workers, and Party A shall handle the insurance formalities for Party B. ..
Article 10 Matters not covered in this contract shall be negotiated separately by both parties, and shall be regarded as an annex to this contract for both parties to abide by.
Article 11 Other agreements
If Party B's technical level and construction period can't meet Party A's requirements during the construction process, Party A has the right to ask Party B to leave unconditionally without settlement, and claim for the delayed construction period and reputation loss from Party B..
Article 12 This contract is made in duplicate, one for each party, with the same legal effect. It shall come into effect after being signed (sealed) by both parties, and will naturally become invalid after the project is completed and accepted.
Party A (seal): _ _ _ _ _ _ _ _ _ _ Party B: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Representative (signature): _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ ID number: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Personal engineering labor contract model version 2 Party A: _ _ _ _ _ (hereinafter referred to as Party A) Party B: _ _ _ _ _ (hereinafter referred to as Party B)
In accordance with the Labor Law of People's Republic of China (PRC), the Labor Contract Law of People's Republic of China (PRC) and relevant laws and regulations, and following the principles of equality, voluntariness, fairness, honesty and trustworthiness, Party A and Party B sign this contract through friendly negotiation. ..
In order to clarify the rights and obligations of both parties, the following clauses are formulated for both parties to abide by.
I. Overview of the Project
Project name: _ _ _ _ _ _ _
Project location: _ _ _ _ _ _ _
Project scale: _ _ _ _ _ _
Second, the project contracting and settlement methods
This project is contracted to Party B in the form of labor service package, and the contract price is in the form of itemized unit price and total price, which is settled according to the latest calculation method of construction area in Shaanxi (bay window area is not calculated, balcony is calculated as half area), and the comprehensive unit price is _ _ _ _ _ _ _ _ _ yuan/㎡ (excluding tax). It is required that contracting enterprises (teams) must have the qualifications of construction labor service enterprises, safety and employment, have a professional labor service team, and the staff must hold relevant certificates.
Three. Scope and content of project contracting
All civil works (rough walls and rough ground) such as foundation works, main works, secondary structures, plastering works, ground works, roofing works, indoor and outdoor backfilling, outdoor aprons and steps, equipment foundations, building materials of main structures, etc. within the scope of construction drawings and construction drawing change documents. The contract unit price includes the following specific contents:
(a), including content
1. Foundation works: fabrication, binding, placement and pouring of underground pile reinforcement, pouring of foundation cushion and waterproof protective layer (excluding coiled material waterproofing).
2. Main projects: steel bar blanking, processing, binding, installation, welding and wire connection (including the cost of casing materials); Template blanking, fabrication, template support and dismantling, screw cutting (required oxygen, acetylene and welding torch materials shall be provided by Party B at its own expense), customized template hoisting, installation, dismantling, cleaning and oiling (including fixed steel template rental fee); Concrete pouring, maintenance, grinding, pump pipe connection, cleaning and maintenance, including post-cast strip and cable well; Erection, dismantling, stacking and painting of scaffolding inside and outside the main body and steel pipes for temporary facilities (the above materials shall be provided by Party B at its own expense); Setting-out of main body construction survey (the control line shall be the responsibility of Party A).
3. Accessory structures: infilled walls (masonry works), ring beams, lintels, constructional columns, retaining walls, water stop beams, aprons, steps, etc.
4. Plastering works: interior wall plastering and exterior wall plastering (including doors and windows, holes, lines, etc.). ), parapet plastering, coping plastering, stair walkways, expansion joints and glass strips.
5. Floor engineering: leveling and cleaning of floor base, leveling of cement mortar, leveling of concrete cushion layer and surface layer, and roughening and curing of concrete.
6. Roofing engineering: slag and slope finding, cement mortar leveling, drilling and installation of PVC exhaust pipe, fabrication, installation and modulation of rigid layer reinforcement.
7. Mechanical equipment: tower cranes, elevators, cloth machines, hanging baskets, reinforcing steel machinery, (welding machinery) woodworking machinery, concrete machinery, power distribution cabinets, secondary distribution boxes, cables, wires and water pipes and accessories for floor maintenance shall be the responsibility of Party B, while power distribution equipment and cables above secondary boxes, urban pipe networks, pipes and accessories from water supply points to the construction site shall be the responsibility of Party A..
8. Materials: commercial concrete, steel bars, waterproof, thermal insulation and water-stop steel plates (water stops) must go to the construction site; The main materials needed for the project, such as bricks, sand, cement and stones, shall be provided by Party A, and the rest materials shall be provided by Party B (waterproof screws, steel pipes, square timber, templates, fasteners, screws, mechanical connection sleeves, shear wall through-wall screws, concrete anti-freezing insulation materials, turnover materials, etc.).
9. Construction management: Party B must have a complete and independent project department organization (1 responsible for construction, 1 responsible for technology, 1 responsible for safety, 1 responsible for technology, 1 responsible for quality, 1 responsible for materials,/kloc-0.
10, secondary handling of all materials in the yard and garbage cleaning.
1 1. Party B must do a good job in creating a provincial-level civilized construction site (erection of work shed, erection of safe passage, protection of three guarantees, temporary climbing of stairs, protective shed, installation signs, site sanitation in the building, housekeeping of temporary dormitory, site hardening, environmental sanitation, etc.). ).
12. Facilities cooperation: Party B actively cooperates with other installation teams to provide tower cranes, elevators and other contents free of charge, and do a good job in process interpenetration and finished product protection.
13, the loss of concrete and steel bars will be increased by 2% according to the number of drawings (the remaining materials of steel bars will be handled by Party A), and the stones and sand will not exceed 3%. If the material exceeds the loss range, Party A will deduct it from the project payment (calculated according to the purchase price of Party A).
14. Insurance premium for accidental injury of construction personnel: the insurance shall be purchased by Party A, and the expenses shall be deducted from Party B's project payment.
15. Cooperate with Party A to handle the handover acceptance according to the submitted complete statements and original technical and economic data. Do a good job in the protection of finished products of buildings, structures, underground pipelines and completed projects around the construction site. Party B shall bear all economic losses caused by the damage of finished products.
(2), exclude the content
1, external wall insulation and coating, stone pasting in business district, strong current, weak current, fire protection, ventilation, heating, waterproof engineering, doors and windows, water supply and drainage.
Fourth, quality standards.
All the project contents contracted by Party B must meet the requirements of relevant standards and specifications, and the first pass rate of the project reaches _ _ _ _ _%. Visual quality requirements: the concrete shall not have appearance quality defects such as rebar leakage, honeycomb, pits, bubbles, slag inclusion, mold running, etc. The angle of yin and yang of wall column beam slab should be founder (after formwork removal, protective measures should be taken). The measurement items of components shall be measured according to the requirements of construction acceptance specifications, and the measurement results shall reach above _ _ _ _ _ _%. The overall quality standards must meet the requirements of national specifications, if any.
Five, the project schedule requirements
The effective time limit for a project is _ _ _ _ _ _ days from the start of foundation cushion (brick mold) construction to the completion acceptance of the project within the scope of the contract. _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
After Party B enters the site, according to the construction period requirements of Party A and the actual situation of the construction site, Party B shall prepare a detailed, concrete and feasible construction organization plan (which shall be submitted to Party A for record and reference); Scientific organization, reasonable arrangement, to ensure the completion of the construction period within the contract period.
Sixth, the construction period is postponed.
1, forced to stop work due to unforeseeable and irresistible natural disasters.
2. The construction cannot be continued because Party A changes the scheme or construction drawing.
3. Because Party A fails to provide construction drawings, materials and equipment on time, or fails to meet the specification requirements after entering the site, Party A is forced to stop work or cannot carry out construction.
4. External interference leads to shutdown.
Seven, stop working
Considering that changes in government policies may lead to work stoppage, Party A will not bear any economic losses to Party B during the work stoppage.
Eight, safe production and civilized construction
1. Safety objective: to create a "zero" accident project; The goal of civilized construction: to create a provincial civilized construction site. During the construction period, the construction site shall be equipped with standards and specifications related to safety production, formulate various safety technical operation procedures, and set them in obvious positions. Safety technical operating rules should be the main content of safety activities and safety education.
2. After Party B enters the site, both parties sign detailed responsibility letters on safety production, environmental protection and project quality, which have the same legal effect as this contract. Before the construction operation, Party B's technicians shall make safety technical disclosure to the construction team and workers on the construction safety technology of partial projects, and the safety management personnel shall participate in the safety technical disclosure, which must be made in writing and signed by both parties.
3. When Party B enters the site, it shall organize the examination and use of social idlers with unknown sources. The hidden dangers of accidents found must be rectified according to the principle of "three determinations", and written records should be made and filed.
4. Party B's personnel should dress neatly and behave in a civilized manner.
5. Party B shall handle the Temporary Residence Permit for migrant workers in time.
Nine, payment method and time limit for a project
1. Both parties of this project agree that the first payment will be paid after the construction of the second floor of the main body of the project is completed, and the service fee will be paid to Party B according to _ _ _% of the completed works, and then _ _ _% of the completed works will be paid every month. 85% service fee will be paid when the main body is capped and the secondary structure is completed, and _ _ service fee will be paid after the project settlement is completed. Keep _ _ _ _ _ _ _ _% quality guarantee money (interest-free) and pay it to Party B in one lump sum within one year without quality problems. Due to the tight project schedule and strict rewards and punishments by the owner, in order to ensure the timely completion of the project, Party B shall pay _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
2. When Party B enters the construction site, it must work out a detailed (year, month, week) schedule according to the time limit determined by Party A. During the construction process, it should be carefully organized and constructed to ensure that the construction period is completed on time. If the construction period is delayed due to Party B's reasons, if the construction period is not postponed after deducting the construction period deposit, it will be punished according to the contract signed between Party A and the owner. The fine is _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
X. Rights and obligations of both parties
I. Party A
1. Party A has the right to examine Party B's qualification, and has the right to punish, financially compensate and dismiss Party B's violation of the contract terms.
2. According to the needs of the project, Party A shall unconditionally abide by the contents of the project contract arranged by Party B. ..
3. Party A shall provide Party B with convenient construction conditions as far as possible, and pay the labor fee according to the labor contract and the owner's payment. If Party A delays at will, all losses and consequences caused shall be borne by Party A, and Party B may recover all expenses (including but not limited to legal fees, arbitration fees, appraisal fees and attorney fees) from Party A according to law.
4. Party A has the right to disclose the macro construction technology, safety quality and acceptance standard to Party B according to the construction drawings and relevant documents (the specific construction plan shall be disclosed by Party B).
5. Party A is responsible for supervising, inspecting and assessing the construction progress, quality, safety and management during the construction.
6. Party A shall provide 1 set of construction drawings and related materials to Party B in time before construction.
7. Party A shall register the construction personnel provided by Party B in real-name registration system, establish health status files, and have the right to prohibit Party B from employing disabled or mentally retarded personnel.
8. Party A shall provide Party A's supplied materials (commercial concrete, steel bars, bricks, cement and stones) in time as required by Party B, and Party B shall have the right to claim compensation from Party A in case of delay.
9. For the losses caused by natural disasters (earthquake, gale, lightning, rainstorm, freezing), Party B will only bear its own property losses, and Party A will bear the rest.
10. If Party A's temporary employment fee for the current month does not exceed _ _ _ _ _ _ _ _ _ Yuan, no fees will be charged.
(II) Party B
1. Party B must submit to Party A the qualifications conforming to the contract, safety and employment, pay accident insurance for workers, and take the initiative to undertake all the work under the contract to ensure the quality, progress and safety of the project.
2. Party B must review the construction drawings before entering the site for construction. If any omission or mistake is found in the design drawings, it shall be reported to the technical department of Party A immediately, otherwise Party B will also bear the corresponding responsibilities.
3. Party B must carry out safety production according to the construction specifications, ensure safe and civilized construction, and have reliable safety measures. All safety accidents and expenses during the construction shall be borne by Party B, and Party A shall not be held responsible.
4. Party B has the right to reject Party A's instructions that do not meet the requirements of safe production, and put forward its own opinions for Party A's reference.
5. Party B shall not conceal or employ disabled or mentally retarded personnel without permission, and provide the roster and copies of ID cards of all Party B's construction personnel.
6. Party B shall manage its own team and shall not engage in illegal and criminal activities (such as gambling, prostitution, etc.). ) online and offline. Party B shall bear all the responsibilities arising therefrom, and Party A shall not bear any responsibilities.
7. In order to ensure the construction period, Party B must ensure the supply of construction labor, mechanical equipment and consumables according to Party A's requirements.
8. Party B shall provide Party A with the schedule of materials supplied by Party A 15 days in advance according to the construction drawings and construction plans, and shall not report more or less at will. The error shall be controlled within 2%, and the losses caused to Party A by the excess shall be borne by Party B. After the materials, components and construction wastes supplied by Party A enter the site, Party B shall timely accept and keep them. In the construction site should be classified according to the layout. If Party B supplies to Party A,
9. Human resources arrangement during the construction of the project: Party B is required to work out the planned employment schedule of each stage of the project, and Party A will compound the actual employment of Party B in each construction stage according to the schedule, and deduct RMB _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ If the actual number of Party B is less than _ _ _ _% of the planned number, Party A has the right to dismiss Party B and bear all losses caused thereby.
10. Within one month after Party B enters the site, Party A shall assist in handling the corresponding insurance at the place where the contracted project is located, and deduct the expenses from Party B's project payment, and provide the insurance purchase documents for Party B's inspection. Failing to provide it shall be deducted according to 2 yuan/㎡, and all responsibilities, consequences and expenses arising therefrom shall be borne by Party A.
Eleven, about work-related injuries (personal injuries) and wage arrears.
1. During the construction of the project contracted by Party B, Party B shall be responsible for solving the industrial accidents of its employees and employees and the personal and property damage of a third party caused by its employees and employees, and Party A shall not be responsible.
2. After the completion of this project, Party B shall pay the workers' wages on time and provide the payroll for paying the workers' wages. If Party B deducts or defaults on the wages of workers without reason, and Party B's personnel and employees report the phenomenon of wage arrears to the relevant departments, Party B shall bear all responsibilities and consequences. If any loss of reputation or property is caused to Party A due to the above matters, Party A has the right to directly deduct it from Party B's service fee or directly compensate for it; If the expenses are insufficient to compensate Party A, Party A may recover all expenses from Party B according to law (including but not limited to litigation, arbitration, evaluation and lawyer's agency fees).
Twelve. responsibility for breach of contract
1. Party A and Party B shall be honest and trustworthy, strictly abide by the terms of the above agreement, and shall not arbitrarily change the terms, let alone breach the contract. In case of breach of contract, the breaching party shall bear economic losses and 20% of the total agreement price as penalty.
2. If the reputation of the other company, on-site equipment and certain economic losses are caused to the project due to the reasons of Party A and Party B, the injured party has the right to require the injured party to compensate all the losses, and the injured party can recover all the expenses (including but not limited to litigation, arbitration, evaluation, appraisal and lawyer's agency fees) from the injured party according to law.
3. All Party B's equipment, tools and instruments must be kept by Party B, and Party B shall not put forward other requirements to Party A, and shall not make excuses to affect the quality and progress of the project, and the losses caused thereby shall be borne by Party B. ..
Personal engineering labor contract model simple version of the third party _ _ _ _ _ _ _ _ (hereinafter referred to as Party A)
Labor Contractor _ _ _ _ _ _ _ _ (hereinafter referred to as Party B)
In order to clarify the cooperation rights and responsibilities of Party A and Party B, and ensure the safety of project implementation and related operators, Party A and Party B, through consultation, signed this contract in accordance with the Economic Contract Law of the People's Republic of China, the Labor Law and relevant laws and regulations, combined with the specific conditions of this project and the relevant provisions of the company's management articles of association, in order to clarify the rights, obligations and economic responsibilities of both parties, and abide by it jointly.
Article 1: Project Overview
Project name: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Structure type: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Building area: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Number of floors: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Article 2: Scope, content and requirements of the contract.
1. The labor contract of Party B in this project specifically includes:
Party B must tidy up the materials used by itself according to the regulations, so as to clean up the materials after work and carry out civilized construction on site.
2, the time limit for a project requirements
Must be completed in accordance with the construction schedule agreed by both parties.
3. Quality requirements
The engineering quality of the division (sub-division) contracted by Party B (according to the existing construction drawing) must reach the "qualified" quality level and the impression is "good". If the result can't be determined at that time, the conclusion can only be reached after the acceptance of the main project, and all the labor expenses can be settled.
Article 3: Safety requirements
1. When Party B's personnel enter the construction site, they must carry out safety induction education, wear safety protection articles, raise safety awareness, and carry out construction in strict accordance with operating procedures. If safety accidents and casualties occur due to violation of operating procedures, the consequences will be at your own risk. Party A does not assume economic responsibility and civil joint liability, and Party B is responsible for all of them.
2. Fighting is strictly prohibited on the construction site. If it happens, both parties will be fined _ _ _ _ _ _ _ yuan and sent to the local judicial department for handling, and the consequences will be at their own risk.
3. Party B's personnel shall take good care of the property and semi-finished products, and compensate the expenses if they are damaged or lost; Ensure safe production, civilized construction and post-construction cleaning. Expenses such as material loss, waste and rework shall be deducted from Party B's salary.
4. Workers who enter the site by Party B shall pay relevant fees and go through all formalities according to regulations. All relevant expenses that should be borne by Party B according to regulations, such as post certificate, qualification certificate and insurance premium, shall be paid by Party B itself.
Article 4: Contract Form and Price Settlement Method
1, and the contract form is a labor contract.
2. Contract price: The project within the contract scope, after acceptance and evaluation, is calculated according to the actual processing area, reaching ① _ _ _ _ _ _ _ _ _ _ _ yuan/square meter.
3. Settlement procedures
Party B shall settle accounts according to the square meters actually processed. On the way, Party A can advance Party B's living expenses. After the project is completed and accepted, Party A shall pay _ _ _ _ _ _ _ _% to Party B and the remaining _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _.
Article 5: Rights and obligations of both parties
1. Rights and obligations of Party A
(1) Party A has the right to propose rectification for Party B's illegal behavior. If Party B fails to make rectification within the time limit, thus causing economic losses to Party A, Party A has the right to unconditionally dismiss all the personnel at Party B's site, terminate this contract, and fail to settle the unsettled labor costs of Party B's completed projects, and all losses caused thereby shall be borne by Party B. ..
(2) Party A has the obligation to provide materials on time according to the construction progress and budget quota. (Note: The information required by Party B must be submitted to Party A one week in advance)
(3) Party A has the obligation to timely and accurately do the leveling and lofting of technical disclosure.
2. Rights and obligations of Party B
(1) Party B has the right to use its own labor force according to law.
(2) Party B has the obligation to equip the hired workers with all kinds of tools at hand.
(3) Party B is responsible for managing its own personnel, checking the identity of workers entering the site, and it is strictly forbidden to fight on site. In case of casualty accidents due to its own reasons or those of others, Party B has the obligation to bear economic, civil and joint liabilities.
(4) If Party B employs workers in violation of the rules and regulations, causing casualties to himself and others, Party B must bear all the consequences.
(5) In case of fire caused by Party B or hired workers, Party B shall be responsible for the consequences.
(6) Party B shall be responsible for the losses caused to Party A or others by the theft of Party B or employees.
(7) Party B has no right to subcontract the project. When a special division (sub-division) project must be subcontracted, it can only be subcontracted with the consent of Party A.. After the subcontract is signed, Party B shall take full responsibility for Party A. ..
(8) Party B is prohibited from hiring child laborers to enter the site for construction.
Article 6: Liability for breach of contract
Neither party hereto shall breach the contract; In case of breach of contract, the breaching party shall bear the liability for breach of contract; And compensate the other party's economic losses in accordance with relevant regulations, especially the quality breach;
Article 7: Effectiveness and Termination of the Contract
1. The signature (seal) of both parties to this contract takes effect, and the settlement price of both parties is terminated.
2. This contract is made in triplicate (one for Party A, Party B and Project Department respectively).
Article 8: Supplementary provisions
1. If the terms of this contract conflict with the current national construction market management documents, regulations and relevant rules and regulations of this contract, both parties shall negotiate on the basis of the documents and sign a supplementary agreement separately.
2. Matters not covered in this contract shall be negotiated separately by both parties. Party A's project department is responsible for implementation.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _